HomeMy WebLinkAbout09 - Award of On -Call Professional Transportation Engineering Services AgreementsTO:
FROM
CITY OF
NEWPORT BEACH
City Council Staff Report
September 24, 2019
Agenda Item No. 9
HONORABLE MAYOR AND MEMBERS OF THE CITY COUNCIL
David A. Webb, Public Works Director - 949-644-3311,
dawebb@newportbeachca.gov
PREPARED BY: Brad Sommers, Principal Civil Engineer
PHONE: 949-644-3326
TITLE: Approval and Award of On -Call Professional Transportation
Engineering Services Agreements with Willdan Engineering, RK
Engineering Group, Inc., and Ganddini Group, Inc.
ABSTRACT:
Transportation related design and planning projects often require use of professional
consulting services to provide design, planning, studies and review to ensure efficient
delivery of transportation -related projects.
Upon completion of the selection process for a Request for Proposal (RFP) for On -Call
Professional Transportation Engineering Services, staff recommends awarding on-call
contracts to Willdan Engineering, RK Engineering Group, Inc., and Ganddini Group, Inc.
for five-year terms and a total not -to -exceed amount of $300,000 per agreement.
RECOMMENDATION:
a) Determine this action is exempt from the California Environmental Quality Act (CEQA)
pursuant to Sections 15060(c)(2) and 15060(c)(3) of the CEQA Guidelines because
this action will not result in a physical change to the environment, directly or indirectly;
and
b) Approve On -Call Professional Transportation Engineering Services Agreements with
Willdan Engineering, RK Engineering Group, Inc., and Ganddini Group, Inc. for a
five-year term and a total amount not -to -exceed $300,000 per agreement, and
authorize the Mayor and City Clerk to execute the agreements.
FUNDING REQUIREMENTS:
The adopted budget(s) include sufficient funding. Services for individual projects will be
expensed to the corresponding Public Works Department Maintenance and Operating
Budget and/or Capital Improvement Program (CIP) Budget.
9-1
Approval and Award of On -Call Professional Transportation Engineering Services
Agreements with Willdan Engineering, RK Engineering Group, Inc., and Ganddini
Group, Inc.
September 24, 2019
Page 2
DISCUSSION:
The City uses private sector consultants to fulfill various engineering and other
professional services associated with Public Works projects. Transportation Engineering
encompasses planning, design, construction, and maintenance of the City's roadway
network with the goal of safe and efficient movement of people and goods. The
transportation discipline is multifaceted with items such as preparation of transportation
studies, traffic signal design, roadway signage and striping, construction traffic control,
and design of pedestrian and bicycle facilities. Each has unique details and requires firms
that specialize in a specific branch of transportation engineering.
In order to address and to expedite transportation related items, studies and projects, the
City currently has ten separate on-call agreements for Transportation Engineering
services to facilitate the wide range of transportation and traffic related needs. Eight of
these agreements are currently set to expire within the year and are being reviewed for
potential time extensions, with the goal of maintaining an adequate number of available
supporting contract consultant resources.
To ensure staff has adequate resources to continue project delivery, the City issued a
Request for Proposals (RFP) in July 2019 for additional On -Call Professional
Transportation Engineering Services. The following 13 firms submitted proposals:
Firm Name
Total Score
Rank
Willdan Engineering
281
1
Kimley-Horn and Associates, Inc. *
279
2
RK Engineering Group, Inc.
279
3
Ganddini Group, Inc.
265
4
Michael Baker International
261
5
DKS
256
6
JM Diaz, Inc.
253
7
Fehr & Peers
252
8
GHD Inc.
252
8
Quantum Consulting, Inc.
248
10
W.G. Zimmerman Engineering, Inc.
247
11
General Technology & Solutions
239
12
Mark Thomas
235
13
Kimley-Horn and the City were not able to agree on the terms of the agreement.
9-2
Approval and Award of On -Call Professional Transportation Engineering Services
Agreements with Willdan Engineering, RK Engineering Group, Inc., and Ganddini
Group, Inc.
September 24, 2019
Page 3
The City's proposal review team consisted of three staff members from the Public Works -
Traffic and Transportation Division. Proposals were evaluated by the review team
independently. Evaluations were based in accordance to each proposal's demonstration
of the firm's abilities and expertise of the project team related to transportation projects,
qualifications and experience, a demonstrated understanding of the City's needs, and the
ability to deploy appropriate resources. Evaluations also considered each firm's recent
experience and project references in conducting work for public agencies of similar scope
and complexity. Upon completion of the qualifications -based review of the proposals, the
sealed fee schedules were opened and reviewed for the top firms and confirmed to be
reasonable and feasible when considering each firm's ability and their available
resources.
Although Kimley-Horn and Associates was ranked second through the review process,
they requested additional revisions to the contract language that are not acceptable by
the City. Therefore, Kimley-Horn and Associates has been removed from further
consideration.
Staff requests approval of three separate On -Call Professional Services Agreements with
Willdan Engineering, RK Engineering Group, Inc., and Ganddini Group, Inc. for
Transportation Engineering Services for a five-year term and a total amount not -to -
exceed $300,000 per agreement.
ENVIRONMENTAL REVIEW:
Staff recommends the City Council find this action is not subject to the California
Environmental Quality Act (CEQA) pursuant to Sections 15060(c)(2) (the activity will not
result in a direct or reasonably foreseeable indirect physical change in the environment)
and 15060(c)(3) (the activity is not a project as defined in Section 15378) of the CEQA
Guidelines, California Code of Regulations, Title 14, Chapter 3, because it has no
potential for resulting in physical change to the environment, directly or indirectly.
NOTICING:
The agenda item has been noticed according to the Brown Act (72 hours in advance of
the meeting at which the City Council considers the item).
ATTACHMENTS:
Attachment A
— Professional Services Agreement with Willdan Engineering
Attachment B
— Professional Services Agreement with RK Engineering Group, Inc.
Attachment C
— Professional Services Agreement with Ganddini Group, Inc.
9-3
ATTACHMENT A
ON-CALL PROFESSIONAL SERVICES AGREEMENT
WITH WILLDAN ENGINEERING FOR
TRAFFIC/TRANSPORTATION ENGINEERING
THIS ON-CALL PROFESSIONAL SERVICES AGREEMENT ("Agreement") is
made and entered into as of this 24th day of September, 2019 ("Effective Date"), by and
between the CITY OF NEWPORT BEACH, a California municipal corporation and charter
city ("City"), and WILLDAN ENGINEERING, a California corporation ("Consultant"),
whose address is 2401 E. Katella Avenue, Suite 300, Anaheim, CA 92806, and is made
with reference to the following:
RECITALS
A. City is a municipal corporation duly organized and validly existing under the laws
of the State of California with the power to carry on its business as it is now being
conducted under the statutes of the State of California and the Charter of City.
B. City desires to engage Consultant to provide professional traffic and/or
transportation engineering services on an on-call/as-needed basis ("Project").
C. Consultant possesses the skill, experience, ability, background, certification and
knowledge to provide the professional services described in this Agreement.
D. City has solicited and received a proposal from Consultant, has reviewed the
previous experience and evaluated the expertise of Consultant, and desires to
retain Consultant to render professional services under the terms and conditions
set forth in this Agreement.
NOW, THEREFORE, it is mutually agreed by and between the undersigned parties
as follows:
The term of this Agreement shall commence on the Effective Date, and shall
terminate on September 23, 2024, unless terminated earlier as set forth herein.
2. SERVICES TO BE PERFORMED
2.1 Consultant shall perform the on-call services described in the Scope of
Services attached hereto as Exhibit A and incorporated herein by reference ("Services"
or "Work"). Upon written request from the Project Administrator as defined herein,
Consultant shall provide a letter proposal for Services requested by the City (hereinafter
referred to as the "Letter Proposal"). The Letter Proposal shall include the following:
2.1.1 A detailed description of the Services to be provided;
2.1.2 The position of each person to be assigned to perform the Services,
and the name of the individuals to be assigned, if available;
and
2.1.3 The estimated number of hours and cost to complete the Services;
2.1.4 The time needed to finish the specific project.
2.2 No Services shall be provided until the Project Administrator has provided
written acceptance of the Letter Proposal. Once authorized to proceed, Consultant shall
diligently perform the duties in the approved Letter Proposal.
3. TIME OF PERFORMANCE
3.1 Time is of the essence in the performance of Services under this Agreement
and Consultant shall perform the Services in accordance with the schedule included in
Exhibit A and the Letter Proposal. In the absence of a specific schedule, the Services
shall be performed to completion in a diligent and timely manner. The failure by
Consultant to strictly adhere to the schedule set forth in Exhibit A and the Letter Proposal,
if any, or perform the Services in a diligent and timely manner may result in termination
of this Agreement by City.
