HomeMy WebLinkAbout09 - Public Works Inspection and Construction Administration ServicesPORT CITY OF
O �
_ i NEWPORT BEACH
City Council Staff Report
<i FO RN
April 9, 2019
Agenda Item No. 9
TO: HONORABLE MAYOR AND MEMBERS OF THE CITY COUNCIL
FROM: David A. Webb, Public Works Director - 949-644-3311,
dawebb@newportbeachca.gov
PREPARED BY: Michael J. Sinacori, Acting City Engineer
msinacori@newportbeachca.gov
PHONE: 949-644-3342
TITLE: Public Works Inspection and Construction Administration Services —
Approval of On-call Professional Services Agreements
ABSTRACT:
Public Works inspection and construction administration services are required for various
Capital Improvement Program (CIP) projects as well as for development and utility permit
work in the public right-of-way. In addition to City staff inspectors, the Public Works
Department uses on-call consultants to provide supplemental inspection and construction
administration services to oversee and process the large workload of projects and
development/utility permit work. Staff issued a Request for Qualifications for these
professional services and is requesting City Council's approval to enter into three (3)
separate on-call Professional Services Agreements with Interwest Consulting Group,
Project Partners, Inc. and Willdan Engineering.
RECOMMENDATION:
a) Determine this action is exempt from the California Environmental Quality Act (CEQA)
pursuant to Sections 15060(c)(2) and 15060(c)(3) of the CEQA Guidelines because
this action will not result in a physical change to the environment, directly or indirectly;
and
b) Approve three separate 5 -year term on-call Professional Services Agreements with
Interwest Consulting Group, Inc., Project Partners, Inc., and Willdan Engineering at a
not -to -exceed amount of $300,000 per agreement, and authorize the Mayor and City
Clerk to execute the agreements.
FUNDING REQUIREMENTS:
The current adopted budget includes sufficient funding for these services. It will be
expensed as needed to the Professional Services account in the Public Works
Department (010808081-811008) as well as respective capital improvement project
budgets within the Capital Improvement Program. Funds for services to be performed in
subsequent fiscal years will be expensed in a similar fashion through approved operating
and CIP budgets.
9-1
Public Works Inspection and Construction Administration Services —
Approval of On-call Professional Services Agreements
April 9, 2019
Page 2
DISCUSSION:
The Public Works Department uses a combination of City staff and outside consultant
and contract services to accomplish a variety of tasks related to the implementation of the
City's Capital Improvement Program, Transportation and Development Services, and
operations activities such as refuse collection, field maintenance, and landscape
maintenance.
The current Capital Improvement Program remains large and the need for Contract
Inspection and Construction Administration staff continues to remain. Knowing current
contracts with Consultant Firms who provide supplemental inspection and construction
administration services to the Department would expire in February 2019, a Request for
Qualifications (RFQ) was issued in late 2018 for Public Works CIP development and
permit inspection services and construction administration. Five firms were requested to
submit Statements of Qualifications and proposals; however, only four proposals were
received. Using the qualification -based selection process, proposals were evaluated by
the review team independently. Following staff review, it was determined that all four of
the submitting firms were equally qualified, with three of them having provided recent
services to the City. As the need for contract inspection and construction administration
services fluctuates, in addition to time constraints on how many hours a consultant can
work for the City in a staff capacity, staff recommended awarding contracts to all four
firms. Each firm, depending on the assignment needs and available personnel, would be
utilized at different times over the five-year contract term.
One of the four firms that submitted a proposal, NV5, Inc. (NV5), had not previously
provided inspection services to the City. To expand the contract inspection pool and due
to an immediate need in late 2018, staff executed an On -Call contract with NV5 with an
expiration date of July 31, 2021. Currently, NV5 provides staff support for development
services inspections. Services performed to date have met expectation.
In anticipation of future needs, staff recommends entering into new five-year On -Call
contracts with the remaining three consulting firms: Interwest Consulting Group
(Interwest), Project Partners, Inc. (Project Partners) and Willdan Engineering (Willdan).
Interwest and Project Partners have previously worked with the City on a variety of City
projects and private property developments. The most recent agreements expired at the
end of February 2019. Willdan Engineering currently provides traffic engineering staff
support services on an as -needed basis but also has an established inspection division.
ENVIRONMENTAL REVIEW:
Staff recommends the City Council find this action is not subject to the California
Environmental Quality Act (CEQA) pursuant to Sections 15060(c)(2) (the activity will not
result in a direct or reasonably foreseeable indirect physical change in the environment)
and 15060(c)(3) (the activity is not a project as defined in Section 15378) of the CEQA
Guidelines, California Code of Regulations, Title 14, Chapter 3, because it has no
potential for resulting in physical change to the environment, directly or indirectly.
9-2
Public Works Inspection and Construction Administration Services —
Approval of On-call Professional Services Agreements
April 9, 2019
Page 3
NOTICING:
The agenda item has been noticed according to the Brown Act (72 hours in advance of
the meeting at which the City Council considers the item).
ATTACHMENTS:
Attachment A —
Professional Services Agreement with Interwest Consulting Group, Inc.
Attachment B —
Professional Services Agreement with Project Partners, Inc.
Attachment C
— Professional Services Agreement with Willdan Engineering
9-3
ATTACHMENT A
ON-CALL PROFESSIONAL SERVICES AGREEMENT
WITH INTERWEST CONSULTING GROUP, INC. FOR
DEVELOPMENT AND UTILITY PERMIT INSPECTION SERVICES AND
CONSTRUCTION ADMINISTRATION
THIS ON-CALL PROFESSIONAL SERVICES AGREEMENT ("Agreement') is
made and entered into as of this 9th day of April, 2019 ("Effective Date"), by and between
the CITY OF NEWPORT BEACH, a California municipal corporation and charter city
("City"), and INTERWEST CONSUL TING GROUP, INC., a Colorado Corporation
("Consultant'), whose address is 15140 Transistor Lane, Huntington Beach, California
92649, and is made with reference to the following:
RECITALS
A. City is a municipal corporation duly organized and validly existing under the laws
of the State of California with the power to carry on its business as it is now being
conducted under the statutes of the State of California and the Charter of City.
B. City desires to engage Consultant to provide comprehensive construction
inspection and administration services on an on-call or as -needed basis ("Project').
C. Consultant possesses the skill, experience, ability, background, certification and
knowledge to provide the professional services described in this Agreement.
D. City has solicited and received a proposal from Consultant, has reviewed the
previous experience and evaluated the expertise of Consultant, and desires to
retain Consultant to render professional services under the terms and conditions
set forth in this Agreement.
NOW, THEREFORE, it is mutually agreed by and between the undersigned parties
as follows:
1. TERM
The term of this Agreement shall commence on the Effective Date, and shall
terminate on March 24, 2024, unless terminated earlier as set forth herein.
2. SERVICES TO BE PERFORMED
2.1 Consultant shall perform the on-call services described in the Scope of
Services attached hereto as Exhibit A and incorporated herein by reference ("Services"
or "Work"). Upon written request from the Project Administrator as defined herein,
Consultant shall provide a letter proposal for Services requested by the City (hereinafter
referred to as the "Letter Proposal'). The Letter Proposal shall include the following:
2.1.1 A detailed description of the Services to be provided;
2.1.2 The position of each person to be assigned to perform the Services,
and the name of the individuals to be assigned, if available;
and
2.1.3 The estimated number of hours and cost to complete the Services;
2.1.4 The time needed to finish the specific project.
2.2 No Services shall be provided until the Project Administrator has provided
written acceptance of the Letter Proposal. Once authorized to proceed, Consultant shall
diligently perform the duties in the approved Letter Proposal.
3. TIME OF PERFORMANCE
3.1 Time is of the essence in the performance of Services under this Agreement
and Consultant shall perform the Services in accordance with the schedule included in
Exhibit A and the Letter Proposal. In the absence of a specific schedule, the Services
shall be performed to completion in a diligent and timely manner. The failure by
Consultant to strictly adhere to the schedule set forth in Exhibit A and the Letter Proposal,
if any, or perform the Services in a diligent and timely manner may result in termination
of this Agreement by City.
3.2 Notwithstanding the foregoing, Consultant shall not be responsible for
delays due to causes beyond Consultant's reasonable control. However, in the case of
any such delay in the Services to be provided for the Project, each party hereby agrees
to provide notice within two (2) calendar days of the occurrence causing the delay to the
other party so that all delays can be addressed.
3.3 Consultant shall submit all requests for extensions of time for performance
in writing to the Project Administrator as defined herein not later than ten (10) calendar
days after the start of the condition that purportedly causes a delay. The Project
Administrator shall review all such requests and may grant reasonable time extensions
for unforeseeable delays that are beyond Consultant's control.
3.4 For all time periods not specifically set forth herein, Consultant shall
respond in the most expedient and appropriate manner under the circumstances, by
hand -delivery or mail.
4. COMPENSATION TO CONSULTANT
4.1 City shall pay Consultant for the Services on a time and expense not -to -
exceed basis in accordance with the provisions of this Section and the Letter Proposal
and the Schedule of Billing Rates attached hereto as Exhibit B and incorporated herein
by reference. Consultant's compensation for all Work performed in accordance with this
Agreement, including all reimbursable items and subconsultant fees, shall not exceed
Three Hundred Thousand Dollars and 001100 ($300,000.00), without prior written
authorization from City. No billing rate changes shall be made during the term of this
Agreement without the prior written approval of City.
Interwest Consulting Group, Inc. Page 2
9-5
4.2 Consultant shall submit monthly invoices to City describing the Work
performed the preceding month. Consultant's bills shall include the name of the person
who performed the Work, a brief description of the Services performed and/or the specific
task in the Scope of Services to which it relates, the date the Services were performed,
the number of hours spent on all Work billed on an hourly basis, and a description of any
reimbursable expenditures. City shall pay Consultant no later than thirty (30) calendar
days after approval of the monthly invoice by City staff.
4.3 City shall reimburse Consultant only for those costs or expenses specifically
identified in Exhibit B to this Agreement and the Letter Proposal or specifically approved
in writing in advance by City.
4.4 Consultant shall not receive any compensation for Extra Work performed
without the prior written authorization of City. As used herein, "Extra Work" means any
Work that is determined by City to be necessary for the proper completion of the Project,
but which is not included within the Scope of Services and which the parties did not
reasonably anticipate would be necessary at the execution of this Agreement.
Compensation for any authorized Extra Work shall be paid in accordance with the
Schedule of Billing Rates as set forth in Exhibit B and the Letter Proposal.
5. PROJECT MANAGER
5.1 Consultant shall designate a Project Manager, who shall coordinate all
phases of the Project. This Project Manager shall be available to City at all reasonable
times during the Agreement term. Consultant has designated Ludy Smeets, PE to be its
Project Manager. Consultant shall not remove or reassign the Project Manager or any
personnel listed in Exhibit A or assign any new or replacement personnel to the Project
without the prior written consent of City. City's approval shall not be unreasonably
withheld with respect to the removal or assignment of non -key personnel.
5.2 Consultant, at the sole discretion of City, shall remove from the Project any
of its personnel assigned to the performance of Services upon written request of City.
Consultant warrants that it will continuously furnish the necessary personnel to complete
the Project on a timely basis as contemplated by this Agreement.
5.3 If Consultant is performing inspection services for City, the Project Manager
and any other assigned staff shall be equipped with a cellular phone to communicate with
City staff. The Project Manager's cellular phone number shall be provided to City.
6. ADMINISTRATION
This Agreement will be administered by the Public Works Department. City's
Public Works Director or designee shall be the Project Administrator and shall have the
authority to act for City under this Agreement. The Project Administrator shall represent
City in all matters pertaining to the Services to be rendered pursuant to this Agreement.
Interwest Consulting Group, Inc. Page 3
7. CITY'S RESPONSIBILITIES
To assist Consultant in the execution of its responsibilities under this Agreement,
City agrees to provide access to and upon request of Consultant, one copy of all existing
relevant information on file at City. City will provide all such materials in a timely manner
so as not to cause delays in Consultant's Work schedule.
8. STANDARD OF CARE
8.1 All of the Services shall be performed by Consultant or under Consultant's
supervision. Consultant represents that it possesses the professional and technical
personnel required to perform the Services required by this Agreement, and that it will
perform all Services in a manner commensurate with community professional standards
and with the ordinary degree of skill and care that would be used by other reasonably
competent practitioners of the same discipline under similar circumstances. All Services
shall be performed by qualified and experienced personnel who are not employed by City.
By delivery of completed Work, Consultant certifies that the Work conforms to the
requirements of this Agreement, all applicable federal, state and local laws, and legally
recognized professional standards.
8.2 Consultant represents and warrants to City that it has, shall obtain, and shall
keep in full force and effect during the term hereof, at its sole cost and expense, all
licenses, permits, qualifications, insurance and approvals of whatsoever nature that is
legally required of Consultant to practice its profession. Consultant shall maintain a City
of Newport Beach business license during the term of this Agreement.
8.3 Consultant shall not be responsible for delay, nor shall Consultant be
responsible for damages or be in default or deemed to be in default by reason of strikes,
lockouts, accidents, acts of God, or the failure of City to furnish timely information or to
approve or disapprove Consultant's Work promptly, or delay or faulty performance by
City, contractors, or governmental agencies.