3.2 Notwithstanding the foregoing, Consultant shall not be responsible for
delays due to causes beyond Consultant's reasonable control. However, in the case of
any such delay in the Services to be provided for the Project, each party hereby agrees
to provide notice within two (2) calendar days of the occurrence causing the delay to the
other party so that all delays can be addressed.
3.3 Consultant shall submit all requests for extensions of time for performance
in writing to the Project Administrator as defined herein not later than ten (10) calendar
days after the start of the condition that purportedly causes a delay. The Project
Administrator shall review all such requests and may grant reasonable time extensions
for unforeseeable delays that are beyond Consultant's control.
3.4 For all time periods not specifically set forth herein, Consultant shall
respond in the most expedient and appropriate manner under the circumstances, by
hand -delivery or mail.
4. COMPENSATION TO CONSULTANT
4.1 City shall pay Consultant for the Services on a time and expense not -to -
exceed basis in accordance with the provisions of this Section and the Letter Proposal
and the Schedule of Billing Rates attached hereto as Exhibit B and incorporated herein
by reference. Consultant's compensation for all Work performed in accordance with this
Agreement, including all reimbursable items and subconsultant fees, shall not exceed
Three Hundred Thousand Dollars and 001100 ($300,000.00), without prior written
authorization from City. Except as otherwise provided herein, no billing rate changes
shall be made during the term of this Agreement without the prior written approval of City.
4.2 Upon the first anniversary of the Effective Date and upon each anniversary
of the Effective Date thereafter, the billing rates set forth in Exhibit B ("Billing Rates") shall
WILLDAN ENGINEERING Page 2
MR
be adjusted in proportion to changes in the Consumer Price Index, subject to the
maximum adjustment set forth below. Such adjustment shall be made by multiplying the
Billing Rates in Exhibit B by a fraction, the numerator of which is the value of the
Consumer Price Index for the calendar month three (3) months preceding the calendar
month for which such adjustment is to be made, and the denominator of which is the value
of the Consumer Price Index for the same calendar month immediately prior to Effective
Date. The Consumer Price Index to be used in such calculation is the "Consumer Price
Index, All Items, 1982-84=100 for All Urban Consumers (CPI -U)", for the Los Angeles -
Riverside -Orange County Metropolitan Area, published by the United States Department
of Labor, Bureau of Labor Statistics. If both an official index and one or more unofficial
indices are published, the official index shall be used. If said Consumer Price Index is no
longer published at the adjustment date, it shall be constructed by conversion tables
included in such new index. In no event, however, shall the amount payable under this
Agreement be reduced below the Billing Rates in effect immediately preceding such
adjustment. The maximum adjustment increase to the Billing Rates, for any year where
an adjustment is made pursuant to this Section, shall not exceed the Consumer Price
Index or 2.0% of the Billing Rates in effect immediately preceding such adjustment,
whichever is less.
4.3 Consultant shall submit monthly invoices to City describing the Work
performed the preceding month. Consultant's bills shall include the name of the person
who performed the Work, a brief description of the Services performed and/or the specific
task in the Scope of Services to which it relates, the date the Services were performed,
the number of hours spent on all Work billed on an hourly basis, and a description of any
reimbursable expenditures. City shall pay Consultant no later than thirty (30) calendar
days after approval of the monthly invoice by City staff.
4.4 City shall reimburse Consultant only for those costs or expenses specifically
identified in Exhibit B to this Agreement and the Letter Proposal or specifically approved
in writing in advance by City.
4.5 Consultant shall not receive any compensation for Extra Work performed
without the prior written authorization of City. As used herein, "Extra Work" means any
Work that is determined by City to be necessary for the proper completion of the Project,
but which is not included within the Scope of Services and which the parties did not
reasonably anticipate would be necessary at the execution of this Agreement.
Compensation for any authorized Extra Work shall be paid in accordance with the
Schedule of Billing Rates as set forth in Exhibit B and the Letter Proposal.
mC91111111►ITTIIZYTITCIA7
5.1 Consultant shall designate a Project Manager, who shall coordinate all
phases of the Project. This Project Manager shall be available to City at all reasonable
times during the Agreement term. Consultant has designated Vanessa Munoz, PE, TE,
PTOE to be its Project Manager. Consultant shall not remove or reassign the Project
Manager or any personnel listed in Exhibit A or assign any new or replacement personnel
WILLDAN ENGINEERING Page 3
on
to the Project without the prior written consent of City. City's approval shall not be
unreasonably withheld with respect to the removal or assignment of non -key personnel.
5.2 Consultant, at the sole discretion of City, shall remove from the Project any
of its personnel assigned to the performance of Services upon written request of City.
Consultant warrants that it will continuously furnish the necessary personnel to complete
the Project on a timely basis as contemplated by this Agreement.
5.3 If Consultant is performing inspection services for City, the Project Manager
and any other assigned staff shall be equipped with a cellular phone to communicate with
City staff. The Project Manager's cellular phone number shall be provided to City.
6. ADMINISTRATION
This Agreement will be administered by the Public Works Department. City's
Public Works Director or designee shall be the Project Administrator and shall have the
authority to act for City under this Agreement. The Project Administrator shall represent
City in all matters pertaining to the Services to be rendered pursuant to this Agreement.
7. CITY'S RESPONSIBILITIES
To assist Consultant in the execution of its responsibilities under this Agreement,
City agrees to provide access to and upon request of Consultant, one copy of all existing
relevant information on file at City. City will provide all such materials in a timely manner
so as not to cause delays in Consultant's Work schedule.
8. STANDARD OF CARE
8.1 All of the Services shall be performed by Consultant or under Consultant's
supervision. Consultant represents that it possesses the professional and technical
personnel required to perform the Services required by this Agreement, and that it will
perform all Services in a manner commensurate with community professional standards
and with the ordinary degree of skill and care that would be used by other reasonably
competent practitioners of the same discipline under similar circumstances. All Services
shall be performed by qualified and experienced personnel who are not employed by City.
By delivery of completed Work, Consultant certifies that the Work conforms to the
requirements of this Agreement, all applicable federal, state and local laws, and legally
recognized professional standards.
8.2 Consultant represents and warrants to City that it has, shall obtain, and shall
keep in full force and effect during the term hereof, at its sole cost and expense, all
licenses, permits, qualifications, insurance and approvals of whatsoever nature that is
legally required of Consultant to practice its profession. Consultant shall maintain a City
of Newport Beach business license during the term of this Agreement.
8.3 Consultant shall not be responsible for delay, nor shall Consultant be
responsible for damages or be in default or deemed to be in default by reason of strikes,
lockouts, accidents, acts of God, or the failure of City to furnish timely information or to
WILLDAN ENGINEERING Page 4
9-7
approve or disapprove Consultant's Work promptly, or delay or faulty performance by
City, contractors, or governmental agencies.
9. HOLD HARMLESS
9.1 To the fullest extent permitted by law, Consultant shall indemnify, defend
and hold harmless City, its City Council, boards and commissions, officers, agents,
volunteers, employees and any person or entity owning or otherwise in legal control of
the property upon which Consultant performs the Project and/or Services contemplated
by this (collectively, the "Indemnified Parties), from and against any and all claims
(including, without limitation, claims for bodily injury, death or damage to property),
demands, obligations, damages, actions, causes of action, suits, losses, judgments,
fines, penalties, liabilities, costs and expenses (including, without limitation, attorneys'
fees, disbursements and court costs) of every kind and nature whatsoever (individually,
a Claim; collectively, "Claims"), and which relate (directly or indirectly) to the negligence,
recklessness, or willful misconduct of the Consultant or its principals, officers, agents,
employees, vendors, suppliers, subconsultants, subcontractors, anyone employed
directly or indirectly by any of them or for whose acts they may be liable, or any or all of
them.
9.2 Notwithstanding the foregoing, nothing herein shall be construed to require
Consultant to indemnify the Indemnified Parties from any Claim arising from the sole
negligence, active negligence or willful misconduct of the Indemnified Parties. Nothing in
this indemnity shall be construed as authorizing any award of attorneys' fees in any action
on or to enforce the terms of this Agreement. This indemnity shall apply to all claims and
liability regardless of whether any insurance policies are applicable. The policy limits do
not act as a limitation upon the amount of indemnification to be provided by the
Consultant.
10. INDEPENDENT CONTRACTOR
10.1 It is understood that City retains Consultant on an independent contractor
basis and Consultant is not an agent or employee of City. The manner and means of
conducting the Work are under the control of Consultant, except to the extent they are
limited by statute, rule or regulation and the expressed terms of this Agreement. No civil
service status or other right of employment shall accrue to Consultant or its employees.