9. HOLD HARMLESS
9.1 To the fullest extent permitted by law, Consultant shall indemnify, defend
and hold harmless City, its City Council, boards and commissions, officers, agents,
volunteers, employees and any person or entity owning or otherwise in legal control of
the property upon which Consultant performs the Project and/or Services contemplated
by this Agreement (collectively, the "Indemnified Parties") from and against any and all
claims (including, without limitation, claims for bodily injury, death or damage to property),
demands, obligations, damages, actions, causes of action, suits, losses, judgments,
fines, penalties, liabilities, costs and expenses (including, without limitation, attorneys'
fees, disbursements and court costs) of every kind and nature whatsoever (individually,
a Claim; collectively, "Claims"), which may arise from or in any manner relate (directly or
indirectly) to any breach of the terms and conditions of this Agreement, any Work
performed or Services provided under this Agreement including, without limitation,
defects in workmanship or materials or Consultant's presence or activities conducted on
Interwest Consulting Group, Inc. Page 4
9-7
the Project (including the negligent, reckless, and/or willful acts, errors and/or omissions
of Consultant, its principals, officers, agents, employees, vendors, suppliers, consultants,
subcontractors, anyone employed directly or indirectly by any of them or for whose acts
they may be liable, or any or all of them).
9.2 Notwithstanding the foregoing, nothing herein shall be construed to require
Consultant to indemnify the Indemnified Parties from any Claim arising from the sole
negligence or willful misconduct of the Indemnified Parties. Nothing in this indemnity shall
be construed as authorizing any award of attorneys' fees in any action on or to enforce
the terms of this Agreement. This indemnity shall apply to all claims and liability
regardless of whether any insurance policies are applicable. The policy limits do not act
as a limitation upon the amount of indemnification to be provided by Consultant.
10. INDEPENDENT CONTRACTOR
10.1 It is understood that City retains Consultant on an independent contractor
basis and Consultant is not an agent or employee of City. The manner and means of
conducting the Work are under the control of Consultant, except to the extent they are
limited by statute, rule or regulation and the expressed terms of this Agreement. No civil
service status or other right of employment shall accrue to Consultant or its employees.
Nothing in this Agreement shall be deemed to constitute approval for Consultant or any
of Consultant's employees or agents, to be the agents or employees of City. Consultant
shall have the responsibility for and control over the means of performing the Work,
provided that Consultant is in compliance with the terms of this Agreement. Anything in
this Agreement that may appear to give City the right to direct Consultant as to the details
of the performance of the Work or to exercise a measure of control over Consultant shall
mean only that Consultant shall follow the desires of City with respect to the results of the
Services.
10.2 Consultant agrees and acknowledges that no individual performing
Services or Work pursuant to this Agreement shall: work full-time for more than six (6)
months; work regular part-time service of at least an average of twenty (20) hours per
week for one year or longer; work nine hundred sixty (960) hours in any fiscal year; or
already be a CalPERS member.
10.3 Consultant must submit to and pass a criminal background investigation by
providing a complete set of fingerprints to City prior to commencing or performing
Services or Work. Consultant is required to submit any fees for the criminal background
investigation according to the City's most current administrative fee schedule or
successor document. Fingerprints may be required to be updated every five (5) years.
11. COOPERATION
Consultant agrees to work closely and cooperate fully with City's designated
Project Administrator and any other agencies that may have jurisdiction or interest in the
Work to be performed. City agrees to cooperate with the Consultant on the Project.
Interwest Consulting Group, Inc. Page 5
12. CITY POLICY
Consultant shall discuss and review all matters relating to policy and Project
direction with City's Project Administrator in advance of all critical decision points in order
to ensure the Project proceeds in a manner consistent with City goals and policies.
13. PROGRESS
Consultant is responsible for keeping the Project Administrator informed on a
regular basis regarding the status and progress of the Project, activities performed and
planned, and any meetings that have been scheduled or are desired.
14. INSURANCE
Without limiting Consultant's indemnification of City, and prior to commencement
of Work, Consultant shall obtain, provide and maintain at its own expense during the term
of this Agreement or for other periods as specified in this Agreement, policies of insurance
of the type, amounts, terms and conditions described in the Insurance Requirements
attached hereto as Exhibit C, and incorporated herein by reference.
15. PROHIBITION AGAINST ASSIGNMENTS AND TRANSFERS
Except as specifically authorized under this Agreement, the Services to be
provided under this Agreement shall not be assigned, transferred contracted or
subcontracted out without the prior written approval of City. Any of the following shall be
construed as an assignment: The sale, assignment, transfer or other disposition of any
of the issued and outstanding capital stock of Consultant, or of the interest of any general
partner or joint venturer or syndicate member or cotenant if Consultant is a partnership or
joint -venture or syndicate or co -tenancy, which shall result in changing the control of
Consultant. Control means fifty percent (50%) or more of the voting power or twenty-five
percent (25%) or more of the assets of the corporation, partnership or joint -venture.
16. SUBCONTRACTING
The subcontractors authorized by City, if any, to perform Work on this Project are
identified in Exhibit A and the Letter Proposal. Consultant shall be fully responsible to
City for all acts and omissions of any subcontractor. Nothing in this Agreement shall
create any contractual relationship between City and any subcontractor nor shall it create
any obligation on the part of City to pay or to see to the payment of any monies due to
any such subcontractor other than as otherwise required by law. City is an intended
beneficiary of any Work performed by the subcontractor for purposes of establishing a
duty of care between the subcontractor and City. Except as specifically authorized herein,
the Services to be provided under this Agreement shall not be otherwise assigned,
transferred, contracted or subcontracted out without the prior written approval of City.
Interwest Consulting Group, Inc. Page 6
17. OWNERSHIP OF DOCUMENTS
17.1 Each and every report, draft, map, record, plan, document and other writing
produced, including but not limited to, websites, blogs, social media accounts and
applications (hereinafter "Documents"), prepared or caused to be prepared by Consultant,
its officers, employees, agents and subcontractors, in the course of implementing this
Agreement, shall become the exclusive property of City, and City shall have the sole right
to use such materials in its discretion without further compensation to Consultant or any
other party. Additionally, all material posted in cyberspace by Consultant, its officers,
employees, agents and subcontractors, in the course of implementing this Agreement,
shall become the exclusive property of City, and City shall have the sole right to use such
materials in its discretion without further compensation to Consultant or any other party.
Consultant shall, at Consultant's expense, provide such Documents, including all logins
and password information to City upon prior written request.
17.2 Documents, including drawings and specifications, prepared by Consultant
pursuant to this Agreement are not intended or represented to be suitable for reuse by
City or others on any other project. Any use of completed Documents for other projects
and any use of incomplete Documents without specific written authorization from
Consultant will be at City's sole risk and without liability to Consultant. Further, any and
all liability arising out of changes made to Consultant's deliverables under this Agreement
by City or persons other than Consultant is waived against Consultant, and City assumes
full responsibility for such changes unless City has given Consultant prior notice and has
received from Consultant written consent for such changes.
17.3 All written documents shall be transmitted to City in formats compatible with
Microsoft Office and/or viewable with Adobe Acrobat.
18. CONFIDENTIALITY
All Documents, including drafts, preliminary drawings or plans, notes and
communications that result from the Services in this Agreement, shall be kept confidential
unless City expressly authorizes in writing the release of information.
19. INTELLECTUAL PROPERTY INDEMNITY
Consultant shall defend and indemnify City, its agents, officers, representatives
and employees against any and all liability, including costs, for infringement or alleged
infringement of any United States' letters patent, trademark, or copyright, including costs,
contained in Consultant's Documents provided under this Agreement.
20. RECORDS
Consultant shall keep records and invoices in connection with the Services to be
performed under this Agreement. Consultant shall maintain complete and accurate
records with respect to the costs incurred under this Agreement and any Services,
expenditures and disbursements charged to City, for a minimum period of three (3) years,
or for any longer period required by law, from the date of final payment to Consultant
Interwest Consulting Group, Inc. Page 7
9-10
under this Agreement. All such records and invoices shall be clearly identifiable.
Consultant shall allow a representative of City to examine, audit and make transcripts or
copies of such records and invoices during regular business hours. Consultant shall allow
inspection of all Work, data, Documents, proceedings and activities related to the
Agreement for a period of three (3) years from the date of final payment to Consultant
under this Agreement.
21. WITHHOLDINGS
City may withhold payment to Consultant of any disputed sums until satisfaction of
the dispute with respect to such payment. Such withholding shall not be deemed to
constitute a failure to pay according to the terms of this Agreement. Consultant shall not
discontinue Work as a result of such withholding. Consultant shall have an immediate
right to appeal to the City Manager or designee with respect to such disputed sums.
Consultant shall be entitled to receive interest on any withheld sums at the rate of return
that City earned on its investments during the time period, from the date of withholding of
any amounts found to have been improperly withheld.
22. ERRORS AND OMISSIONS
In the event of errors or omissions that are due to the negligence or professional
inexperience of Consultant which result in expense to City greater than what would have
resulted if there were not errors or omissions in the Work accomplished by Consultant,
the additional design, construction and/or restoration expense shall be borne by
Consultant. Nothing in this Section is intended to limit City's rights under the law or any
other sections of this Agreement.
23. CITY'S RIGHT TO EMPLOY OTHER CONSULTANTS
City reserves the right to employ other Consultants in connection with the Project.
24. CONFLICTS OF INTEREST
24.1 Consultant or its employees may be subject to the provisions of the
California Political Reform Act of 1974 (the "Act") and/or Government Code §§ 1090 et
seg., which (1) require such persons to disclose any financial interest that may
foreseeably be materially affected by the Work performed under this Agreement, and (2)
prohibit such persons from making, or participating in making, decisions that will
foreseeably financially affect such interest.
24.2 If subject to the Act and/or Government Code §§ 1090 et seg., Consultant
shall conform to all requirements therein. Failure to do so constitutes a material breach
and is grounds for immediate termination of this Agreement by City. Consultant shall
indemnify and hold harmless City for any and all claims for damages resulting from
Consultant's violation of this Section.
Interwest Consulting Group, Inc. Page 8
9-11
25. NOTICES
25.1 All notices, demands, requests or approvals, including any change in
mailing address, to be given under the terms of this Agreement shall be given in writing,
and conclusively shall be deemed served when delivered personally, or on the third
business day after the deposit thereof in the United States mail, postage prepaid, first-
class mail, addressed as hereinafter provided.
25.2 All notices, demands, requests or approvals from Consultant to City shall
be addressed to City at:
Attn: Public Works Director
Public Works Department
City of Newport Beach
100 Civic Center Drive
PO Box 1768
Newport Beach, CA 92658
25.3 All notices, demands, requests or approvals from City to Consultant shall
be addressed to Consultant at:
Attn: James G. Ross
Interwest Consulting Group, Inc.
15140 Transistor Lane
Huntington Beach, CA 92649
26. CLAIMS
26.1 Unless a shorter time is specified elsewhere in this Agreement, before
making its final request for payment under this Agreement, Consultant shall submit to
City, in writing, all claims for compensation under or arising out of this Agreement.
Consultant's acceptance of the final payment shall constitute a waiver of all claims for
compensation under or arising out of this Agreement except those previously made in
writing and identified by Consultant in writing as unsettled at the time of its final request
for payment. Consultant and City expressly agree that in addition to any claims filing
requirements set forth in the Agreement, Consultant shall be required to file any claim
Consultant may have against City in strict conformance with the Government Claims Act
(Government Code sections 900 et seq.).
26.2 To the extent that Consultant's claim is a "Claim" as defined in Public
Contract Code section 9204 or any successor statute thereto, the Parties agree to follow
the dispute resolution process set forth therein. Any part of such "Claim" remaining in
dispute after completion of the dispute resolution process provided for in Public Contract
Code section 9204 or any successor statute thereto shall be subject to the Government
Claims Act requirements requiring Consultant to file a claim in strict conformance with the
Government Claims Act. To the extent that Contractor/Consultant's claim is not a "Claim"
as defined in Public Contract Code section 9204 or any successor statute thereto,
Interwest Consulting Group, Inc. Page 9
9-12
Consultant shall be required to file such claim with the City in strict conformance with the
Government Claims Act (Government Code sections 900 et seq.).
27. TERMINATION
27.1 In the event that either party fails or refuses to perform any of the provisions
of this Agreement at the time and in the manner required, that party shall be deemed in
default in the performance of this Agreement. If such default is not cured within a period
of two (2) calendar days, or if more than two (2) calendar days are reasonably required
to cure the default and the defaulting party fails to give adequate assurance of due
performance within two (2) calendar days after receipt of written notice of default,
specifying the nature of such default and the steps necessary to cure such default, and
thereafter diligently take steps to cure the default, the non -defaulting party may terminate
the Agreement forthwith by giving to the defaulting party written notice thereof.
27.2 Notwithstanding the above provisions, City shall have the right, at its sole
and absolute discretion and without cause, of terminating this Agreement at any time by
giving no less than seven (7) calendar days' prior written notice to Consultant. In the
event of termination under this Section, City shall pay Consultant for Services
satisfactorily performed and costs incurred up to the effective date of termination for which
Consultant has not been previously paid. On the effective date of termination, Consultant
shall deliver to City all reports, Documents and other information developed or
accumulated in the performance of this Agreement, whether in draft or final form.
28. PREVAILING WAGES
28.1 Pursuant to the applicable provisions of the Labor Code of the State of
California, not less than the general prevailing rate of per diem wages including legal
holidays and overtime Work for each craft or type of workman needed to execute the
Work contemplated under the Agreement shall be paid to all workmen employed on the
Work to be done according to the Agreement by the Consultant and any subcontractor.
In accordance with the California Labor Code (Sections 1770 et seq.), the Director of
Industrial Relations has ascertained the general prevailing rate of per diem wages in the
locality in which the Work is to be performed for each craft, classification, or type of
workman or mechanic needed to execute the Agreement. A copy of said determination
is available by calling the prevailing wage hotline number (415) 703-4774, and requesting
one from the Department of Industrial Relations. The Consultant is required to obtain the
wage determinations from the Department of Industrial Relations and post at the job site
the prevailing rate or per diem wages. It shall be the obligation of the Consultant or any
subcontractor under him/her to comply with all State of California labor laws, rules and
regulations and the parties agree that the City shall not be liable for any violation thereof.
28.2 Unless otherwise exempt by law, Consultant warrants that no contractor or
subcontractor was listed on the bid proposal for the Services that it is not currently
registered and qualified to perform public work. Consultant further warrants that it is
currently registered and qualified to perform "public work" pursuant to California Labor
Code section 1725.5 or any successor statute thereto and that no contractor or
Interwest Consulting Group, Inc. Page 10
9-13
subcontractor will engage in the performance of the Services unless currently registered
and qualified to perform public work.
29. STANDARD PROVISIONS
29.1 Recitals. City and Consultant acknowledge that the above Recitals are true
and correct and are hereby incorporated by reference into this Agreement.
29.2 Compliance with all Laws. Consultant shall, at its own cost and expense,
comply with all statutes, ordinances, regulations and requirements of all governmental
entities, including federal, state, county or municipal, whether now in force or hereinafter
enacted. In addition, all Work prepared by Consultant shall conform to applicable City,
county, state and federal laws, rules, regulations and permit requirements and be subject
to approval of the Project Administrator and City.
29.3 Waiver. A waiver by either party of any breach, of any term, covenant or
condition contained herein shall not be deemed to be a waiver of any subsequent breach
of the same or any other term, covenant or condition contained herein, whether of the
same or a different character.
29.4 Integrated Contract. This Agreement represents the full and complete
understanding of every kind or nature whatsoever between the parties hereto, and all
preliminary negotiations and agreements of whatsoever kind or nature are merged herein.
No verbal agreement or implied covenant shall be held to vary the provisions herein.
29.5 Conflicts or Inconsistencies. In the event there are any conflicts or
inconsistencies between this Agreement and the Scope of Services or any other
attachments attached hereto, the terms of this Agreement shall govern.
29.6 Interpretation. The terms of this Agreement shall be construed in
accordance with the meaning of the language used and shall not be construed for or
against either party by reason of the authorship of the Agreement or any other rule of
construction which might otherwise apply.
29.7 Amendments. This Agreement may be modified or amended only by a
written document executed by both Consultant and City and approved as to form by the
City Attorney.
29.8 Severability. If any term or portion of this Agreement is held to be invalid,
illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining
provisions of this Agreement shall continue in full force and effect.
29.9 Controlling Law and Venue. The laws of the State of California shall govern
this Agreement and all matters relating to it and any action brought relating to this
Agreement shall be adjudicated in a court of competent jurisdiction in the County of
Orange, State of California.
Interwest Consulting Group, Inc. Page 11
9-14
29.10 Equal Opportunity Employment. Consultant represents that it is an equal
opportunity employer and it shall not discriminate against any subcontractor, employee
or applicant for employment because race, religious creed, color, national origin,
ancestry, physical handicap, medical condition, marital status, sex, sexual orientation,
age or any other impermissible basis under law.
29.11 No Attorneys' Fees. In the event of any dispute or legal action arising under
this Agreement, the prevailing party shall not be entitled to attorneys' fees.
29.12 Counterparts. This Agreement may be executed in two (2) or more
counterparts, each of which shall be deemed an original and all of which together shall
constitute one (1) and the same instrument.
[SIGNATURES ON NEXT PAGE]
Interwest Consulting Group, Inc. Page 12
9-15
IN WITNESS WHEREOF, the parties have caused this Agreement to be executed
on the dates written below.
APPROVED AS TO FORM:
CITY ATT EY'S OFFICE
Date: 3,20
By:
Out, -
W'. Aaron C. Harp Us3•IL-1l
City Attorney
ATTEST:
Date:
go
CITY OF NEWPORT BEACH,
a California municipal corporation
Date:
By:
Diane B
Mayor
Dixon
CONSULTANT: Interwest Consulting
Group, Inc., a Colorado Corporation
Date:
By:
Leilani I. Brown Terry J. Rodrigue
City Clerk Chief Executive Officer
Date:
By:
Debbie Thorson
Chief Financial Officer
[END OF SIGNATURES]
Attachments: Exhibit A — Scope of Services
Exhibit B — Schedule of Billing Rates
Exhibit C — Insurance Requirements
Interwest Consulting Group, Inc. Page 13
9-16
EXHIBIT A
SCOPE OF SERVICES
On -Call Services for Public Works: Development and Utility Permit Inspection
Services and Construction Administration
Consultant shall provide public works inspection and construction administration on-call
services as determined by Public Works Department.
• Depending on the project or inspection activity, services would be agreed to
depending on the need for inspection and construction administration services.
• Consultant will be assigned to specific projects/permits and work with City staff
on administration and inspection of City projects and private
improvements/encroachments within public right-of-way in the following areas as
necessary:
o construction observation;
o public contract administration;
o attend project meetings;
o utility coordination;
o traffic control;
o construction staking and surveying;
o material testing;
o project documentation;
o record drawings;
o permit system record keeping; and
o liaison with Staff.
Interwest Consulting Group, Inc. Page A-1 9-17
EXHIBIT B
SCHEDULE OF BILLING RATES
The rates displayed in the fee schedule below reflect Interwest's current hourly rates. Hourly rates are
typically reviewed yearly on July 1 and may be subject to revision unless under specific contract
obligations. These rates are inclusive of shipping, supply, or material costs.
CLASSIFICATION
Principal in Charge.....................................................................
HOURLY BILLING RATE
................................................ $175
ProjectManager.......................................................................................................................................160
SeniorEngineer........................................................................................................................................140
ConstructionManager.............................................................................................................................
145
Assistant Construction Manager.............................................................................................................
130
Supervising Public Works Observer.........................................................................................................
135
Senior Public Works Observer.................................................................................................................
130
PublicWorks Observer III.........................................................................................................................
125
PublicWorks Observer II..........................................................................................................................
115
PublicWorks Observer I...........................................................................................................................105
Overtime, Night and Holiday Work....................................................................140% of the rates listed above
Mileage............................................................................................................... Reimbursed at current IRS
rate
Interwest Consulting Group, Inc. Page B-1 9.18
EXHIBIT C
INSURANCE REQUIREMENTS — PROFESSIONAL SERVICES
1. Provision of Insurance. Without limiting Consultant's indemnification of City, and
prior to commencement of Work, Consultant shall obtain, provide and maintain at
its own expense during the term of this Agreement, policies of insurance of the
type and amounts described below and in a form satisfactory to City. Consultant
agrees to provide insurance in accordance with requirements set forth here. If
Consultant uses existing coverage to comply and that coverage does not meet
these requirements, Consultant agrees to amend, supplement or endorse the
existing coverage.
2. Acceptable Insurers. All insurance policies shall be issued by an insurance
company currently authorized by the Insurance Commissioner to transact
business of insurance in the State of California, with an assigned policyholders'
Rating of A- (or higher) and Financial Size Category Class VII (or larger) in
accordance with the latest edition of Best's Key Rating Guide, unless otherwise
approved by the City's Risk Manager.
3. Coverage Requirements.
A. Workers' Compensation Insurance. Consultant shall maintain Workers'
Compensation Insurance, statutory limits, and Employer's Liability
Insurance with limits of at least one million dollars ($1,000,000) each
accident for bodily injury by accident and each employee for bodily injury by
disease in accordance with the laws of the State of California, Section 3700
of the Labor Code.
Consultant shall submit to City, along with the certificate of insurance, a
Waiver of Subrogation endorsement in favor of City, its City Council, boards
and commissions, officers, agents, volunteers, employees and any person
or entity owning or otherwise in legal control of the property upon which
Consultant performs the Project and/or Services contemplated by this
Agreement.
B. General Liability Insurance. Consultant shall maintain commercial general
liability insurance, and if necessary umbrella liability insurance, with
coverage at least as broad as provided by Insurance Services Office form
CG 00 01, in an amount not less than one million dollars ($1,000,000) per
occurrence, two million dollars ($2,000,000) general aggregate. The policy
shall cover liability arising from premises, operations, personal and
advertising injury, and liability assumed under an insured contract (including
the tort liability of another assumed in a business contract).
C. Automobile Liability Insurance. Consultant shall maintain automobile
insurance at least as broad as Insurance Services Office form CA 00 01
covering bodily injury and property damage for all activities of Consultant
arising out of or in connection with Work to be performed under this
Interwest Consulting Group, Inc. Page C-1 9-19
Agreement, including coverage for any owned, hired, non -owned or rented
vehicles, in an amount not less than one million dollars ($1,000,000)
combined single limit each accident.
D. Professional Liability (Errors & Omissions) Insurance. Consultant shall
maintain professional liability insurance that covers the Services to be
performed in connection with this Agreement, in the minimum amount of
one million dollars ($1,000,000) per claim and two million dollars
($2,000,000) in the aggregate. Any policy inception date, continuity date,
or retroactive date must be before the Effective Date of this Agreement and
Consultant agrees to maintain continuous coverage through a period no
less than three years after completion of the Services required by this
Agreement.
4. Other Insurance Requirements. The policies are to contain, or be endorsed to
contain, the following provisions:
A. Waiver of Subrogation. All insurance coverage maintained or procured
pursuant to this Agreement shall be endorsed to waive subrogation against
City, its City Council, boards and commissions, officers, agents, volunteers,
employees and any person or entity owning or otherwise in legal control of
the property upon which Consultant performs the Project and/or Services
contemplated by this Agreement or shall specifically allow Consultant or
others providing insurance evidence in compliance with these requirements
to waive their right of recovery prior to a loss. Consultant hereby waives its
own right of recovery against City, and shall require similar written express
waivers from each of its subconsultants.
B. Additional Insured Status. All liability policies including general liability,
excess liability, pollution liability, and automobile liability, if required, but not
including professional liability, shall provide or be endorsed to provide that
City, its City Council, boards and commissions, officers, agents, volunteers,
employees and any person or entity owning or otherwise in legal control of
the property upon which Consultant performs the Project and/or Services
contemplated by this Agreement shall be included as insureds under such
policies.
C. Primary and Non Contributory. All liability coverage shall apply on a primary
basis and shall not require contribution from any insurance or self-insurance
maintained by City.
D. Notice of Cancellation. All policies shall provide City with thirty (30)
calendar days' notice of cancellation (except for nonpayment for which ten
(10) calendar days' notice is required) or nonrenewal of coverage for each
required coverage.
5. Additional Agreements Between the Parties. The parties hereby agree to the
following:
Interwest Consulting Group, Inc. Page C-2 9-20
A. Evidence of Insurance. Consultant shall provide certificates of insurance to
City as evidence of the insurance coverage required herein, along with a
waiver of subrogation endorsement for workers' compensation and other
endorsements as specified herein for each coverage. Insurance certificates
and endorsement must be approved by City's Risk Manager prior to
commencement of performance. Current certification of insurance shall be
kept on file with City at all times during the term of this Agreement. City
reserves the right to require complete, certified copies of all required
insurance policies, at any time.
B. City's Right to Revise Requirements. City reserves the right at any time
during the term of the Agreement to change the amounts and types of
insurance required by giving Consultant sixty (60) calendar days' advance
written notice of such change. If such change results in substantial
additional cost to Consultant, City and Consultant may renegotiate
Consultant's compensation.
C. Enforcement of Agreement Provisions. Consultant acknowledges and
agrees that any actual or alleged failure on the part of City to inform
Consultant of non-compliance with any requirement imposes no additional
obligations on City nor does it waive any rights hereunder.
D. Requirements not Limiting. Requirements of specific coverage features or
limits contained in this Section are not intended as a limitation on coverage,
limits or other requirements, or a waiver of any coverage normally provided
by any insurance. Specific reference to a given coverage feature is for
purposes of clarification only as it pertains to a given issue and is not
intended by any party or insured to be all inclusive, or to the exclusion of
other coverage, or a waiver of any type. If the Consultant maintains higher
limits than the minimums shown above, the City requires and shall be
entitled to coverage for higher limits maintained by the Consultant. Any
available insurance proceeds in excess of the specified minimum limits of
insurance and coverage shall be available to the City.
E. Self-insured Retentions. Any self-insured retentions must be declared to
and approved by City. City reserves the right to require that self-insured
retentions be eliminated, lowered, or replaced by a deductible. Self-
insurance will not be considered to comply with these requirements unless
approved by City.
F. City Remedies for Non -Compliance. If Consultant or any subconsultant fails
to provide and maintain insurance as required herein, then City shall have
the right but not the obligation, to purchase such insurance, to terminate this
Agreement, or to suspend Consultant's right to proceed until proper
evidence of insurance is provided. Any amounts paid by City shall, at City's
sole option, be deducted from amounts payable to Consultant or reimbursed
by Consultant upon demand.
Interwest Consulting Group, Inc. Page C-3 9-21
G. Timely Notice of Claims. Consultant shall give City prompt and timely notice
of claims made or suits instituted that arise out of or result from Consultant's
performance under this Agreement, and that involve or may involve
coverage under any of the required liability policies. City assumes no
obligation or liability by such notice, but has the right (but not the duty) to
monitor the handling of any such claim or claims if they are likely to involve
City.
H. Consultant's Insurance. Consultant shall also procure and maintain, at its
own cost and expense, any additional kinds of insurance, which in its own
judgment may be necessary for its proper protection and prosecution of the
Work.
Interwest Consulting Group, Inc. Page C-4 9.22
FIN ar_Ta:ILTA 141!1i 1
ON-CALL PROFESSIONAL SERVICES AGREEMENT
WITH PROJECT PARTNERS INC. FOR
DEVELOPMENT AND UTILITY PERMIT INSPECTION SERVICES AND
CONSTRUCTION ADMINISTRATION
THIS ON-CALL PROFESSIONAL SERVICES AGREEMENT ("Agreement") is
made and entered into as of this 9th day of April, 2019 ("Effective Date"), by and between
the CITY OF NEWPORT BEACH, a California municipal corporation and charter city
("City"), and PROJECT PARTNERS, INC., a California corporation ("Consultant"), whose
address is 23195 La Cadena Drive, Suite 101, Laguna Hills, California 92653, and is
made with reference to the following:
RECITALS
A. City is a municipal corporation duly organized and validly existing under the laws
of the State of California with the power to carry on its business as it is now being
conducted under the statutes of the State of California and the Charter of City.