Nothing in this Agreement shall be deemed to constitute approval for Consultant or any
of Consultant's employees or agents, to be the agents or employees of City. Consultant
shall have the responsibility for and control over the means of performing the Work,
provided that Consultant is in compliance with the terms of this Agreement. Anything in
this Agreement that may appear to give City the right to direct Consultant as to the details
of the performance of the Work or to exercise a measure of control over Consultant shall
mean only that Consultant shall follow the desires of City with respect to the results of the
Services.
10.2 Consultant agrees and acknowledges that no individual performing
Services or Work pursuant to this Agreement shall: work full-time for more than six (6)
WILLDAN ENGINEERING Page 5
9-8
months; work regular part-time service of at least an average of twenty (20) hours per
week for one year or longer; work nine hundred sixty (960) hours in any fiscal year; or
already be a CalPERS member.
10.3 Consultant must submit to and pass a criminal background investigation by
providing a complete set of fingerprints to City prior to commencing or performing
Services or Work. Consultant is required to submit any fees for the criminal background
investigation according to the City's most current administrative fee schedule or
successor document. Fingerprints may be required to be updated every five (5) years.
11. COOPERATION
Consultant agrees to work closely and cooperate fully with City's designated
Project Administrator and any other agencies that may have jurisdiction or interest in the
Work to be performed. City agrees to cooperate with the Consultant on the Project.
12. CITY POLICY
Consultant shall discuss and review all matters relating to policy and Project
direction with City's Project Administrator in advance of all critical decision points in order
to ensure the Project proceeds in a manner consistent with City goals and policies.
13. PROGRESS
Consultant is responsible for keeping the Project Administrator informed on a
regular basis regarding the status and progress of the Project, activities performed and
planned, and any meetings that have been scheduled or are desired.
14. INSURANCE
Without limiting Consultant's indemnification of City, and prior to commencement
of Work, Consultant shall obtain, provide and maintain at its own expense during the term
of this Agreement or for other periods as specified in this Agreement, policies of insurance
of the type, amounts, terms and conditions described in the Insurance Requirements
attached hereto as Exhibit C, and incorporated herein by reference.
15. PROHIBITION AGAINST ASSIGNMENTS AND TRANSFERS
Except as specifically authorized under this Agreement, the Services to be
provided under this Agreement shall not be assigned, transferred contracted or
subcontracted out without the prior written approval of City. Any of the following shall be
construed as an assignment: The sale, assignment, transfer or other disposition of any
of the issued and outstanding capital stock of Consultant, or of the interest of any general
partner or joint venturer or syndicate member or cotenant if Consultant is a partnership or
joint -venture or syndicate or co -tenancy, which shall result in changing the control of
Consultant. Control means fifty percent (50%) or more of the voting power or twenty-five
percent (25%) or more of the assets of the corporation, partnership or joint -venture.
WILLDAN ENGINEERING Page 6
16. SUBCONTRACTING
The subcontractors authorized by City, if any, to perform Work on this Project are
identified in Exhibit A and the Letter Proposal. Consultant shall be fully responsible to
City for all acts and omissions of any subcontractor. Nothing in this Agreement shall
create any contractual relationship between City and any subcontractor nor shall it create
any obligation on the part of City to pay or to see to the payment of any monies due to
any such subcontractor other than as otherwise required by law. City is an intended
beneficiary of any Work performed by the subcontractor for purposes of establishing a
duty of care between the subcontractor and City. Except as specifically authorized herein,
the Services to be provided under this Agreement shall not be otherwise assigned,
transferred, contracted or subcontracted out without the prior written approval of City.
17. OWNERSHIP OF DOCUMENTS
17.1 Each and every report, draft, map, record, plan, document and other writing
produced, including but not limited to, websites, blogs, social media accounts and
applications (hereinafter "Documents"), prepared or caused to be prepared by Consultant,
its officers, employees, agents and subcontractors, in the course of implementing this
Agreement, shall become the exclusive property of City, and City shall have the sole right
to use such materials in its discretion without further compensation to Consultant or any
other party. Additionally, all material posted in cyberspace by Consultant, its officers,
employees, agents and subcontractors, in the course of implementing this Agreement,
shall become the exclusive property of City, and City shall have the sole right to use such
materials in its discretion without further compensation to Consultant or any other party.
Consultant shall, at Consultant's expense, provide such Documents, including all logins
and password information to City upon prior written request.
17.2 Documents, including drawings and specifications, prepared by Consultant
pursuant to this Agreement are not intended or represented to be suitable for reuse by
City or others on any other project. Any use of completed Documents for other projects
and any use of incomplete Documents without specific written authorization from
Consultant will be at City's sole risk and without liability to Consultant. Further, any and
all liability arising out of changes made to Consultant's deliverables under this Agreement
by City or persons other than Consultant is waived against Consultant, and City assumes
full responsibility for such changes unless City has given Consultant prior notice and has
received from Consultant written consent for such changes.
17.3 CADD data delivered to City shall include the professional stamp of the
engineer or architect in charge of or responsible for the Work. City agrees that Consultant
shall not be liable for claims, liabilities or losses arising out of, or connected with (a) the
modification or misuse by City, or anyone authorized by City, of CADD data; (b) the
decline of accuracy or readability of CADD data due to inappropriate storage conditions
or duration; or (c) any use by City, or anyone authorized by City, of CADD data for
additions to this Project, for the completion of this Project by others, or for any other
Project, excepting only such use as is authorized, in writing, by Consultant. By
acceptance of CADD data, City agrees to indemnify Consultant for damages and liability
WILLDAN ENGINEERING Page 7
9-10
resulting from the modification or misuse of such CADD data. All original drawings shall
be submitted to City in the version of AutoCAD used by the City in .dwg file format, on a
CD, and should comply with the City's digital submission requirements for improvement
plans available from the City's Public Works Department. The City will provide Consultant
with City title sheets as AutoCAD file(s) in .dwg file format. All written documents shall
be transmitted to City in formats compatible with Microsoft Office and/or viewable with
Adobe Acrobat.
17.4 All improvement and/or construction plans shall be prepared with indelible
waterproof ink or electrostatically plotted on standard twenty-four inch (24") by thirty-six
inch (36") Mylar with a minimum thickness of three (3) mils. Consultant shall provide to
City 'As -Built' drawings and a copy of digital Computer Aided Design and Drafting
("CADD") and Tagged Image File Format (.tiff) files of all final sheets within ninety (90)
days after finalization of the Project. For more detailed requirements, a copy of the City
of Newport Beach Standard Design Requirements is available from the City's Public
Works Department.
18. OPINION OF COST
Any opinion of the construction cost prepared by Consultant represents the
Consultant's judgment as a design professional and is supplied for the general guidance
of City. Since Consultant has no control over the cost of labor and material, or over
competitive bidding or market conditions, Consultant does not guarantee the accuracy of
such opinions as compared to Consultant or contractor bids or actual cost to City.
19. CONFIDENTIALITY
All Documents, including drafts, preliminary drawings or plans, notes and
communications that result from the Services in this Agreement, shall be kept confidential
unless City expressly authorizes in writing the release of information.
20. INTELLECTUAL PROPERTY INDEMNITY
Consultant shall defend and indemnify City, its agents, officers, representatives
and employees against any and all liability, including costs, for infringement or alleged
infringement of any United States' letters patent, trademark, or copyright, including costs,
contained in Consultant's Documents provided under this Agreement.
21. RECORDS
Consultant shall keep records and invoices in connection with the Services to be
performed under this Agreement. Consultant shall maintain complete and accurate
records with respect to the costs incurred under this Agreement and any Services,
expenditures and disbursements charged to City, for a minimum period of three (3) years,
or for any longer period required by law, from the date of final payment to Consultant
under this Agreement. All such records and invoices shall be clearly identifiable.
Consultant shall allow a representative of City to examine, audit and make transcripts or
copies of such records and invoices during regular business hours. Consultant shall allow
WILLDAN ENGINEERING Page 8
9-11
inspection of all Work, data, Documents, proceedings and activities related to the
Agreement for a period of three (3) years from the date of final payment to Consultant
under this Agreement.
22. WITHHOLDINGS
City may withhold payment to Consultant of any disputed sums until satisfaction of
the dispute with respect to such payment. Such withholding shall not be deemed to
constitute a failure to pay according to the terms of this Agreement. Consultant shall not
discontinue Work as a result of such withholding. Consultant shall have an immediate
right to appeal to the City Manager or designee with respect to such disputed sums.
Consultant shall be entitled to receive interest on any withheld sums at the rate of return
that City earned on its investments during the time period, from the date of withholding of
any amounts found to have been improperly withheld.
23. ERRORS AND OMISSIONS
In the event of errors or omissions that are due to the negligence or professional
inexperience of Consultant which result in expense to City greater than what would have
resulted if there were not errors or omissions in the Work accomplished by Consultant,
the additional design, construction and/or restoration expense shall be borne by
Consultant. Nothing in this Section is intended to limit City's rights under the law or any
other sections of this Agreement.