B. City desires to engage Consultant to provide comprehensive construction
inspection and administration services on an on-call or as -needed basis.
("Project').
C. Consultant possesses the skill, experience, ability, background, certification and
knowledge to provide the professional services described in this Agreement.
D. City has solicited and received a proposal from Consultant, has reviewed the
previous experience and evaluated the expertise of Consultant, and desires to
retain Consultant to render professional services under the terms and conditions
set forth in this Agreement.
NOW, THEREFORE, it is mutually agreed by and between the undersigned parties
as follows:
1. TERM
The term of this Agreement shall commence on the Effective Date, and shall
terminate on March 24, 2024, unless terminated earlier as set forth herein.
2. SERVICES TO BE PERFORMED
2.1 Consultant shall perform the on-call services described in the Scope of
Services attached hereto as Exhibit A and incorporated herein by reference ("Services"
or "Work"). Upon written request from the Project Administrator as defined herein,
Consultant shall provide a letter proposal for Services requested by the City (hereinafter
referred to as the "Letter Proposal"). The Letter Proposal shall include the following:
2.1.1 A detailed description of the Services to be provided;
9-23
2.1.2 The position of each person to be assigned to perform the Services,
and the name of the individuals to be assigned, if available;
and
2.1.3 The estimated number of hours and cost to complete the Services;
2.1.4 The time needed to finish the specific project.
2.2 No Services shall be provided until the Project Administrator has provided
written acceptance of the Letter Proposal. Once authorized to proceed, Consultant shall
diligently perform the duties in the approved Letter Proposal.
3. TIME OF PERFORMANCE
3.1 Time is of the essence in the performance of Services under this Agreement
and Consultant shall perform the Services in accordance with the schedule included in
Exhibit A and the Letter Proposal. In the absence of a specific schedule, the Services
shall be performed to completion in a diligent and timely manner. The failure by
Consultant to strictly adhere to the schedule set forth in Exhibit A and the Letter Proposal,
if any, or perform the Services in a diligent and timely manner may result in termination
of this Agreement by City.
3.2 Notwithstanding the foregoing, Consultant shall not be responsible for
delays due to causes beyond Consultant's reasonable control. However, in the case of
any such delay in the Services to be provided for the Project, each party hereby agrees
to provide notice within two (2) calendar days of the occurrence causing the delay to the
other party so that all delays can be addressed.
3.3 Consultant shall submit all requests for extensions of time for performance
in writing to the Project Administrator as defined herein not later than ten (10) calendar
days after the start of the condition that purportedly causes a delay. The Project
Administrator shall review all such requests and may grant reasonable time extensions
for unforeseeable delays that are beyond Consultant's control.
3.4 For all time periods not specifically set forth herein, Consultant shall
respond in the most expedient and appropriate manner under the circumstances, by
hand -delivery or mail.
4. COMPENSATION TO CONSULTANT
4.1 City shall pay Consultant for the Services on a time and expense not -to -
exceed basis in accordance with the provisions of this Section and the Letter Proposal
and the Schedule of Billing Rates attached hereto as Exhibit B and incorporated herein
by reference. Consultant's compensation for all Work performed in accordance with this
Agreement, including all reimbursable items and subconsultant fees, shall not exceed
Three Hundred Thousand Dollars and 001100 ($300,000.00), without prior written
authorization from City. No billing rate changes shall be made during the term of this
Agreement without the prior written approval of City.
Project Partners Inc. Page 2
9-24
4.2 Consultant shall submit monthly invoices to City describing the Work
performed the preceding month. Consultant's bills shall include the name of the person
who performed the Work, a brief description of the Services performed and/or the specific
task in the Scope of Services to which it relates, the date the Services were performed,
the number of hours spent on all Work billed on an hourly basis, and a description of any
reimbursable expenditures. City shall pay Consultant no later than thirty (30) calendar
days after approval of the monthly invoice by City staff.
4.3 City shall reimburse Consultant only for those costs or expenses specifically
identified in Exhibit B to this Agreement and the Letter Proposal or specifically approved
in writing in advance by City.
4.4 Consultant shall not receive any compensation for Extra Work performed
without the prior written authorization of City. As used herein, "Extra Work" means any
Work that is determined by City to be necessary for the proper completion of the Project,
but which is not included within the Scope of Services and which the parties did not
reasonably anticipate would be necessary at the execution of this Agreement.
Compensation for any authorized Extra Work shall be paid in accordance with the
Schedule of Billing Rates as set forth in Exhibit B and the Letter Proposal.
5. PROJECT MANAGER
5.1 Consultant shall designate a Project Manager, who shall coordinate all
phases of the Project. This Project Manager shall be available to City at all reasonable
times during the Agreement term. Consultant has designated Kimo Look, P.E. to be its
Project Manager. Consultant shall not remove or reassign the Project Manager or any
personnel listed in Exhibit A or assign any new or replacement personnel to the Project
without the prior written consent of City. City's approval shall not be unreasonably
withheld with respect to the removal or assignment of non -key personnel.
5.2 Consultant, at the sole discretion of City, shall remove from the Project any
of its personnel assigned to the performance of Services upon written request of City.
Consultant warrants that it will continuously furnish the necessary personnel to complete
the Project on a timely basis as contemplated by this Agreement.
5.3 If Consultant is performing inspection services for City, the Project Manager
and any other assigned staff shall be equipped with a cellular phone to communicate with
City staff. The Project Manager's cellular phone number shall be provided to City.
6. ADMINISTRATION
This Agreement will be administered by the Public Works Department. City's
Public Works Director or designee shall be the Project Administrator and shall have the
authority to act for City under this Agreement. The Project Administrator shall represent
City in all matters pertaining to the Services to be rendered pursuant to this Agreement.
Project Partners Inc. Page 3
9-25
7. CITY'S RESPONSIBILITIES
To assist Consultant in the execution of its responsibilities under this Agreement,
City agrees to provide access to and upon request of Consultant, one copy of all existing
relevant information on file at City. City will provide all such materials in a timely manner
so as not to cause delays in Consultant's Work schedule.
8. STANDARD OF CARE
8.1 All of the Services shall be performed by Consultant or under Consultant's
supervision. Consultant represents that it possesses the professional and technical
personnel required to perform the Services required by this Agreement, and that it will
perform all Services in a manner commensurate with community professional standards
and with the ordinary degree of skill and care that would be used by other reasonably
competent practitioners of the same discipline under similar circumstances. All Services
shall be performed by qualified and experienced personnel who are not employed by City.
By delivery of completed Work, Consultant certifies that the Work conforms to the
requirements of this Agreement, all applicable federal, state and local laws, and legally
recognized professional standards.
8.2 Consultant represents and warrants to City that it has, shall obtain, and shall
keep in full force and effect during the term hereof, at its sole cost and expense, all
licenses, permits, qualifications, insurance and approvals of whatsoever nature that is
legally required of Consultant to practice its profession. Consultant shall maintain a City
of Newport Beach business license during the term of this Agreement.
8.3 Consultant shall not be responsible for delay, nor shall Consultant be
responsible for damages or be in default or deemed to be in default by reason of strikes,
lockouts, accidents, acts of God, or the failure of City to furnish timely information or to
approve or disapprove Consultant's Work promptly, or delay or faulty performance by
City, contractors, or governmental agencies.
9. HOLD HARMLESS
9.1 To the fullest extent permitted by law, Consultant shall indemnify, defend
and hold harmless City, its City Council, boards and commissions, officers, agents,
volunteers, employees and any person or entity owning or otherwise in legal control of
the property upon which Consultant performs the Project and/or Services contemplated
by this Agreement (collectively, the "Indemnified Parties") from and against any and all
claims (including, without limitation, claims for bodily injury, death or damage to property),
demands, obligations, damages, actions, causes of action, suits, losses, judgments,
fines, penalties, liabilities, costs and expenses (including, without limitation, attorneys'
fees, disbursements and court costs) of every kind and nature whatsoever (individually,
a Claim; collectively, "Claims"), which may arise from or in any manner relate (directly or
indirectly) to any breach of the terms and conditions of this Agreement, any Work
performed or Services provided under this Agreement including, without limitation,
defects in workmanship or materials or Consultant's presence or activities conducted on
Project Partners Inc. Page 4
9-26
the Project (including the negligent, reckless, and/or willful acts, errors and/or omissions
of Consultant, its principals, officers, agents, employees, vendors, suppliers, consultants,
subcontractors, anyone employed directly or indirectly by any of them or for whose acts
they may be liable, or any or all of them).
9.2 Notwithstanding the foregoing, nothing herein shall be construed to require
Consultant to indemnify the Indemnified Parties from any Claim arising from the sole
negligence or willful misconduct of the Indemnified Parties. Nothing in this indemnity shall
be construed as authorizing any award of attorneys' fees in any action on or to enforce
the terms of this Agreement. This indemnity shall apply to all claims and liability
regardless of whether any insurance policies are applicable. The policy limits do not act
as a limitation upon the amount of indemnification to be provided by Consultant.
10. INDEPENDENT CONTRACTOR
10.1 It is understood that City retains Consultant on an independent contractor
basis and Consultant is not an agent or employee of City. The manner and means of
conducting the Work are under the control of Consultant, except to the extent they are
limited by statute, rule or regulation and the expressed terms of this Agreement. No civil
service status or other right of employment shall accrue to Consultant or its employees.
Nothing in this Agreement shall be deemed to constitute approval for Consultant or any
of Consultant's employees or agents, to be the agents or employees of City. Consultant
shall have the responsibility for and control over the means of performing the Work,
provided that Consultant is in compliance with the terms of this Agreement. Anything in
this Agreement that may appear to give City the right to direct Consultant as to the details
of the performance of the Work or to exercise a measure of control over Consultant shall
mean only that Consultant shall follow the desires of City with respect to the results of the
Services.
10.2 Consultant agrees and acknowledges that no individual performing
Services or Work pursuant to this Agreement shall: work full-time for more than six (6)
months; work regular part-time service of at least an average of twenty (20) hours per
week for one year or longer; work nine hundred sixty (960) hours in any fiscal year; or
already be a CalPERS member.
10.3 Consultant must submit to and pass a criminal background investigation by
providing a complete set of fingerprints to City prior to commencing or performing
Services or Work. Consultant is required to submit any fees for the criminal background
investigation according to the City's most current administrative fee schedule or
successor document. Fingerprints may be required to be updated every five (5) years.
11. COOPERATION
Consultant agrees to work closely and cooperate fully with City's designated
Project Administrator and any other agencies that may have jurisdiction or interest in the
Work to be performed. City agrees to cooperate with the Consultant on the Project.
Project Partners Inc. Page 5
9-27
12. CITY POLICY
Consultant shall discuss and review all matters relating to policy and Project
direction with City's Project Administrator in advance of all critical decision points in order
to ensure the Project proceeds in a manner consistent with City goals and policies.
13. PROGRESS
Consultant is responsible for keeping the Project Administrator informed on a
regular basis regarding the status and progress of the Project, activities performed and
planned, and any meetings that have been scheduled or are desired.
14. INSURANCE
Without limiting Consultant's indemnification of City, and prior to commencement
of Work, Consultant shall obtain, provide and maintain at its own expense during the term
of this Agreement or for other periods as specified in this Agreement, policies of insurance
of the type, amounts, terms and conditions described in the Insurance Requirements
attached hereto as Exhibit C, and incorporated herein by reference.
15. PROHIBITION AGAINST ASSIGNMENTS AND TRANSFERS
Except as specifically authorized under this Agreement, the Services to be
provided under this Agreement shall not be assigned, transferred contracted or
subcontracted out without the prior written approval of City. Any of the following shall be
construed as an assignment: The sale, assignment, transfer or other disposition of any
of the issued and outstanding capital stock of Consultant, or of the interest of any general
partner or joint venturer or syndicate member or cotenant if Consultant is a partnership or
joint -venture or syndicate or co -tenancy, which shall result in changing the control of
Consultant. Control means fifty percent (50%) or more of the voting power or twenty-five
percent (25%) or more of the assets of the corporation, partnership or joint -venture.
16. SUBCONTRACTING
The subcontractors authorized by City, if any, to perform Work on this Project are
identified in Exhibit A and the Letter Proposal. Consultant shall be fully responsible to
City for all acts and omissions of any subcontractor. Nothing in this Agreement shall
create any contractual relationship between City and any subcontractor nor shall it create
any obligation on the part of City to pay or to see to the payment of any monies due to
any such subcontractor other than as otherwise required by law. City is an intended
beneficiary of any Work performed by the subcontractor for purposes of establishing a
duty of care between the subcontractor and City. Except as specifically authorized herein,
the Services to be provided under this Agreement shall not be otherwise assigned,
transferred, contracted or subcontracted out without the prior written approval of City.
Project Partners Inc. Page 6
010
17. OWNERSHIP OF DOCUMENTS
17.1 Each and every report, draft, map, record, plan, document and other writing
produced, including but not limited to, websites, blogs, social media accounts and
applications (hereinafter "Documents"), prepared or caused to be prepared by Consultant,
its officers, employees, agents and subcontractors, in the course of implementing this
Agreement, shall become the exclusive property of City, and City shall have the sole right
to use such materials in its discretion without further compensation to Consultant or any
other party. Additionally, all material posted in cyberspace by Consultant, its officers,
employees, agents and subcontractors, in the course of implementing this Agreement,
shall become the exclusive property of City, and City shall have the sole right to use such
materials in its discretion without further compensation to Consultant or any other party.
Consultant shall, at Consultant's expense, provide such Documents, including all logins
and password information to City upon prior written request.