24. CITY'S RIGHT TO EMPLOY OTHER CONSULTANTS
City reserves the right to employ other Consultants in connection with the Project.
25. CONFLICTS OF INTEREST
25.1 Consultant or its employees may be subject to the provisions of the
California Political Reform Act of 1974 (the "Act") and/or Government Code §§ 1090 et
seq., which (1) require such persons to disclose any financial interest that may
foreseeably be materially affected by the Work performed under this Agreement, and (2)
prohibit such persons from making, or participating in making, decisions that will
foreseeably financially affect such interest.
25.2 If subject to the Act and/or Government Code §§ 1090 et seq., Consultant
shall conform to all requirements therein. Failure to do so constitutes a material breach
and is grounds for immediate termination of this Agreement by City. Consultant shall
indemnify and hold harmless City for any and all claims for damages resulting from
Consultant's violation of this Section.
26. NOTICES
26.1 All notices, demands, requests or approvals, including any change in
mailing address, to be given under the terms of this Agreement shall be given in writing,
and conclusively shall be deemed served when delivered personally, or on the third
WILLDAN ENGINEERING Page 9
9-12
business day after the deposit thereof in the United States mail, postage prepaid, first-
class mail, addressed as hereinafter provided.
26.2 All notices, demands, requests or approvals from Consultant to City shall
be addressed to City at:
Attn: Public Works Director
Public Works Department
City of Newport Beach
100 Civic Center Drive
PO Box 1768
Newport Beach, CA 92658
26.3 All notices, demands, requests or approvals from City to Consultant shall
be addressed to Consultant at:
Attn: Vanessa Munoz, PE, TE, PTOE
WILLDAN ENGINEERING
2401 East Katella Avenue, Suite 300
Anaheim, CA 92806
27. CLAIMS
Unless a shorter time is specified elsewhere in this Agreement, before making its
final request for payment under this Agreement, Consultant shall submit to City, in writing,
all claims for compensation under or arising out of this Agreement. Consultant's
acceptance of the final payment shall constitute a waiver of all claims for compensation
under or arising out of this Agreement except those previously made in writing and
identified by Consultant in writing as unsettled at the time of its final request for payment.
Consultant and City expressly agree that in addition to any claims filing requirements set
forth in the Agreement, Consultant shall be required to file any claim Consultant may have
against City in strict conformance with the Government Claims Act (Government Code
sections 900 et seq.).
28. TERMINATION
28.1 In the event that either party fails or refuses to perform any of the provisions
of this Agreement at the time and in the manner required, that party shall be deemed in
default in the performance of this Agreement. If such default is not cured within a period
of two (2) calendar days, or if more than two (2) calendar days are reasonably required
to cure the default and the defaulting party fails to give adequate assurance of due
performance within two (2) calendar days after receipt of written notice of default,
specifying the nature of such default and the steps necessary to cure such default, and
thereafter diligently take steps to cure the default, the non -defaulting party may terminate
the Agreement forthwith by giving to the defaulting party written notice thereof.
28.2 Notwithstanding the above provisions, City shall have the right, at its sole
and absolute discretion and without cause, of terminating this Agreement at any time by
WILLDAN ENGINEERING Page 10
9-13
giving no less than seven (7) calendar days' prior written notice to Consultant. In the
event of termination under this Section, City shall pay Consultant for Services
satisfactorily performed and costs incurred up to the effective date of termination for which
Consultant has not been previously paid. On the effective date of termination, Consultant
shall deliver to City all reports, Documents and other information developed or
accumulated in the performance of this Agreement, whether in draft or final form.
29. STANDARD PROVISIONS
29.1 Recitals. City and Consultant acknowledge that the above Recitals are true
and correct and are hereby incorporated by reference into this Agreement.
29.2 Compliance with all Laws. Consultant shall, at its own cost and expense,
comply with all statutes, ordinances, regulations and requirements of all governmental
entities, including federal, state, county or municipal, whether now in force or hereinafter
enacted. In addition, all Work prepared by Consultant shall conform to applicable City,
county, state and federal laws, rules, regulations and permit requirements and be subject
to approval of the Project Administrator and City.
29.3 Waiver. A waiver by either party of any breach, of any term, covenant or
condition contained herein shall not be deemed to be a waiver of any subsequent breach
of the same or any other term, covenant or condition contained herein, whether of the
same or a different character.
29.4 Integrated Contract. This Agreement represents the full and complete
understanding of every kind or nature whatsoever between the parties hereto, and all
preliminary negotiations and agreements of whatsoever kind or nature are merged herein.
No verbal agreement or implied covenant shall be held to vary the provisions herein.
29.5 Conflicts or Inconsistencies. In the event there are any conflicts or
inconsistencies between this Agreement and the Scope of Services or any other
attachments attached hereto, the terms of this Agreement shall govern.
29.6 Interpretation. The terms of this Agreement shall be construed in
accordance with the meaning of the language used and shall not be construed for or
against either party by reason of the authorship of the Agreement or any other rule of
construction which might otherwise apply.
29.7 Amendments. This Agreement may be modified or amended only by a
written document executed by both Consultant and City and approved as to form by the
City Attorney.
29.8 Severability. If any term or portion of this Agreement is held to be invalid,
illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining
provisions of this Agreement shall continue in full force and effect.
29.9 Controlling Law and Venue. The laws of the State of California shall govern
this Agreement and all matters relating to it and any action brought relating to this
WILLDAN ENGINEERING Page 11
9-14
Agreement shall be adjudicated in a court of competent jurisdiction in the County of
Orange, State of California.
29.10 Equal Opportunity Employment. Consultant represents that it is an equal
opportunity employer and it shall not discriminate against any subcontractor, employee
or applicant for employment because race, religious creed, color, national origin,
ancestry, physical handicap, medical condition, marital status, sex, sexual orientation,
age or any other impermissible basis under law.
29.11 No Attorneys' Fees. In the event of any dispute or legal action arising under
this Agreement, the prevailing party shall not be entitled to attorneys' fees.
29.12 Counterparts. This Agreement may be executed in two (2) or more
counterparts, each of which shall be deemed an original and all of which together shall
constitute one (1) and the same instrument.
[SIGNATURES ON NEXT PAGE]
WILLDAN ENGINEERING Page 12
9-15
IN WITNESS WHEREOF, the parties have caused this Agreement to be executed
on the dates written below.
APPROVED AS TO FORM:
CITY ATTORNEY'S OFFICE
Date:
By:
ran C. Harp
City Attorney pq1
ATTEST:
Date:
CITY OF NEWPORT BEACH,
a California municipal corporation
Date:
By:
Diane B. Dixon
Mayor
CONSULTANT:WILLDAN
ENGINEERING, a California corporation
Date:
Bv:
Leilani I. Brown Daniel Chow
City Clerk Chief Executive Officer
Date:
By:
Stacy McLaughlin
Chief Financial Officer
[END OF SIGNATURES]
Attachments: Exhibit A — Scope of Services
Exhibit B — Schedule of Billing Rates
Exhibit C — Insurance Requirements
WILLDAN ENGINEERING Page 13
9-16
EXHIBIT
SCOPE OF SERVICES
WILLDAN ENGINEERING Page A-1 9-17
EXHIBIT A
SCOPE OF SERVICES
ON-CALL PROFESSIONAL ENGINEERING SERVICES —TRAFFIC/ TRANSPORTATION ENGINEERING
The following is a list of professional traffic/transportation engineering services that may be
required:
• Provide full-sized plans, specifications, and estimates for traffic/transportation
engineering projects;
• Perform general traffic -related studies;
• Review/prepare traffic signal timing/coordination plans;
• Prepare conceptual design plans/exhibits;
• Provide cost estimating and value engineering services;
• Prepare/Review transportation impact studies;
• Prepare traffic calming (neighborhood) studies;
• Review/prepare traffic control plans;
• Provide bid support and preparation of record drawings; and
• Traffic signal operation observation, review and response (excluding physical traffic signal
maintenance and repair);
• Review City's traffic control devices and policies for State and Federal Compliance;
• Attend meetings as requested; and
• Other traffic/transportation engineering -related tasks, as requested by the City.
Consultant shall perform the on-call services described in the Scope of Work ("Services" or
"Work"). Upon written request from the Project Administrator as defined herein, Consultant shall
provide a Letter Proposal for Services requested by the City (hereinafter referred to as the "Letter
Proposal").
Consultant, its contractors, and subcontractors are prohibited from providing any Work or
Services under this Agreement that would require the payment of the prevailing wage rate
under any federal, state, or local laws.
EXHIBIT B
SCHEDULE OF BILLING RATES
WILLDAN ENGINEERING Page B-1 9-19
EXHIBIT B
FEE SCHEDULE
ON-CALL PROFESSIONAL ENGINEERING SERVICES -TRAFFIC /TRANSPORTATION ENGINEERING
W"WILLDAN
WR.LDAN ENGINEERING
Schedule of Hourly Rates
Program Manager I
Program Manager II
Prociram Manaqer III
Assistant Engineer I
Assistant Engineer II
Assistant Engineer III
Assistant Engineer IV
Associate Encineer I
Associate Engineer 11
Associate Engineer III
Senior Engineer I
Senior Engineer II
Senior Engineer III
Senior Engineer IV
Supervising Engineer
Traffic Engineer I
Traffic Engineer II
Crly Engineer I
City Engineer II
Deputy Director
Director
Principal Engineer
' Mr. Reggie Greene to be biked at a r—_ducea rate of S t 55,1',our =or as-needec staff augmentation servioFs
$174
$182
$208
$121
$137
$144
$149
$155
$161
$168
$171
$174
$177
$185
$140
$188
$203
$203
$213
$211
$216
$_35
MileageiT eld Vesicle usage wadbe charged at &* rate in accordance with the ctarent FTR m:�eeage re:rtburseinent rate. subject to negotiation.
Tre above scee-awe Is ror straight bme. Ove4nrrre Will ce charged at 1.5 times, and Sundays and hDOMys. 2C Mmes tre 5-'Idaid rates. SitsaF4lrcing, repriMictlon.
messenger services, and prfMng'e+il 7e t'IvbloM at oosf Fvus rr;een p-rcent i l5%k . A sub-mrsuttant manage�r?rt f?e b'S1f�-er ?ercerr, f 7 S%: 'A91 be added to Te ^JrecZ
=5t M at 5w)—co tswarl Wwces to provice lir Vie cost or adtNnls=on, cwsutlatiori, anc ccon:ilmtor.
41081
Technical Aide I
S67
Technical Aide II
S87
Technical Aisle III
$107
CAD Operator 1
$102
CAD Operator II
$125
CAD Operator III
$139
GIS Analyst 1
$145
GIS Analyst 11
$164
GIS Analyst III
$176
Environmental Analyst I
$121
Environmental Analyst II
$135
Environrrlental Analyst III
$144
Environmertal Specialist
$155
Desiqner I
$145
Designer II
$150
Senior Designer 1
$159
Senior Designer 11
$167
Design Manager •
317 C
Senior Desicn Manager
$176
Project Manager I
$15E
Project Manager 11
$177
Project Manager III
$187
Project Manager IV
5203
Principal Project Manager
$207
WR.LDAN ENGINEERING
Schedule of Hourly Rates
Program Manager I
Program Manager II
Prociram Manaqer III
Assistant Engineer I
Assistant Engineer II
Assistant Engineer III
Assistant Engineer IV
Associate Encineer I
Associate Engineer 11
Associate Engineer III
Senior Engineer I
Senior Engineer II
Senior Engineer III
Senior Engineer IV
Supervising Engineer
Traffic Engineer I
Traffic Engineer II
Crly Engineer I
City Engineer II
Deputy Director
Director
Principal Engineer
' Mr. Reggie Greene to be biked at a r—_ducea rate of S t 55,1',our =or as-needec staff augmentation servioFs
$174
$182
$208
$121
$137
$144
$149
$155
$161
$168
$171
$174
$177
$185
$140
$188
$203
$203
$213
$211
$216
$_35
MileageiT eld Vesicle usage wadbe charged at &* rate in accordance with the ctarent FTR m:�eeage re:rtburseinent rate. subject to negotiation.
Tre above scee-awe Is ror straight bme. Ove4nrrre Will ce charged at 1.5 times, and Sundays and hDOMys. 2C Mmes tre 5-'Idaid rates. SitsaF4lrcing, repriMictlon.
messenger services, and prfMng'e+il 7e t'IvbloM at oosf Fvus rr;een p-rcent i l5%k . A sub-mrsuttant manage�r?rt f?e b'S1f�-er ?ercerr, f 7 S%: 'A91 be added to Te ^JrecZ
=5t M at 5w)—co tswarl Wwces to provice lir Vie cost or adtNnls=on, cwsutlatiori, anc ccon:ilmtor.
41081
EXHIBIT C
INSURANCE REQUIREMENTS — PROFESSIONAL SERVICES
1. Provision of Insurance. Without limiting Consultant's indemnification of City, and
prior to commencement of Work, Consultant shall obtain, provide and maintain at
its own expense during the term of this Agreement, policies of insurance of the
type and amounts described below and in a form satisfactory to City. Consultant
agrees to provide insurance in accordance with requirements set forth here. If
Consultant uses existing coverage to comply and that coverage does not meet
these requirements, Consultant agrees to amend, supplement or endorse the
existing coverage.
2. Acceptable Insurers. All insurance policies shall be issued by an insurance
company currently authorized by the Insurance Commissioner to transact
business of insurance in the State of California, with an assigned policyholders'
Rating of A- (or higher) and Financial Size Category Class VII (or larger) in
accordance with the latest edition of Best's Key Rating Guide, unless otherwise
approved by the City's Risk Manager.
3. Coverage Requirements.
A. Workers' Compensation Insurance. Consultant shall maintain Workers'
Compensation Insurance, statutory limits, and Employer's Liability
Insurance with limits of at least one million dollars ($1,000,000) each
accident for bodily injury by accident and each employee for bodily injury by
disease in accordance with the laws of the State of California, Section 3700
of the Labor Code.
Consultant shall submit to City, along with the certificate of insurance, a
Waiver of Subrogation endorsement in favor of City, its City Council, boards
and commissions, officers, agents, volunteers, employees and any person
or entity owning or otherwise in legal control of the property upon which
Consultant performs the Project and/or Services contemplated by this
Agreement.
B. General Liability Insurance. Consultant shall maintain commercial general
liability insurance, and if necessary umbrella liability insurance, with
coverage at least as broad as provided by Insurance Services Office form
CG 00 01, in an amount not less than one million dollars ($1,000,000) per
occurrence, two million dollars ($2,000,000) general aggregate. The policy
shall cover liability arising from premises, operations, personal and
advertising injury, and liability assumed under an insured contract (including
the tort liability of another assumed in a business contract).
C. Automobile Liability Insurance. Consultant shall maintain automobile
insurance at least as broad as Insurance Services Office form CA 00 01
covering bodily injury and property damage for all activities of Consultant
arising out of or in connection with Work to be performed under this
WILLDAN ENGINEERING Page C-1 9-21
Agreement, including coverage for any owned, hired, non -owned or rented
vehicles, in an amount not less than one million dollars ($1,000,000)
combined single limit each accident.
D. Professional Liability (Errors & Omissions) Insurance. Consultant shall
maintain professional liability insurance that covers the Services to be
performed in connection with this Agreement, in the minimum amount of
one million dollars ($1,000,000) per claim and two million dollars
($2,000,000) in the aggregate. Any policy inception date, continuity date,
or retroactive date must be before the Effective Date of this Agreement and
Consultant agrees to maintain continuous coverage through a period no
less than three years after completion of the Services required by this
Agreement.
4. Other Insurance Requirements. The policies are to contain, or be endorsed to
contain, the following provisions:
A. Waiver of Subrogation. All insurance coverage maintained or procured
pursuant to this Agreement shall be endorsed to waive subrogation against
City, its City Council, boards and commissions, officers, agents, volunteers,
employees and any person or entity owning or otherwise in legal control of
the property upon which Consultant performs the Project and/or Services
contemplated by this Agreement or shall specifically allow Consultant or
others providing insurance evidence in compliance with these requirements
to waive their right of recovery prior to a loss. Consultant hereby waives its
own right of recovery against City, and shall require similar written express
waivers from each of its subconsultants.
B. Additional Insured Status. All liability policies including general liability,
excess liability, pollution liability, and automobile liability, if required, but not
including professional liability, shall provide or be endorsed to provide that
City, its City Council, boards and commissions, officers, agents, volunteers,
employees and any person or entity owning or otherwise in legal control of
the property upon which Consultant performs the Project and/or Services
contemplated by this Agreement shall be included as insureds under such
policies.
C. Primary and Non Contributory. All liability coverage shall apply on a primary
basis and shall not require contribution from any insurance or self-insurance
maintained by City.
D. Notice of Cancellation. All policies shall provide City with thirty (30)
calendar days' notice of cancellation (except for nonpayment for which ten
(10) calendar days' notice is required) or nonrenewal of coverage for each
required coverage.