17.2 Documents, including drawings and specifications, prepared by Consultant
pursuant to this Agreement are not intended or represented to be suitable for reuse by
City or others on any other project. Any use of completed Documents for other projects
and any use of incomplete Documents without specific written authorization from
Consultant will be at City's sole risk and without liability to Consultant. Further, any and
all liability arising out of changes made to Consultant's deliverables under this Agreement
by City or persons other than Consultant is waived against Consultant, and City assumes
full responsibility for such changes unless City has given Consultant prior notice and has
received from Consultant written consent for such changes.
17.3 All written documents shall be transmitted to City in formats compatible with
Microsoft Office and/or viewable with Adobe Acrobat.
18. CONFIDENTIALITY
All Documents, including drafts, preliminary drawings or plans, notes and
communications that result from the Services in this Agreement, shall be kept confidential
unless City expressly authorizes in writing the release of information.
19. INTELLECTUAL PROPERTY INDEMNITY
Consultant shall defend and indemnify City, its agents, officers, representatives
and employees against any and all liability, including costs, for infringement or alleged
infringement of any United States' letters patent, trademark, or copyright, including costs,
contained in Consultant's Documents provided under this Agreement.
20. RECORDS
Consultant shall keep records and invoices in connection with the Services to be
performed under this Agreement. Consultant shall maintain complete and accurate
records with respect to the costs incurred under this Agreement and any Services,
expenditures and disbursements charged to City, for a minimum period of three (3) years,
or for any longer period required by law, from the date of final payment to Consultant
Project Partners Inc. Page 7
9-29
under this Agreement. All such records and invoices shall be clearly identifiable.
Consultant shall allow a representative of City to examine, audit and make transcripts or
copies of such records and invoices during regular business hours. Consultant shall allow
inspection of all Work, data, Documents, proceedings and activities related to the
Agreement for a period of three (3) years from the date of final payment to Consultant
under this Agreement.
21. WITHHOLDINGS
City may withhold payment to Consultant of any disputed sums until satisfaction of
the dispute with respect to such payment. Such withholding shall not be deemed to
constitute a failure to pay according to the terms of this Agreement. Consultant shall not
discontinue Work as a result of such withholding. Consultant shall have an immediate
right to appeal to the City Manager or designee with respect to such disputed sums.
Consultant shall be entitled to receive interest on any withheld sums at the rate of return
that City earned on its investments during the time period, from the date of withholding of
any amounts found to have been improperly withheld.
22. ERRORS AND OMISSIONS
In the event of errors or omissions that are due to the negligence or professional
inexperience of Consultant which result in expense to City greater than what would have
resulted if there were not errors or omissions in the Work accomplished by Consultant,
the additional design, construction and/or restoration expense shall be borne by
Consultant. Nothing in this Section is intended to limit City's rights under the law or any
other sections of this Agreement.
23. CITY'S RIGHT TO EMPLOY OTHER CONSULTANTS
City reserves the right to employ other Consultants in connection with the Project.
24. CONFLICTS OF INTEREST
24.1 Consultant or its employees may be subject to the provisions of the
California Political Reform Act of 1974 (the "Act") and/or Government Code §§ 1090 et
seq., which (1) require such persons to disclose any financial interest that may
foreseeably be materially affected by the Work performed under this Agreement, and (2)
prohibit such persons from making, or participating in making, decisions that will
foreseeably financially affect such interest.
24.2 If subject to the Act and/or Government Code §§ 1090 et seq., Consultant
shall conform to all requirements therein. Failure to do so constitutes a material breach
and is grounds for immediate termination of this Agreement by City. Consultant shall
indemnify and hold harmless City for any and all claims for damages resulting from
Consultant's violation of this Section.
Project Partners Inc. Page 8
9-30
25. NOTICES
25.1 All notices, demands, requests or approvals, including any change in
mailing address, to be given under the terms of this Agreement shall be given in writing,
and conclusively shall be deemed served when delivered personally, or on the third
business day after the deposit thereof in the United States mail, postage prepaid, first-
class mail, addressed as hereinafter provided.
25.2 All notices, demands, requests or approvals from Consultant to City shall
be addressed to City at:
Attn: Public Works Director
Public Works Department
City of Newport Beach
100 Civic Center Drive
PO Box 1768
Newport Beach, CA 92658
25.3 All notices, demands, requests or approvals from City to Consultant shall
be addressed to Consultant at:
Attn: Kimo T. Look, P.E.
Project Partners Inc.
23195 La Cadena Drive, Suite 101
Laguna Hills, CA 92653
26. CLAIMS
26.1 Unless a shorter time is specified elsewhere in this Agreement, before
making its final request for payment under this Agreement, Consultant shall submit to
City, in writing, all claims for compensation under or arising out of this Agreement.
Consultant's acceptance of the final payment shall constitute a waiver of all claims for
compensation under or arising out of this Agreement except those previously made in
writing and identified by Consultant in writing as unsettled at the time of its final request
for payment. Consultant and City expressly agree that in addition to any claims filing
requirements set forth in the Agreement, Consultant shall be required to file any claim
Consultant may have against City in strict conformance with the Government Claims Act
(Government Code sections 900 et seq.).
26.2 To the extent that Consultant's claim is a "Claim" as defined in Public
Contract Code section 9204 or any successor statute thereto, the Parties agree to follow
the dispute resolution process set forth therein. Any part of such "Claim" remaining in
dispute after completion of the dispute resolution process provided for in Public Contract
Code section 9204 or any successor statute thereto shall be subject to the Government
Claims Act requirements requiring Consultant to file a claim in strict conformance with the
Government Claims Act. To the extent that Contractor/Consultant's claim is not a "Claim"
as defined in Public Contract Code section 9204 or any successor statute thereto,
Project Partners Inc. Page 9
9-31
Consultant shall be required to file such claim with the City in strict conformance with the
Government Claims Act (Government Code sections 900 et seq.).
27. TERMINATION
27.1 In the event that either party fails or refuses to perform any of the provisions
of this Agreement at the time and in the manner required, that party shall be deemed in
default in the performance of this Agreement. If such default is not cured within a period
of two (2) calendar days, or if more than two (2) calendar days are reasonably required
to cure the default and the defaulting party fails to give adequate assurance of due
performance within two (2) calendar days after receipt of written notice of default,
specifying the nature of such default and the steps necessary to cure such default, and
thereafter diligently take steps to cure the default, the non -defaulting party may terminate
the Agreement forthwith by giving to the defaulting party written notice thereof.
27.2 Notwithstanding the above provisions, City shall have the right, at its sole
and absolute discretion and without cause, of terminating this Agreement at any time by
giving no less than seven (7) calendar days' prior written notice to Consultant. In the
event of termination under this Section, City shall pay Consultant for Services
satisfactorily performed and costs incurred up to the effective date of termination for which
Consultant has not been previously paid. On the effective date of termination, Consultant
shall deliver to City all reports, Documents and other information developed or
accumulated in the performance of this Agreement, whether in draft or final form.
28. PREVAILING WAGES
28.1 Pursuant to the applicable provisions of the Labor Code of the State of
California, not less than the general prevailing rate of per diem wages including legal
holidays and overtime Work for each craft or type of workman needed to execute the
Work contemplated under the Agreement shall be paid to all workmen employed on the
Work to be done according to the Agreement by the Consultant and any subcontractor.
In accordance with the California Labor Code (Sections 1770 et seq.), the Director of
Industrial Relations has ascertained the general prevailing rate of per diem wages in the
locality in which the Work is to be performed for each craft, classification, or type of
workman or mechanic needed to execute the Agreement. A copy of said determination
is available by calling the prevailing wage hotline number (415) 703-4774, and requesting
one from the Department of Industrial Relations. The Consultant is required to obtain the
wage determinations from the Department of Industrial Relations and post at the job site
the prevailing rate or per diem wages. It shall be the obligation of the Consultant or any
subcontractor under him/her to comply with all State of California labor laws, rules and
regulations and the parties agree that the City shall not be liable for any violation thereof.
28.2 Unless otherwise exempt by law, Consultant warrants that no contractor or
subcontractor was listed on the bid proposal for the Services that it is not currently
registered and qualified to perform public work. Consultant further warrants that it is
currently registered and qualified to perform "public work" pursuant to California Labor
Code section 1725.5 or any successor statute thereto and that no contractor or
Project Partners Inc. Page 10
9-32
subcontractor will engage in the performance of the Services unless currently registered
and qualified to perform public work.
29. STANDARD PROVISIONS
29.1 Recitals. City and Consultant acknowledge that the above Recitals are true
and correct and are hereby incorporated by reference into this Agreement.
29.2 Compliance with all Laws. Consultant shall, at its own cost and expense,
comply with all statutes, ordinances, regulations and requirements of all governmental
entities, including federal, state, county or municipal, whether now in force or hereinafter
enacted. In addition, all Work prepared by Consultant shall conform to applicable City,
county, state and federal laws, rules, regulations and permit requirements and be subject
to approval of the Project Administrator and City.
29.3 Waiver. A waiver by either party of any breach, of any term, covenant or
condition contained herein shall not be deemed to be a waiver of any subsequent breach
of the same or any other term, covenant or condition contained herein, whether of the
same or a different character.
29.4 Integrated Contract. This Agreement represents the full and complete
understanding of every kind or nature whatsoever between the parties hereto, and all
preliminary negotiations and agreements of whatsoever kind or nature are merged herein.
No verbal agreement or implied covenant shall be held to vary the provisions herein.
29.5 Conflicts or Inconsistencies. In the event there are any conflicts or
inconsistencies between this Agreement and the Scope of Services or any other
attachments attached hereto, the terms of this Agreement shall govern.
29.6 Interpretation. The terms of this Agreement shall be construed in
accordance with the meaning of the language used and shall not be construed for or
against either party by reason of the authorship of the Agreement or any other rule of
construction which might otherwise apply.
29.7 Amendments. This Agreement may be modified or amended only by a
written document executed by both Consultant and City and approved as to form by the
City Attorney.
29.8 Severability. If any term or portion of this Agreement is held to be invalid,
illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining
provisions of this Agreement shall continue in full force and effect.
29.9 Controlling Law and Venue. The laws of the State of California shall govern
this Agreement and all matters relating to it and any action brought relating to this
Agreement shall be adjudicated in a court of competent jurisdiction in the County of
Orange, State of California.
Project Partners Inc. Page 11
9-33
29.10 Equal Opportunity Employment. Consultant represents that it is an equal
opportunity employer and it shall not discriminate against any subcontractor, employee
or applicant for employment because race, religious creed, color, national origin,
ancestry, physical handicap, medical condition, marital status, sex, sexual orientation,
age or any other impermissible basis under law.
29.11 No Attorneys' Fees. In the event of any dispute or legal action arising under
this Agreement, the prevailing party shall not be entitled to attorneys' fees.
29.12 Counterparts. This Agreement may be executed in two (2) or more
counterparts, each of which shall be deemed an original and all of which together shall
constitute one (1) and the same instrument.
[SIGNATURES ON NEXT PAGE]
Project Partners Inc. Page 12
9-34
IN WITNESS WHEREOF, the parties have caused this Agreement to be executed
on the dates written below.
APPROVED AS TO FORM:
CITY ATTORNEYOFFICE
Date: 2 20
By. da'—
F()C
; Aaron C. Harp Guw3•[?'A
City Attorney
CITY OF NEWPORT BEACH,
a California municipal corporation
Date:
By:
Diane B
Mayor
Dixon
ATTEST: CONSULTANT: Project Partners Inc., a
Date: California corporation
Date:
By: By:
Leilani 1. Brown Kimo T. Look
City Cleric Chief Executive Officer and Secretary
[END OF SIGNATURES]
Attachments: Exhibit A — Scope of Services
Exhibit B — Schedule of Billing Rates
Exhibit C — Insurance Requirements
Project Partners Inc. Page 13
9-35
EXHIBIT A
SCOPE OF SERVICES
On -Call Services for Public Works: Development and Utility Permit Inspection
Services and Construction Administration
Consultant shall provide public works inspection and construction administration on-call
services as determined by Public Works Department.
• Depending on the project or inspection activity, services would be agreed to
depending on the need for inspection and construction administration services.
Consultant will be assigned to specific projects/permits and work with City staff
on administration and inspection of City projects and private
improvements/encroachments within public right-of-way in the following areas as
necessary:
o construction observation;
o public contract administration;
o attend project meetings;
o utility coordination;
o traffic control;
o construction staking and surveying;
o material testing;
o project documentation;
o record drawings;
o permit system record keeping; and
o liaison with Staff.
Project Partners, Inc. Page A-1 9-36
EXHIBIT B
SCHEDULE OF BILLING RATES
Project Partners'
Billing
Rate
Title
Engineering
Bill Rates
Entry Level
$
55.00
Assistant
$
60.00
Associate
$
65.00
Staff
$
70.00
Project Engineer
$
75.00
Project Management
Associate Project Manager
$
85.00
Project Manager
$
95.00
Senior Project Manaqer 1
$
100.00
Senior Project Manager II
$ 110.00
Senior Project Manager III
$ 120.00
Specialist
Engineering Specialist I
$
130.00
Enqineering Specialist II
$
140.00
Engineering Specialist III
$
150.00
Inspectors
Inspector Prevailing Wage
$
123.00
Project Coordinators
Project Coordinators 1
$
70.00
Project Coordinators II
$
85.00
Project Coordinators III
$
95.00
Project Partners, Inc. Page B-1 9-37
EXHIBIT C
INSURANCE REQUIREMENTS — PROFESSIONAL SERVICES
1. Provision of Insurance. Without limiting Consultant's indemnification of City, and
prior to commencement of Work, Consultant shall obtain, provide and maintain at
its own expense during the term of this Agreement, policies of insurance of the
type and amounts described below and in a form satisfactory to City. Consultant
agrees to provide insurance in accordance with requirements set forth here. If
Consultant uses existing coverage to comply and that coverage does not meet
these requirements, Consultant agrees to amend, supplement or endorse the
existing coverage.