5. Additional Aqreements Between the Parties. The parties hereby agree to the
following:
WILLDAN ENGINEERING Page C-2 9.22
A. Evidence of Insurance. Consultant shall provide certificates of insurance to
City as evidence of the insurance coverage required herein, along with a
waiver of subrogation endorsement for workers' compensation and other
endorsements as specified herein for each coverage. Insurance certificates
and endorsement must be approved by City's Risk Manager prior to
commencement of performance. Current certification of insurance shall be
kept on file with City at all times during the term of this Agreement. City
reserves the right to require complete, certified copies of all required
insurance policies, at any time.
B. City's Right to Revise Requirements. City reserves the right at any time
during the term of the Agreement to change the amounts and types of
insurance required by giving Consultant sixty (60) calendar days' advance
written notice of such change. If such change results in substantial
additional cost to Consultant, City and Consultant may renegotiate
Consultant's compensation.
C. Enforcement of Agreement Provisions. Consultant acknowledges and
agrees that any actual or alleged failure on the part of City to inform
Consultant of non-compliance with any requirement imposes no additional
obligations on City nor does it waive any rights hereunder.
D. Requirements not Limitinq. Requirements of specific coverage features or
limits contained in this Section are not intended as a limitation on coverage,
limits or other requirements, or a waiver of any coverage normally provided
by any insurance. Specific reference to a given coverage feature is for
purposes of clarification only as it pertains to a given issue and is not
intended by any party or insured to be all inclusive, or to the exclusion of
other coverage, or a waiver of any type. If the Consultant maintains higher
limits than the minimums shown above, the City requires and shall be
entitled to coverage for higher limits maintained by the Consultant. Any
available insurance proceeds in excess of the specified minimum limits of
insurance and coverage shall be available to the City.
E. Self-insured Retentions. Any self-insured retentions must be declared to
and approved by City. City reserves the right to require that self-insured
retentions be eliminated, lowered, or replaced by a deductible. Self-
insurance will not be considered to comply with these requirements unless
approved by City.
F. City Remedies for Non -Compliance. If Consultant or any subconsultant fails
to provide and maintain insurance as required herein, then City shall have
the right but not the obligation, to purchase such insurance, to terminate this
Agreement, or to suspend Consultant's right to proceed until proper
evidence of insurance is provided. Any amounts paid by City shall, at City's
sole option, be deducted from amounts payable to Consultant or reimbursed
by Consultant upon demand.
WILLDAN ENGINEERING Page C-3 9-23
G. Timely Notice of Claims. Consultant shall give City prompt and timely notice
of claims made or suits instituted that arise out of or result from Consultant's
performance under this Agreement, and that involve or may involve
coverage under any of the required liability policies. City assumes no
obligation or liability by such notice, but has the right (but not the duty) to
monitor the handling of any such claim or claims if they are likely to involve
City.
H. Consultant's Insurance. Consultant shall also procure and maintain, at its
own cost and expense, any additional kinds of insurance, which in its own
judgment may be necessary for its proper protection and prosecution of the
Work.
WILLDAN ENGINEERING Page C-4 9.24
ATTACHMENT B
ON-CALL PROFESSIONAL SERVICES AGREEMENT
WITH RK ENGINEERING GROUP, INC. FOR
TRAFFIC/TRANSPORTATION ENGINEERING
THIS ON-CALL PROFESSIONAL SERVICES AGREEMENT ("Agreement") is
made and entered into as of this 24th day of September, 2019 ("Effective Date"), by and
between the CITY OF NEWPORT BEACH, a California municipal corporation and charter
city ("City"), and RK ENGINEERING GROUP, INC., a California corporation
("Consultant'), whose address is 4000 Westerly Place, Suite 280, Newport Beach, CA
92660, and is made with reference to the following:
RECITALS
A. City is a municipal corporation duly organized and validly existing under the laws
of the State of California with the power to carry on its business as it is now being
conducted under the statutes of the State of California and the Charter of City.
B. City desires to engage Consultant to provide professional traffic and/or
transportation engineering services on an on-call/as-needed basis ("Project").
C. Consultant possesses the skill, experience, ability, background, certification and
knowledge to provide the professional services described in this Agreement.
D. City has solicited and received a proposal from Consultant, has reviewed the
previous experience and evaluated the expertise of Consultant, and desires to
retain Consultant to render professional services under the terms and conditions
set forth in this Agreement.
NOW, THEREFORE, it is mutually agreed by and between the undersigned parties
as follows:
1. TERM
The term of this Agreement shall commence on the Effective Date, and shall
terminate on September 23, 2024, unless terminated earlier as set forth herein.
2. SERVICES TO BE PERFORMED
2.1 Consultant shall perform the on-call services described in the Scope of
Services attached hereto as Exhibit A and incorporated herein by reference ("Services"
or "Work"). Upon written request from the Project Administrator as defined herein,
Consultant shall provide a letter proposal for Services requested by the City (hereinafter
referred to as the "Letter Proposal"). The Letter Proposal shall include the following:
2.1.1 A detailed description of the Services to be provided;
2.1.2 The position of each person to be assigned to perform the Services,
and the name of the individuals to be assigned, if available;
9-25
and
2.1.3 The estimated number of hours and cost to complete the Services;
2.1.4 The time needed to finish the specific project
2.2 No Services shall be provided until the Project Administrator has provided
written acceptance of the Letter Proposal. Once authorized to proceed, Consultant shall
diligently perform the duties in the approved Letter Proposal.
3. TIME OF PERFORMANCE
3.1 Time is of the essence in the performance of Services under this Agreement
and Consultant shall perform the Services in accordance with the schedule included in
Exhibit A and the Letter Proposal. In the absence of a specific schedule, the Services
shall be performed to completion in a diligent and timely manner. The failure by
Consultant to strictly adhere to the schedule set forth in Exhibit A and the Letter Proposal,
if any, or perform the Services in a diligent and timely manner may result in termination
of this Agreement by City.
3.2 Notwithstanding the foregoing, Consultant shall not be responsible for
delays due to causes beyond Consultant's reasonable control. However, in the case of
any such delay in the Services to be provided for the Project, each party hereby agrees
to provide notice within two (2) calendar days of the occurrence causing the delay to the
other party so that all delays can be addressed.
3.3 Consultant shall submit all requests for extensions of time for performance
in writing to the Project Administrator as defined herein not later than ten (10) calendar
days after the start of the condition that purportedly causes a delay. The Project
Administrator shall review all such requests and may grant reasonable time extensions
for unforeseeable delays that are beyond Consultant's control.
3.4 For all time periods not specifically set forth herein, Consultant shall
respond in the most expedient and appropriate manner under the circumstances, by
hand -delivery or mail.
4. COMPENSATION TO CONSULTANT
4.1 City shall pay Consultant for the Services on a time and expense not -to -
exceed basis in accordance with the provisions of this Section and the Letter Proposal
and the Schedule of Billing Rates attached hereto as Exhibit B and incorporated herein
by reference. Consultant's compensation for all Work performed in accordance with this
Agreement, including all reimbursable items and subconsultant fees, shall not exceed
Three Hundred Thousand Dollars and 001100 ($300,000.00), without prior written
authorization from City. Except as otherwise provided herein, no billing rate changes
shall be made during the term of this Agreement without the prior written approval of City.
4.2 Upon the first anniversary of the Effective Date and upon each anniversary
of the Effective Date thereafter, the billing rates set forth in Exhibit B ("Billing Rates") shall
RK ENGINEERING GROUP, INC. Page 2
9-26
be adjusted in proportion to changes in the Consumer Price Index, subject to the
maximum adjustment set forth below. Such adjustment shall be made by multiplying the
Billing Rates in Exhibit B by a fraction, the numerator of which is the value of the
Consumer Price Index for the calendar month three (3) months preceding the calendar
month for which such adjustment is to be made, and the denominator of which is the value
of the Consumer Price Index for the same calendar month immediately prior to Effective
Date. The Consumer Price Index to be used in such calculation is the "Consumer Price
Index, All Items, 1982-84=100 for All Urban Consumers (CPI -U)", for the Los Angeles -
Riverside -Orange County Metropolitan Area, published by the United States Department
of Labor, Bureau of Labor Statistics. If both an official index and one or more unofficial
indices are published, the official index shall be used. If said Consumer Price Index is no
longer published at the adjustment date, it shall be constructed by conversion tables
included in such new index. In no event, however, shall the amount payable under this
Agreement be reduced below the Billing Rates in effect immediately preceding such
adjustment. The maximum adjustment increase to the Billing Rates, for any year where
an adjustment is made pursuant to this Section, shall not exceed the Consumer Price
Index or 2.0% of the Billing Rates in effect immediately preceding such adjustment,
whichever is less.
4.3 Consultant shall submit monthly invoices to City describing the Work
performed the preceding month. Consultant's bills shall include the name of the person
who performed the Work, a brief description of the Services performed and/or the specific
task in the Scope of Services to which it relates, the date the Services were performed,
the number of hours spent on all Work billed on an hourly basis, and a description of any
reimbursable expenditures. City shall pay Consultant no later than thirty (30) calendar
days after approval of the monthly invoice by City staff.
4.4 City shall reimburse Consultant only for those costs or expenses specifically
identified in Exhibit B to this Agreement and the Letter Proposal or specifically approved
in writing in advance by City.
4.5 Consultant shall not receive any compensation for Extra Work performed
without the prior written authorization of City. As used herein, "Extra Work" means any
Work that is determined by City to be necessary for the proper completion of the Project,
but which is not included within the Scope of Services and which the parties did not
reasonably anticipate would be necessary at the execution of this Agreement.
Compensation for any authorized Extra Work shall be paid in accordance with the
Schedule of Billing Rates as set forth in Exhibit B and the Letter Proposal.
5. PROJECT MANAGER
5.1 Consultant shall designate a Project Manager, who shall coordinate all
phases of the Project. This Project Manager shall be available to City at all reasonable
times during the Agreement term. Consultant has designated Robert Khan, P.E., T.E. to
be its Project Manager. Consultant shall not remove or reassign the Project Manager or
any personnel listed in Exhibit A or assign any new or replacement personnel to the
RK ENGINEERING GROUP, INC. Page 3
9-27
Project without the prior written consent of City. City's approval shall not be unreasonably
withheld with respect to the removal or assignment of non -key personnel.
5.2 Consultant, at the sole discretion of City, shall remove from the Project any
of its personnel assigned to the performance of Services upon written request of City.
Consultant warrants that it will continuously furnish the necessary personnel to complete
the Project on a timely basis as contemplated by this Agreement.
5.3 If Consultant is performing inspection services for City, the Project Manager
and any other assigned staff shall be equipped with a cellular phone to communicate with
City staff. The Project Manager's cellular phone number shall be provided to City.
6. ADMINISTRATION
This Agreement will be administered by the Public Works Department. City's
Public Works Director or designee shall be the Project Administrator and shall have the
authority to act for City under this Agreement. The Project Administrator shall represent
City in all matters pertaining to the Services to be rendered pursuant to this Agreement.
7. CITY'S RESPONSIBILITIES
To assist Consultant in the execution of its responsibilities under this Agreement,
City agrees to provide access to and upon request of Consultant, one copy of all existing
relevant information on file at City. City will provide all such materials in a timely manner
so as not to cause delays in Consultant's Work schedule.
8. STANDARD OF CARE
8.1 All of the Services shall be performed by Consultant or under Consultant's
supervision. Consultant represents that it possesses the professional and technical
personnel required to perform the Services required by this Agreement, and that it will
perform all Services in a manner commensurate with community professional standards
and with the ordinary degree of skill and care that would be used by other reasonably
competent practitioners of the same discipline under similar circumstances. All Services
shall be performed by qualified and experienced personnel who are not employed by City.
By delivery of completed Work, Consultant certifies that the Work conforms to the
requirements of this Agreement, all applicable federal, state and local laws, and legally
recognized professional standards.
8.2 Consultant represents and warrants to City that it has, shall obtain, and shall
keep in full force and effect during the term hereof, at its sole cost and expense, all
licenses, permits, qualifications, insurance and approvals of whatsoever nature that is
legally required of Consultant to practice its profession. Consultant shall maintain a City
of Newport Beach business license during the term of this Agreement.
8.3 Consultant shall not be responsible for delay, nor shall Consultant be
responsible for damages or be in default or deemed to be in default by reason of strikes,
lockouts, accidents, acts of God, or the failure of City to furnish timely information or to
RK ENGINEERING GROUP, INC. Page 4
WWI
approve or disapprove Consultant's Work promptly, or delay or faulty performance by
City, contractors, or governmental agencies.
9. HOLD HARMLESS
9.1 To the fullest extent permitted by law, Consultant shall indemnify, defend
and hold harmless City, its City Council, boards and commissions, officers, agents,
volunteers, employees and any person or entity owning or otherwise in legal control of
the property upon which Consultant performs the Project and/or Services contemplated
by this (collectively, the "Indemnified Parties), from and against any and all claims
(including, without limitation, claims for bodily injury, death or damage to property),
demands, obligations, damages, actions, causes of action, suits, losses, judgments,
fines, penalties, liabilities, costs and expenses (including, without limitation, attorneys'
fees, disbursements and court costs) of every kind and nature whatsoever (individually,
a Claim; collectively, "Claims"), and which relate (directly or indirectly) to the negligence,
recklessness, or willful misconduct of the Consultant or its principals, officers, agents,
employees, vendors, suppliers, subconsultants, subcontractors, anyone employed
directly or indirectly by any of them or for whose acts they may be liable, or any or all of
them.
9.2 Notwithstanding the foregoing, nothing herein shall be construed to require
Consultant to indemnify the Indemnified Parties from any Claim arising from the sole
negligence, active negligence or willful misconduct of the Indemnified Parties. Nothing in
this indemnity shall be construed as authorizing any award of attorneys' fees in any action
on or to enforce the terms of this Agreement. This indemnity shall apply to all claims and
liability regardless of whether any insurance policies are applicable. The policy limits do
not act as a limitation upon the amount of indemnification to be provided by the
Consultant.
10. INDEPENDENT CONTRACTOR
10.1 It is understood that City retains Consultant on an independent contractor
basis and Consultant is not an agent or employee of City. The manner and means of
conducting the Work are under the control of Consultant, except to the extent they are
limited by statute, rule or regulation and the expressed terms of this Agreement. No civil
service status or other right of employment shall accrue to Consultant or its employees.
Nothing in this Agreement shall be deemed to constitute approval for Consultant or any
of Consultant's employees or agents, to be the agents or employees of City. Consultant
shall have the responsibility for and control over the means of performing the Work,
provided that Consultant is in compliance with the terms of this Agreement. Anything in
this Agreement that may appear to give City the right to direct Consultant as to the details
of the performance of the Work or to exercise a measure of control over Consultant shall
mean only that Consultant shall follow the desires of City with respect to the results of the
Services.
10.2 Consultant agrees and acknowledges that no individual performing
Services or Work pursuant to this Agreement shall: work full-time for more than six (6)
RK ENGINEERING GROUP, INC. Page 5
9-29
months, work regular part-time service of at least an average of twenty (20) hours per
week for one year or longer; work nine hundred sixty (960) hours in any fiscal year; or
already be a CalPERS member.
10.3 Consultant must submit to and pass a criminal background investigation by
providing a complete set of fingerprints to City prior to commencing or performing
Services or Work. Consultant is required to submit any fees for the criminal background
investigation according to the City's most current administrative fee schedule or
successor document. Fingerprints may be required to be updated every five (5) years.
11. COOPERATION
Consultant agrees to work closely and cooperate fully with City's designated
Project Administrator and any other agencies that may have jurisdiction or interest in the
Work to be performed. City agrees to cooperate with the Consultant on the Project.
12. CITY POLICY
Consultant shall discuss and review all matters relating to policy and Project
direction with City's Project Administrator in advance of all critical decision points in order
to ensure the Project proceeds in a manner consistent with City goals and policies.
13. PROGRESS
Consultant is responsible for keeping the Project Administrator informed on a
regular basis regarding the status and progress of the Project, activities performed and
planned, and any meetings that have been scheduled or are desired.
14. INSURANCE
Without limiting Consultant's indemnification of City, and prior to commencement
of Work, Consultant shall obtain, provide and maintain at its own expense during the term
of this Agreement or for other periods as specified in this Agreement, policies of insurance
of the type, amounts, terms and conditions described in the Insurance Requirements
attached hereto as Exhibit C, and incorporated herein by reference.
15. PROHIBITION AGAINST ASSIGNMENTS AND TRANSFERS
Except as specifically authorized under this Agreement, the Services to be
provided under this Agreement shall not be assigned, transferred contracted or
subcontracted out without the prior written approval of City. Any of the following shall be
construed as an assignment: The sale, assignment, transfer or other disposition of any
of the issued and outstanding capital stock of Consultant, or of the interest of any general
partner or joint venturer or syndicate member or cotenant if Consultant is a partnership or
joint -venture or syndicate or co -tenancy, which shall result in changing the control of
Consultant. Control means fifty percent (50%) or more of the voting power or twenty-five
percent (25%) or more of the assets of the corporation, partnership or joint -venture.
RK ENGINEERING GROUP, INC. Page 6
9-30
16. SUBCONTRACTING
The subcontractors authorized by City, if any, to perform Work on this Project are
identified in Exhibit A and the Letter Proposal. Consultant shall be fully responsible to
City for all acts and omissions of any subcontractor. Nothing in this Agreement shall
create any contractual relationship between City and any subcontractor nor shall it create
any obligation on the part of City to pay or to see to the payment of any monies due to
any such subcontractor other than as otherwise required by law. City is an intended
beneficiary of any Work performed by the subcontractor for purposes of establishing a
duty of care between the subcontractor and City. Except as specifically authorized herein,
the Services to be provided under this Agreement shall not be otherwise assigned,
transferred, contracted or subcontracted out without the prior written approval of City.