2. Acceptable Insurers. All insurance policies shall be issued by an insurance
company currently authorized by the Insurance Commissioner to transact
business of insurance in the State of California, with an assigned policyholders'
Rating of A- (or higher) and Financial Size Category Class VII (or larger) in
accordance with the latest edition of Best's Key Rating Guide, unless otherwise
approved by the City's Risk Manager,
3. Coverage Requirements.
A. Workers' Compensation Insurance. Consultant shall maintain Workers'
Compensation Insurance, statutory limits, and Employer's Liability
Insurance with limits of at least one million dollars ($1,000,000) each
accident for bodily injury by accident and each employee for bodily injury by
disease in accordance with the laws of the State of California, Section 3700
of the Labor Code.
Consultant shall submit to City, along with the certificate of insurance, a
Waiver of Subrogation endorsement in favor of City, its City Council, boards
and commissions, officers, agents, volunteers, employees and any person
or entity owning or otherwise in legal control of the property upon which
Consultant performs the Project and/or Services contemplated by this
Agreement.
B. General Liability Insurance. Consultant shall maintain commercial general
liability insurance, and if necessary umbrella liability insurance, with
coverage at least as broad as provided by Insurance Services Office form
CG 00 01, in an amount not less than one million dollars ($1,000,000) per
occurrence, two million dollars ($2,000,000) general aggregate. The policy
shall cover liability arising from premises, operations, personal and
advertising injury, and liability assumed under an insured contract (including
the tort liability of another assumed in a business contract).
C. Automobile Liability Insurance. Consultant shall maintain automobile
insurance at least as broad as Insurance Services Office form CA 00 01
covering bodily injury and property damage for all activities of Consultant
arising out of or in connection with Work to be performed under this
Project Partners, Inc. Page C-1 9.38
Agreement, including coverage for any owned, hired, non -owned or rented
vehicles, in an amount not less than one million dollars ($1,000,000)
combined single limit each accident.
D. Professional Liability (Errors & Omissions) Insurance. Consultant shall
maintain professional liability insurance that covers the Services to be
performed in connection with this Agreement, in the minimum amount of
one million dollars ($1,000,000) per claim and two million dollars
($2,000,000) in the aggregate. Any policy inception date, continuity date,
or retroactive date must be before the Effective Date of this Agreement and
Consultant agrees to maintain continuous coverage through a period no
less than three years after completion of the Services required by this
Agreement.
4. Other Insurance Requirements. The policies are to contain, or be endorsed to
contain, the following provisions:
A. Waiver of Subrogation. All insurance coverage maintained or procured
pursuant to this Agreement shall be endorsed to waive subrogation against
City, its City Council, boards and commissions, officers, agents, volunteers,
employees and any person or entity owning or otherwise in legal control of
the property upon which Consultant performs the Project and/or Services
contemplated by this Agreement or shall specifically allow Consultant or
others providing insurance evidence in compliance with these requirements
to waive their right of recovery prior to a loss. Consultant hereby waives its
own right of recovery against City, and shall require similar written express
waivers from each of its subconsultants.
B. Additional Insured Status. All liability policies including general liability,
excess liability, pollution liability, and automobile liability, if required, but not
including professional liability, shall provide or be endorsed to provide that
City, its City Council, boards and commissions, officers, agents, volunteers,
employees and any person or entity owning or otherwise in legal control of
the property upon which Consultant performs the Project and/or Services
contemplated by this Agreement shall be included as insureds under such
policies.
C. Primary and Non Contributory. All liability coverage shall apply on a primary
basis and shall not require contribution from any insurance or self-insurance
maintained by City.
D. Notice of Cancellation. All policies shall provide City with thirty (30)
calendar days' notice of cancellation (except for nonpayment for which ten
(10) calendar days' notice is required) or nonrenewal of coverage for each
required coverage.
5. Additional Agreements Between the Parties. The parties hereby agree to the
following:
Project Partners, Inc. Page C-2 9.39
A. Evidence of Insurance. Consultant shall provide certificates of insurance to
City as evidence of the insurance coverage required herein, along with a
waiver of subrogation endorsement for workers' compensation and other
endorsements as specified herein for each coverage. Insurance certificates
and endorsement must be approved by City's Risk Manager prior to
commencement of performance. Current certification of insurance shall be
kept on file with City at all times during the term of this Agreement. City
reserves the right to require complete, certified copies of all required
insurance policies, at any time.
B. City's Right to Revise Requirements. City reserves the right at any time
during the term of the Agreement to change the amounts and types of
insurance required by giving Consultant sixty (60) calendar days' advance
written notice of such change. If such change results in substantial
additional cost to Consultant, City and Consultant may renegotiate
Consultant's compensation.
C. Enforcement of Agreement Provisions. Consultant acknowledges and
agrees that any actual or alleged failure on the part of City to inform
Consultant of non-compliance with any requirement imposes no additional
obligations on City nor does it waive any rights hereunder.
D. Requirements not Limiting. Requirements of specific coverage features or
limits contained in this Section are not intended as a limitation on coverage,
limits or other requirements, or a waiver of any coverage normally provided
by any insurance. Specific reference to a given coverage feature is for
purposes of clarification only as it pertains to a given issue and is not
intended by any party or insured to be all inclusive, or to the exclusion of
other coverage, or a waiver of any type. If the Consultant maintains higher
limits than the minimums shown above, the City requires and shall be
entitled to coverage for higher limits maintained by the Consultant. Any
available insurance proceeds in excess of the specified minimum limits of
insurance and coverage shall be available to the City.
E. Self-insured Retentions. Any self-insured retentions must be declared to
and approved by City. City reserves the right to require that self-insured
retentions be eliminated, lowered, or replaced by a deductible. Self-
insurance will not be considered to comply with these requirements unless
approved by City.
F. City Remedies for Non -Compliance. If Consultant or any subconsultant fails
to provide and maintain insurance as required herein, then City shall have
the right but not the obligation, to purchase such insurance, to terminate this
Agreement, or to suspend Consultant's right to proceed until proper
evidence of insurance is provided. Any amounts paid by City shall, at City's
sole option, be deducted from amounts payable to Consultant or reimbursed
by Consultant upon demand.
Project Partners, Inc. Page C-3 9-40
G. Timely Notice of Claims. Consultant shall give City prompt and timely notice
of claims made or suits instituted that arise out of or result from Consultant's
performance under this Agreement, and that involve or may involve
coverage under any of the required liability policies. City assumes no
obligation or liability by such notice, but has the right (but not the duty) to
monitor the handling of any such claim or claims if they are likely to involve
City.
H. Consultant's Insurance. Consultant shall also procure and maintain, at its
own cost and expense, any additional kinds of insurance, which in its own
judgment may be necessary for its proper protection and prosecution of the
Work.
Project Partners, Inc. Page C-4 9-41
ATTACHMENT C
ON-CALL PROFESSIONAL SERVICES AGREEMENT
WITH WILLDAN ENGINEERING FOR
DEVELOPMENT AND UTILITY PERMIT INSPECTION SERVICES AND
CONSTRUCTION ADMINISTRATION
THIS ON-CALL PROFESSIONAL SERVICES AGREEMENT ("Agreement') is
made and entered into as of this 9th day of April, 2019 ("Effective Date"), by and
between the CITY OF NEWPORT BEACH, a California municipal corporation and
charter city ("City"), and WILLDAN ENGINEERING, a California corporation
("Consultant'), whose address is 2401 E. Katella Avenue, Suite 300, Anaheim, California
92806, and is made with reference to the following:
RECITALS
A. City is a municipal corporation duly organized and validly existing under the laws
of the State of California with the power to carry on its business as it is now being
conducted under the statutes of the State of California and the Charter of City.
B. City desires to engage Consultant to provide comprehensive construction
inspection and administration services on an on-call or as -needed basis.
("Project').
C. Consultant possesses the skill, experience, ability, background, certification and
knowledge to provide the professional services described in this Agreement.
D. City has solicited and received a proposal from Consultant, has reviewed the
previous experience and evaluated the expertise of Consultant, and desires to
retain Consultant to render professional services under the terms and conditions
set forth in this Agreement.
NOW, THEREFORE, it is mutually agreed by and between the undersigned parties
as follows:
1. TERM
The term of this Agreement shall commence on the Effective Date, and shall
terminate on March 24, 2024, unless terminated earlier as set forth herein.
2. SERVICES TO BE PERFORMED
2.1 Consultant shall perform the on-call services described in the Scope of
Services attached hereto as Exhibit A and incorporated herein by reference ("Services"
or "Work"). Upon written request from the Project Administrator as defined herein,
Consultant shall provide a letter proposal for Services requested by the City (hereinafter
referred to as the "Letter Proposal"). The Letter Proposal shall include the following:
2.1.1 A detailed description of the Services to be provided;
9-42
2.1.2 The position of each person to be assigned to perform the Services,
and the name of the individuals to be assigned, if available;
and
2.1.3 The estimated number of hours and cost to complete the Services;
2.1.4 The time needed to finish the specific project.
2.2 No Services shall be provided until the Project Administrator has provided
written acceptance of the Letter Proposal. Once authorized to proceed, Consultant shall
diligently perform the duties in the approved Letter Proposal.
3. TIME OF PERFORMANCE
3.1 Time is of the essence in the performance of Services under this Agreement
and Consultant shall perform the Services in accordance with the schedule included in
Exhibit A and the Letter Proposal. In the absence of a specific schedule, the Services
shall be performed to completion in a diligent and timely manner. The failure by
Consultant to strictly adhere to the schedule set forth in Exhibit A and the Letter Proposal,
if any, or perform the Services in a diligent and timely manner may result in termination
of this Agreement by City.
3.2 Notwithstanding the foregoing, Consultant shall not be responsible for
delays due to causes beyond Consultant's reasonable control. However, in the case of
any such delay in the Services to be provided for the Project, each party hereby agrees
to provide notice within two (2) calendar days of the occurrence causing the delay to the
other party so that all delays can be addressed.
3.3 Consultant shall submit all requests for extensions of time for performance
in writing to the Project Administrator as defined herein not later than ten (10) calendar
days after the start of the condition that purportedly causes a delay. The Project
Administrator shall review all such requests and may grant reasonable time extensions
for unforeseeable delays that are beyond Consultant's control.
3.4 For all time periods not specifically set forth herein, Consultant shall
respond in the most expedient and appropriate manner under the circumstances, by
hand -delivery or mail.
4. COMPENSATION TO CONSULTANT
4.1 City shall pay Consultant for the Services on a time and expense not -to -
exceed basis in accordance with the provisions of this Section and the Letter Proposal
and the Schedule of Billing Rates attached hereto as Exhibit B and incorporated herein
by reference. Consultant's compensation for all Work performed in accordance with this
Agreement, including all reimbursable items and subconsultant fees, shall not exceed
Three Hundred Thousand Dollars and 001100 ($300,000.00), without prior written
authorization from City. No billing rate changes shall be made during the term of this
Agreement without the prior written approval of City.
Willdan Engineering Page 2
9-43
4.2 Consultant shall submit monthly invoices to City describing the Work
performed the preceding month. Consultant's bills shall include the name of the person
who performed the Work, a brief description of the Services performed and/or the specific
task in the Scope of Services to which it relates, the date the Services were performed,
the number of hours spent on all Work billed on an hourly basis, and a description of any
reimbursable expenditures. City shall pay Consultant no later than thirty (30) calendar
days after approval of the monthly invoice by City staff.
4.3 City shall reimburse Consultant only for those costs or expenses specifically
identified in Exhibit B to this Agreement and the Letter Proposal or specifically approved
in writing in advance by City.
4.4 Consultant shall not receive any compensation for Extra Work performed
without the prior written authorization of City. As used herein, "Extra Work" means any
Work that is determined by City to be necessary for the proper completion of the Project,
but which is not included within the Scope of Services and which the parties did not
reasonably anticipate would be necessary at the execution of this Agreement.
Compensation for any authorized Extra Work shall be paid in accordance with the
Schedule of Billing Rates as set forth in Exhibit B and the Letter Proposal.
5. PROJECT MANAGER
5.1 Consultant shall designate a Project Manager, who shall coordinate all
phases of the Project. This Project Manager shall be available to City at all reasonable
times during the Agreement term. Consultant has designated Christopher Baca to be its
Project Manager. Consultant shall not remove or reassign the Project Manager or any
personnel listed in Exhibit A or assign any new or replacement personnel to the Project
without the prior written consent of City. City's approval shall not be unreasonably
withheld with respect to the removal or assignment of non -key personnel.
5.2 Consultant, at the sole discretion of City, shall remove from the Project any
of its personnel assigned to the performance of Services upon written request of City.
Consultant warrants that it will continuously furnish the necessary personnel to complete
the Project on a timely basis as contemplated by this Agreement.
5.3 If Consultant is performing inspection services for City, the Project Manager
and any other assigned staff shall be equipped with a cellular phone to communicate with
City staff. The Project Manager's cellular phone number shall be provided to City.
6. ADMINISTRATION
This Agreement will be administered by the Public Works Department. City's
Public Works Director or designee shall be the Project Administrator and shall have the
authority to act for City under this Agreement. The Project Administrator shall represent
City in all matters pertaining to the Services to be rendered pursuant to this Agreement.
Willdan Engineering Page 3
9-44
7. CITY'S RESPONSIBILITIES
To assist Consultant in the execution of its responsibilities under this Agreement,
City agrees to provide access to and upon request of Consultant, one copy of all existing
relevant information on file at City. City will provide all such materials in a timely manner
so as not to cause delays in Consultant's Work schedule.
8. STANDARD OF CARE
8.1 All of the Services shall be performed by Consultant or under Consultant's
supervision. Consultant represents that it possesses the professional and technical
personnel required to perform the Services required by this Agreement, and that it will
perform all Services in a manner commensurate with community professional standards
and with the ordinary degree of skill and care that would be used by other reasonably
competent practitioners of the same discipline under similar circumstances. All Services
shall be performed by qualified and experienced personnel who are not employed by City.
By delivery of completed Work, Consultant certifies that the Work conforms to the
requirements of this Agreement, all applicable federal, state and local laws, and legally
recognized professional standards.
8.2 Consultant represents and warrants to City that it has, shall obtain, and shall
keep in full force and effect during the term hereof, at its sole cost and expense, all
licenses, permits, qualifications, insurance and approvals of whatsoever nature that is
legally required of Consultant to practice its profession. Consultant shall maintain a City
of Newport Beach business license during the term of this Agreement.
8.3 Consultant shall not be responsible for delay, nor shall Consultant be
responsible for damages or be in default or deemed to be in default by reason of strikes,
lockouts, accidents, acts of God, or the failure of City to furnish timely information or to
approve or disapprove Consultant's Work promptly, or delay or faulty performance by
City, contractors, or governmental agencies.
9. HOLD HARMLESS
9.1 To the fullest extent permitted by law, Consultant shall indemnify, defend
and hold harmless City, its City Council, boards and commissions, officers, agents,
volunteers, employees and any person or entity owning or otherwise in legal control of
the property upon which Consultant performs the Project and/or Services contemplated
by this Agreement (collectively, the "Indemnified Parties") from and against any and all
claims (including, without limitation, claims for bodily injury, death or damage to property),
demands, obligations, damages, actions, causes of action, suits, losses, judgments,
fines, penalties, liabilities, costs and expenses (including, without limitation, attorneys'
fees, disbursements and court costs) of every kind and nature whatsoever (individually,
a Claim; collectively, "Claims"), which may arise from or in any manner relate (directly or
indirectly) to any breach of the terms and conditions of this Agreement, any Work
performed or Services provided under this Agreement including, without limitation,
defects in workmanship or materials or Consultant's presence or activities conducted on
Willdan Engineering Page 4
9-45
the Project (including the negligent, reckless, and/or willful acts, errors and/or omissions
of Consultant, its principals, officers, agents, employees, vendors, suppliers, consultants,
subcontractors, anyone employed directly or indirectly by any of them or for whose acts
they may be liable, or any or all of them).
9.2 Notwithstanding the foregoing, nothing herein shall be construed to require
Consultant to indemnify the Indemnified Parties from any Claim arising from the sole
negligence or willful misconduct of the Indemnified Parties. Nothing in this indemnity shall
be construed as authorizing any award of attorneys' fees in any action on or to enforce
the terms of this Agreement. This indemnity shall apply to all claims and liability
regardless of whether any insurance policies are applicable. The policy limits do not act
as a limitation upon the amount of indemnification to be provided by Consultant.
10. INDEPENDENT CONTRACTOR
10.1 It is understood that City retains Consultant on an independent contractor
basis and Consultant is not an agent or employee of City. The manner and means of
conducting the Work are under the control of Consultant, except to the extent they are
limited by statute, rule or regulation and the expressed terms of this Agreement. No civil
service status or other right of employment shall accrue to Consultant or its employees.
Nothing in this Agreement shall be deemed to constitute approval for Consultant or any
of Consultant's employees or agents, to be the agents or employees of City. Consultant
shall have the responsibility for and control over the means of performing the Work,
provided that Consultant is in compliance with the terms of this Agreement. Anything in
this Agreement that may appear to give City the right to direct Consultant as to the details
of the performance of the Work or to exercise a measure of control over Consultant shall
mean only that Consultant shall follow the desires of City with respect to the results of the
Services.
10.2 Consultant agrees and acknowledges that no individual performing
Services or Work pursuant to this Agreement shall: work full-time for more than six (6)
months; work regular part-time service of at least an average of twenty (20) hours per
week for one year or longer; work nine hundred sixty (960) hours in any fiscal year; or
already be a CalPERS member.
10.3 Consultant must submit to and pass a criminal background investigation by
providing a complete set of fingerprints to City prior to commencing or performing
Services or Work. Consultant is required to submit any fees for the criminal background
investigation according to the City's most current administrative fee schedule or
successor document. Fingerprints may be required to be updated every five (5) years.
11. COOPERATION
Consultant agrees to work closely and cooperate fully with City's designated
Project Administrator and any other agencies that may have jurisdiction or interest in the
Work to be performed. City agrees to cooperate with the Consultant on the Project.
Willdan Engineering Page 5
91M
12. CITY POLICY
Consultant shall discuss and review all matters relating to policy and Project
direction with City's Project Administrator in advance of all critical decision points in order
to ensure the Project proceeds in a manner consistent with City goals and policies.
13. PROGRESS
Consultant is responsible for keeping the Project Administrator informed on a
regular basis regarding the status and progress of the Project, activities performed and
planned, and any meetings that have been scheduled or are desired.
14. INSURANCE
Without limiting Consultant's indemnification of City, and prior to commencement
of Work, Consultant shall obtain, provide and maintain at its own expense during the term
of this Agreement or for other periods as specified in this Agreement, policies of insurance
of the type, amounts, terms and conditions described in the Insurance Requirements
attached hereto as Exhibit C, and incorporated herein by reference.
15. PROHIBITION AGAINST ASSIGNMENTS AND TRANSFERS
Except as specifically authorized under this Agreement, the Services to be
provided under this Agreement shall not be assigned, transferred contracted or
subcontracted out without the prior written approval of City. Any of the following shall be
construed as an assignment: The sale, assignment, transfer or other disposition of any
of the issued and outstanding capital stock of Consultant, or of the interest of any general
partner or joint venturer or syndicate member or cotenant if Consultant is a partnership or
joint -venture or syndicate or co -tenancy, which shall result in changing the control of
Consultant. Control means fifty percent (50%) or more of the voting power or twenty-five
percent (25%) or more of the assets of the corporation, partnership or joint -venture.
16. SUBCONTRACTING
The subcontractors authorized by City, if any, to perform Work on this Project are
identified in Exhibit A and the Letter Proposal. Consultant shall be fully responsible to
City for all acts and omissions of any subcontractor. Nothing in this Agreement shall
create any contractual relationship between City and any subcontractor nor shall it create
any obligation on the part of City to pay or to see to the payment of any monies due to
any such subcontractor other than as otherwise required by law. City is an intended
beneficiary of any Work performed by the subcontractor for purposes of establishing a
duty of care between the subcontractor and City. Except as specifically authorized herein,
the Services to be provided under this Agreement shall not be otherwise assigned,
transferred, contracted or subcontracted out without the prior written approval of City.
Willdan Engineering Page 6
9-47
17. OWNERSHIP OF DOCUMENTS
17.1 Each and every report, draft, map, record, plan, document and other writing
produced, including but not limited to, websites, blogs, social media accounts and
applications (hereinafter "Documents"), prepared or caused to be prepared by Consultant,
its officers, employees, agents and subcontractors, in the course of implementing this
Agreement, shall become the exclusive property of City, and City shall have the sole right
to use such materials in its discretion without further compensation to Consultant or any
other party. Additionally, all material posted in cyberspace by Consultant, its officers,
employees, agents and subcontractors, in the course of implementing this Agreement,
shall become the exclusive property of City, and City shall have the sole right to use such
materials in its discretion without further compensation to Consultant or any other party.
Consultant shall, at Consultant's expense, provide such Documents, including all logins
and password information to City upon prior written request.
17.2 Documents, including drawings and specifications, prepared by Consultant
pursuant to this Agreement are not intended or represented to be suitable for reuse by
City or others on any other project. Any use of completed Documents for other projects
and any use of incomplete Documents without specific written authorization from
Consultant will be at City's sole risk and without liability to Consultant. Further, any and
all liability arising out of changes made to Consultant's deliverables under this Agreement
by City or persons other than Consultant is waived against Consultant, and City assumes
full responsibility for such changes unless City has given Consultant prior notice and has
received from Consultant written consent for such changes.
17.3 All written documents shall be transmitted to City in formats compatible with
Microsoft Office and/or viewable with Adobe Acrobat.
18. CONFIDENTIALITY
All Documents, including drafts, preliminary drawings or plans, notes and
communications that result from the Services in this Agreement, shall be kept confidential
unless City expressly authorizes in writing the release of information.
19. INTELLECTUAL PROPERTY INDEMNITY
Consultant shall defend and indemnify City, its agents, officers, representatives
and employees against any and all liability, including costs, for infringement or alleged
infringement of any United States' letters patent, trademark, or copyright, including costs,
contained in Consultant's Documents provided under this Agreement.
20. RECORDS
Consultant shall keep records and invoices in connection with the Services to be
performed under this Agreement. Consultant shall maintain complete and accurate
records with respect to the costs incurred under this Agreement and any Services,
expenditures and disbursements charged to City, for a minimum period of three (3) years,
or for any longer period required by law, from the date of final payment to Consultant
Willdan Engineering Page 7
mm
under this Agreement. All such records and invoices shall be clearly identifiable.
Consultant shall allow a representative of City to examine, audit and make transcripts or
copies of such records and invoices during regular business hours. Consultant shall allow
inspection of all Work, data, Documents, proceedings and activities related to the
Agreement for a period of three (3) years from the date of final payment to Consultant
under this Agreement.
21. WITHHOLDINGS
City may withhold payment to Consultant of any disputed sums until satisfaction of
the dispute with respect to such payment. Such withholding shall not be deemed to
constitute a failure to pay according to the terms of this Agreement. Consultant shall not
discontinue Work as a result of such withholding. Consultant shall have an immediate
right to appeal to the City Manager or designee with respect to such disputed sums.
Consultant shall be entitled to receive interest on any withheld sums at the rate of return
that City earned on its investments during the time period, from the date of withholding of
any amounts found to have been improperly withheld.
22. ERRORS AND OMISSIONS
In the event of errors or omissions that are due to the negligence or professional
inexperience of Consultant which result in expense to City greater than what would have
resulted if there were not errors or omissions in the Work accomplished by Consultant,
the additional design, construction and/or restoration expense shall be borne by
Consultant. Nothing in this Section is intended to limit City's rights under the law or any
other sections of this Agreement.
23. CITY'S RIGHT TO EMPLOY OTHER CONSULTANTS
City reserves the right to employ other Consultants in connection with the Project.
24. CONFLICTS OF INTEREST
24.1 Consultant or its employees may be subject to the provisions of the
California Political Reform Act of 1974 (the "Act") and/or Government Code §§ 1090 et
seq., which (1) require such persons to disclose any financial interest that may
foreseeably be materially affected by the Work performed under this Agreement, and (2)
prohibit such persons from making, or participating in making, decisions that will
foreseeably financially affect such interest.
24.2 If subject to the Act and/or Government Code §§ 1090 et seg., Consultant
shall conform to all requirements therein. Failure to do so constitutes a material breach
and is grounds for immediate termination of this Agreement by City. Consultant shall
indemnify and hold harmless City for any and all claims for damages resulting from
Consultant's violation of this Section.
Willdan Engineering Page 8
N1=0
25. NOTICES
25.1 All notices, demands, requests or approvals, including any change in
mailing address, to be given under the terms of this Agreement shall be given in writing,
and conclusively shall be deemed served when delivered personally, or on the third
business day after the deposit thereof in the United States mail, postage prepaid, first-
class mail, addressed as hereinafter provided.
25.2 All notices, demands, requests or approvals from Consultant to City shall
be addressed to City at:
Attn: Public Works Director
Public Works Department
City of Newport Beach
100 Civic Center Drive
PO Box 1768
Newport Beach, CA 92658
25.3 All notices, demands, requests or approvals from City to Consultant shall
be addressed to Consultant at:
Attn: Vanessa Munoz
Willdan Engineering
2401 E. Katella Avenue, Suite 300
Anaheim, CA 92805
26. CLAIMS
26.1 Unless a shorter time is specified elsewhere in this Agreement, before
making its final request for payment under this Agreement, Consultant shall submit to
City, in writing, all claims for compensation under or arising out of this Agreement.
Consultant's acceptance of the final payment shall constitute a waiver of all claims for
compensation under or arising out of this Agreement except those previously made in
writing and identified by Consultant in writing as unsettled at the time of its final request
for payment. Consultant and City expressly agree that in addition to any claims filing
requirements set forth in the Agreement, Consultant shall be required to file any claim
Consultant may have against City in strict conformance with the Government Claims Act
(Government Code sections 900 et seq.).
26.2 To the extent that Consultant's claim is a "Claim" as defined in Public
Contract Code section 9204 or any successor statute thereto, the Parties agree to follow
the dispute resolution process set forth therein. Any part of such "Claim" remaining in
dispute after completion of the dispute resolution process provided for in Public Contract
Code section 9204 or any successor statute thereto shall be subject to the Government
Claims Act requirements requiring Consultant to file a claim in strict conformance with the
Government Claims Act. To the extent that Contractor/Consultant's claim is not a "Claim"
as defined in Public Contract Code section 9204 or any successor statute thereto,
Willdan Engineering Page 9
W1
Consultant shall be required to file such claim with the City in strict conformance with the
Government Claims Act (Government Code sections 900 et seq.).
27. TERMINATION
27.1 In the event that either party fails or refuses to perform any of the provisions
of this Agreement at the time and in the manner required, that party shall be deemed in
default in the performance of this Agreement. If such default is not cured within a period
of two (2) calendar days, or if more than two (2) calendar days are reasonably required
to cure the default and the defaulting party fails to give adequate assurance of due
performance within two (2) calendar days after receipt of written notice of default,
specifying the nature of such default and the steps necessary to cure such default, and
thereafter diligently take steps to cure the default, the non -defaulting party may terminate
the Agreement forthwith by giving to the defaulting party written notice thereof.
27.2 Notwithstanding the above provisions, City shall have the right, at its sole
and absolute discretion and without cause, of terminating this Agreement at any time by
giving no less than seven (7) calendar days' prior written notice to Consultant. In the
event of termination under this Section, City shall pay Consultant for Services
satisfactorily performed and costs incurred up to the effective date of termination for which
Consultant has not been previously paid. On the effective date of termination, Consultant
shall deliver to City all reports, Documents and other information developed or
accumulated in the performance of this Agreement, whether in draft or final form.
28. PREVAILING WAGES
28.1 Pursuant to the applicable provisions of the Labor Code of the State of
California, not less than the general prevailing rate of per diem wages including legal
holidays and overtime Work for each craft or type of workman needed to execute the
Work contemplated under the Agreement shall be paid to all workmen employed on the
Work to be done according to the Agreement by the Consultant and any subcontractor.
In accordance with the California Labor Code (Sections 1770 et seq.), the Director of
Industrial Relations has ascertained the general prevailing rate of per diem wages in the
locality in which the Work is to be performed for each craft, classification, or type of
workman or mechanic needed to execute the Agreement. A copy of said determination
is available by calling the prevailing wage hotline number (415) 703-4774, and requesting
one from the Department of Industrial Relations. The Consultant is required to obtain the
wage determinations from the Department of Industrial Relations and post at the job site
the prevailing rate or per diem wages. It shall be the obligation of the Consultant or any
subcontractor under him/her to comply with all State of California labor laws, rules and
regulations and the parties agree that the City shall not be liable for any violation thereof.
28.2 Unless otherwise exempt by law, Consultant warrants that no contractor or
subcontractor was listed on the bid proposal for the Services that it is not currently
registered and qualified to perform public work. Consultant further warrants that it is
currently registered and qualified to perform "public work" pursuant to California Labor
Code section 1725.5 or any successor statute thereto and that no contractor or
Willdan Engineering Page 10
9-51
subcontractor will engage in the performance of the Services unless currently registered
and qualified to perform public work.
29. STANDARD PROVISIONS
29.1 Recitals. City and Consultant acknowledge that the above Recitals are true
and correct and are hereby incorporated by reference into this Agreement.
29.2 Compliance with all Laws. Consultant shall, at its own cost and expense,
comply with all statutes, ordinances, regulations and requirements of all governmental
entities, including federal, state, county or municipal, whether now in force or hereinafter
enacted. In addition, all Work prepared by Consultant shall conform to applicable City,
county, state and federal laws, rules, regulations and permit requirements and be subject
to approval of the Project Administrator and City.
29.3 Waiver. A waiver by either party of any breach, of any term, covenant or
condition contained herein shall not be deemed to be a waiver of any subsequent breach
of the same or any other term, covenant or condition contained herein, whether of the
same or a different character.
29.4 Integrated Contract. This Agreement represents the full and complete
understanding of every kind or nature whatsoever between the parties hereto, and all
preliminary negotiations and agreements of whatsoever kind or nature are merged herein.
No verbal agreement or implied covenant shall be held to vary the provisions herein.
29.5 Conflicts or Inconsistencies. In the event there are any conflicts or
inconsistencies between this Agreement and the Scope of Services or any other
attachments attached hereto, the terms of this Agreement shall govern.
29.6 Interpretation. The terms of this Agreement shall be construed in
accordance with the meaning of the language used and shall not be construed for or
against either party by reason of the authorship of the Agreement or any other rule of
construction which might otherwise apply.
29.7 Amendments. This Agreement may be modified or amended only by a
written document executed by both Consultant and City and approved as to form by the
City Attorney.
29.8 Severability. If any term or portion of this Agreement is held to be invalid,
illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining
provisions of this Agreement shall continue in full force and effect.
29.9 Controlling Law and Venue. The laws of the State of California shall govern
this Agreement and all matters relating to it and any action brought relating to this
Agreement shall be adjudicated in a court of competent jurisdiction in the County of
Orange, State of California.
Willdan Engineering Page 11
9-52
29.10 Equal Opportunity Employment. Consultant represents that it is an equal
opportunity employer and it shall not discriminate against any subcontractor, employee
or applicant for employment because race, religious creed, color, national origin,
ancestry, physical handicap, medical condition, marital status, sex, sexual orientation,
age or any other impermissible basis under law.
29.11 No Attorneys' Fees. In the event of any dispute or legal action arising under
this Agreement, the prevailing party shall not be entitled to attorneys' fees.
29.12 Counterparts. This Agreement may be executed in two (2) or more
counterparts, each of which shall be deemed an original and all of which together shall
constitute one (1) and the same instrument.
[SIGNATURES ON NEXT PAGE]
Willdan Engineering Page 12
9-53
IN WITNESS WHEREOF, the parties have caused this Agreement to be executed
on the dates written below.
APPROVED AS TO FORM:
CITY ATTOR EY'S OFFICE
Date: STZ 2a
By:
. Aaron C. Harp'
City Attorney
ATTEST:
Date:
in
Leilani I. Brown
City Clerk
CITY OF NEWPORT BEACH,
a California municipal corporation
Date:
By:
Diane B. Dixon
Mayor
CONSULTANT: Willdan
California corporation
Date:
By:_
Daniel Chow
Chief Executive Officer
Date:
By:
Stacey McLaughlin
Chief Financial Officer
[END OF SIGNATURES]
Attachments: Exhibit A — Scope of Services
Exhibit B — Schedule of Billing Rates
Exhibit C — Insurance Requirements
Engineering, a
Willdan Engineering Page 13
9-54
EXHIBIT A
SCOPE OF SERVICES
On -Call Services for Public Works: Development and Utility Permit Inspection
Services and Construction Administration
Consultant shall provide public works inspection and construction administration on-call
services as determined by Public Works Department.
• Depending on the project or inspection activity, services would be agreed to
depending on the need for inspection and construction administration services.
Consultant will be assigned to specific projects/permits and work with City staff
on administration and inspection of City projects and private
improvements/encroachments within public right-of-way in the following areas as
necessary:
o construction observation;
o public contract administration;
o attend project meetings;
o utility coordination;
o traffic control;
o construction staking and surveying;
o material testing;
o project documentation;
o record drawings;
o permit system record keeping; and
o liaison with Staff.
Willdan Engineering Page A-1 9-55
EXHIBIT B
SCHEDULE OF BILLING RATES
Name
Chris Baca, RCI, CESSWI
Role
Project Manager
Hourly Rate
$209
Michael Sustos, PE, ENV SP
Resident Engineer
$166
Lee Marshall
Public Works Inspector
$116
Cesar Cantuba
Public Works Inspector
$116
Barry Knutson
Public Works Inspector
$116
Glenn Stanley
Public Works Inspector
$116
Tim Scheffer
Public Works Inspector
$116
Victor Ayala
Public Works Inspector
$116
Willdan Engineering page B-1 9-56
EXHIBIT C
INSURANCE REQUIREMENTS — PROFESSIONAL SERVICES
1. Provision of Insurance. Without limiting Consultant's indemnification of City, and
prior to commencement of Work, Consultant shall obtain, provide and maintain at
its own expense during the term of this Agreement, policies of insurance of the
type and amounts described below and in a form satisfactory to City. Consultant
agrees to provide insurance in accordance with requirements set forth here. If
Consultant uses existing coverage to comply and that coverage does not meet
these requirements, Consultant agrees to amend, supplement or endorse the
existing coverage.
2. Acceptable Insurers. All insurance policies shall be issued by an insurance
company currently authorized by the Insurance Commissioner to transact
business of insurance in the State of California, with an assigned policyholders'
Rating of A- (or higher) and Financial Size Category Class VII (or larger) in
accordance with the latest edition of Best's Key Rating Guide, unless otherwise
approved by the City's Risk Manager,
3. Coverage Requirements.
A. Workers' Compensation Insurance. Consultant shall maintain Workers'
Compensation Insurance, statutory limits, and Employer's Liability
Insurance with limits of at least one million dollars ($1,000,000) each
accident for bodily injury by accident and each employee for bodily injury by
disease in accordance with the laws of the State of California, Section 3700
of the Labor Code.
Consultant shall submit to City, along with the certificate of insurance, a
Waiver of Subrogation endorsement in favor of City, its City Council, boards
and commissions, officers, agents, volunteers, employees and any person
or entity owning or otherwise in legal control of the property upon which
Consultant performs the Project and/or Services contemplated by this
Agreement.
B. General Liability Insurance. Consultant shall maintain commercial general
liability insurance, and if necessary umbrella liability insurance, with
coverage at least as broad as provided by Insurance Services Office form
CG 00 01, in an amount not less than one million dollars ($1,000,000) per
occurrence, two million dollars ($2,000,000) general aggregate. The policy
shall cover liability arising from premises, operations, personal and
advertising injury, and liability assumed under an insured contract (including
the tort liability of another assumed in a business contract).
C. Automobile Liability Insurance. Consultant shall maintain automobile
insurance at least as broad as Insurance Services Office form CA 00 01
covering bodily injury and property damage for all activities of Consultant
arising out of or in connection with Work to be performed under this
Willdan Engineering Page C-1 9-57
Agreement, including coverage for any owned, hired, non -owned or rented
vehicles, in an amount not less than one million dollars ($1,000,000)
combined single limit each accident.
D. Professional Liabili Errors & Omissions Insurance. Consultant shall
maintain professional liability insurance that covers the Services to be
performed in connection with this Agreement, in the minimum amount of
one million dollars ($1,000,000) per claim and two million dollars
($2,000,000) in the aggregate. Any policy inception date, continuity date,
or retroactive date must be before the Effective Date of this Agreement and
Consultant agrees to maintain continuous coverage through a period no
less than three years after completion of the Services required by this
Agreement.
4. Other Insurance Requirements. The policies are to contain, or be endorsed to
contain, the following provisions:
A. Waiver of Subrogation. All insurance coverage maintained or procured
pursuant to this Agreement shall be endorsed to waive subrogation against
City, its City Council, boards and commissions, officers, agents, volunteers,
employees and any person or entity owning or otherwise in legal control of
the property upon which Consultant performs the Project and/or Services
contemplated by this Agreement or shall specifically allow Consultant or
others providing insurance evidence in compliance with these requirements
to waive their right of recovery prior to a loss. Consultant hereby waives its
own right of recovery against City, and shall require similar written express
waivers from each of its subconsultants.
B. Additional Insured Status. All liability policies including general liability,
excess liability, pollution liability, and automobile liability, if required, but not
including professional liability, shall provide or be endorsed to provide that
City, its City Council, boards and commissions, officers, agents, volunteers,
employees and any person or entity owning or otherwise in legal control of
the property upon which Consultant performs the Project and/or Services
contemplated by this Agreement shall be included as insureds under such
policies.
C. Primary and Non Contributory. All liability coverage shall apply on a primary
basis and shall not require contribution from any insurance or self-insurance
maintained by City.
D. Notice of Cancellation. All policies shall provide City with thirty (30)
calendar days' notice of cancellation (except for nonpayment for which ten
(10) calendar days' notice is required) or nonrenewal of coverage for each
required coverage.
5. Additional Agreements Between the Parties. The parties hereby agree to the
following:
Willdan Engineering Page C-2 9-58
A. Evidence of Insurance. Consultant shall provide certificates of insurance to
City as evidence of the insurance coverage required herein, along with a
waiver of subrogation endorsement for workers' compensation and other
endorsements as specified herein for each coverage. Insurance certificates
and endorsement must be approved by City's Risk Manager prior to
commencement of performance. Current certification of insurance shall be
kept on file with City at all times during the term of this Agreement. City
reserves the right to require complete, certified copies of all required
insurance policies, at any time.
B. City's Right to Revise Requirements. City reserves the right at any time
during the term of the Agreement to change the amounts and types of
insurance required by giving Consultant sixty (60) calendar days' advance
written notice of such change. If such change results in substantial
additional cost to Consultant, City and Consultant may renegotiate
Consultant's compensation.
C. Enforcement of Agreement Provisions. Consultant acknowledges and
agrees that any actual or alleged failure on the part of City to inform
Consultant of non-compliance with any requirement imposes no additional
obligations on City nor does it waive any rights hereunder.
D. Requirements not Limiting. Requirements of specific coverage features or
limits contained in this Section are not intended as a limitation on coverage,
limits or other requirements, or a waiver of any coverage normally provided
by any insurance. Specific reference to a given coverage feature is for
purposes of clarification only as it pertains to a given issue and is not
intended by any party or insured to be all inclusive, or to the exclusion of
other coverage, or a waiver of any type. If the Consultant maintains higher
limits than the minimums shown above, the City requires and shall be
entitled to coverage for higher limits maintained by the Consultant. Any
available insurance proceeds in excess of the specified minimum limits of
insurance and coverage shall be available to the City.
E. Self-insured Retentions. Any self-insured retentions must be declared to
and approved by City. City reserves the right to require that self-insured
retentions be eliminated, lowered, or replaced by a deductible. Self-
insurance will not be considered to comply with these requirements unless
approved by City.
F. City Remedies for Non -Compliance. If Consultant or any subconsultant fails
to provide and maintain insurance as required herein, then City shall have
the right but not the obligation, to purchase such insurance, to terminate this
Agreement, or to suspend Consultant's right to proceed until proper
evidence of insurance is provided. Any amounts paid by City shall, at City's
sole option, be deducted from amounts payable to Consultant or reimbursed
by Consultant upon demand.
Willdan Engineering Page C-3 9.59
G. Timely Notice of Claims. Consultant shall give City prompt and timely notice
of claims made or suits instituted that arise out of or result from Consultant's
performance under this Agreement, and that involve or may involve
coverage under any of the required liability policies. City assumes no
obligation or liability by such notice, but has the right (but not the duty) to
monitor the handling of any such claim or claims if they are likely to involve
City.
H. Consultant's Insurance. Consultant shall also procure and maintain, at its
own cost and expense, any additional kinds of insurance, which in its own
judgment may be necessary for its proper protection and prosecution of the
Work.
Willdan Engineering Page C-4 9-60