17. OWNERSHIP OF DOCUMENTS
17.1 Each and every report, draft, map, record, plan, document and other writing
produced, including but not limited to, websites, blogs, social media accounts and
applications (hereinafter "Documents"), prepared or caused to be prepared by Consultant,
its officers, employees, agents and subcontractors, in the course of implementing this
Agreement, shall become the exclusive property of City, and City shall have the sole right
to use such materials in its discretion without further compensation to Consultant or any
other party. Additionally, all material posted in cyberspace by Consultant, its officers,
employees, agents and subcontractors, in the course of implementing this Agreement,
shall become the exclusive property of City, and City shall have the sole right to use such
materials in its discretion without further compensation to Consultant or any other party.
Consultant shall, at Consultant's expense, provide such Documents, including all logins
and password information to City upon prior written request.
17.2 Documents, including drawings and specifications, prepared by Consultant
pursuant to this Agreement are not intended or represented to be suitable for reuse by
City or others on any other project. Any use of completed Documents for other projects
and any use of incomplete Documents without specific written authorization from
Consultant will be at City's sole risk and without liability to Consultant. Further, any and
all liability arising out of changes made to Consultant's deliverables under this Agreement
by City or persons other than Consultant is waived against Consultant, and City assumes
full responsibility for such changes unless City has given Consultant prior notice and has
received from Consultant written consent for such changes.
17.3 CADD data delivered to City shall include the professional stamp of the
engineer or architect in charge of or responsible for the Work. City agrees that Consultant
shall not be liable for claims, liabilities or losses arising out of, or connected with (a) the
modification or misuse by City, or anyone authorized by City, of CADD data; (b) the
decline of accuracy or readability of CADD data due to inappropriate storage conditions
or duration; or (c) any use by City, or anyone authorized by City, of CADD data for
additions to this Project, for the completion of this Project by others, or for any other
Project, excepting only such use as is authorized, in writing, by Consultant. By
acceptance of CADD data, City agrees to indemnify Consultant for damages and liability
RK ENGINEERING GROUP, INC. Page 7
9-31
resulting from the modification or misuse of such CADD data. All original drawings shall
be submitted to City in the version of AutoCAD used by the City in .dwg file format, on a
CD, and should comply with the City's digital submission requirements for improvement
plans available from the City's Public Works Department. The City will provide Consultant
with City title sheets as AutoCAD file(s) in .dwg file format. All written documents shall
be transmitted to City in formats compatible with Microsoft Office and/or viewable with
Adobe Acrobat.
17.4 All improvement and/or construction plans shall be prepared with indelible
waterproof ink or electrostatically plotted on standard twenty-four inch (24") by thirty-six
inch (36") Mylar with a minimum thickness of three (3) mils. Consultant shall provide to
City 'As -Built' drawings and a copy of digital Computer Aided Design and Drafting
("CADD") and Tagged Image File Format (.tiff) files of all final sheets within ninety (90)
days after finalization of the Project. For more detailed requirements, a copy of the City
of Newport Beach Standard Design Requirements is available from the City's Public
Works Department.
18. OPINION OF COST
Any opinion of the construction cost prepared by Consultant represents the
Consultant's judgment as a design professional and is supplied for the general guidance
of City. Since Consultant has no control over the cost of labor and material, or over
competitive bidding or market conditions, Consultant does not guarantee the accuracy of
such opinions as compared to Consultant or contractor bids or actual cost to City.
19. CONFIDENTIALITY
All Documents, including drafts, preliminary drawings or plans, notes and
communications that result from the Services in this Agreement, shall be kept confidential
unless City expressly authorizes in writing the release of information.
20. INTELLECTUAL PROPERTY INDEMNITY
Consultant shall defend and indemnify City, its agents, officers, representatives
and employees against any and all liability, including costs, for infringement or alleged
infringement of any United States' letters patent, trademark, or copyright, including costs,
contained in Consultant's Documents provided under this Agreement.
21. RECORDS
Consultant shall keep records and invoices in connection with the Services to be
performed under this Agreement. Consultant shall maintain complete and accurate
records with respect to the costs incurred under this Agreement and any Services,
expenditures and disbursements charged to City, for a minimum period of three (3) years,
or for any longer period required by law, from the date of final payment to Consultant
under this Agreement. All such records and invoices shall be clearly identifiable.
Consultant shall allow a representative of City to examine, audit and make transcripts or
copies of such records and invoices during regular business hours. Consultant shall allow
RK ENGINEERING GROUP, INC. Page 8
9-32
inspection of all Work, data, Documents, proceedings and activities related to the
Agreement for a period of three (3) years from the date of final payment to Consultant
under this Agreement.
22. WITHHOLDINGS
City may withhold payment to Consultant of any disputed sums until satisfaction of
the dispute with respect to such payment. Such withholding shall not be deemed to
constitute a failure to pay according to the terms of this Agreement. Consultant shall not
discontinue Work as a result of such withholding. Consultant shall have an immediate
right to appeal to the City Manager or designee with respect to such disputed sums.
Consultant shall be entitled to receive interest on any withheld sums at the rate of return
that City earned on its investments during the time period, from the date of withholding of
any amounts found to have been improperly withheld.
23. ERRORS AND OMISSIONS
In the event of errors or omissions that are due to the negligence or professional
inexperience of Consultant which result in expense to City greater than what would have
resulted if there were not errors or omissions in the Work accomplished by Consultant,
the additional design, construction and/or restoration expense shall be borne by
Consultant. Nothing in this Section is intended to limit City's rights under the law or any
other sections of this Agreement.
24. CITY'S RIGHT TO EMPLOY OTHER CONSULTANTS
City reserves the right to employ other Consultants in connection with the Project.
25. CONFLICTS OF INTEREST
25.1 Consultant or its employees may be subject to the provisions of the
California Political Reform Act of 1974 (the "Act") and/or Government Code §§ 1090 et
seq., which (1) require such persons to disclose any financial interest that may
foreseeably be materially affected by the Work performed under this Agreement, and (2)
prohibit such persons from making, or participating in making, decisions that will
foreseeably financially affect such interest.
25.2 If subject to the Act and/or Government Code §§ 1090 et seq., Consultant
shall conform to all requirements therein. Failure to do so constitutes a material breach
and is grounds for immediate termination of this Agreement by City. Consultant shall
indemnify and hold harmless City for any and all claims for damages resulting from
Consultant's violation of this Section.
26. NOTICES
26.1 All notices, demands, requests or approvals, including any change in
mailing address, to be given under the terms of this Agreement shall be given in writing,
and conclusively shall be deemed served when delivered personally, or on the third
RK ENGINEERING GROUP, INC. Page 9
9-33
business day after the deposit thereof in the United States mail, postage prepaid, first-
class mail, addressed as hereinafter provided.
26.2 All notices, demands, requests or approvals from Consultant to City shall
be addressed to City at:
Attn: Public Works Director
Public Works Department
City of Newport Beach
100 Civic Center Drive
PO Box 1768
Newport Beach, CA 92658
26.3 All notices, demands, requests or approvals from City to Consultant shall
be addressed to Consultant at-
Attn: Robert Kahn
RK ENGINEERING GROUP, INC.
4000 Westerly Place, Suite 280
Newport Beach 92660
27. CLAIMS
Unless a shorter time is specified elsewhere in this Agreement, before making its
final request for payment under this Agreement, Consultant shall submit to City, in writing,
all claims for compensation under or arising out of this Agreement. Consultant's
acceptance of the final payment shall constitute a waiver of all claims for compensation
under or arising out of this Agreement except those previously made in writing and
identified by Consultant in writing as unsettled at the time of its final request for payment.
Consultant and City expressly agree that in addition to any claims filing requirements set
forth in the Agreement, Consultant shall be required to file any claim Consultant may have
against City in strict conformance with the Government Claims Act (Government Code
sections 900 et seq.).
28. TERMINATION
28.1 In the event that either party fails or refuses to perform any of the provisions
of this Agreement at the time and in the manner required, that party shall be deemed in
default in the performance of this Agreement. If such default is not cured within a period
of two (2) calendar days, or if more than two (2) calendar days are reasonably required
to cure the default and the defaulting party fails to give adequate assurance of due
performance within two (2) calendar days after receipt of written notice of default,
specifying the nature of such default and the steps necessary to cure such default, and
thereafter diligently take steps to cure the default, the non -defaulting party may terminate
the Agreement forthwith by giving to the defaulting party written notice thereof.
28.2 Notwithstanding the above provisions, City shall have the right, at its sole
and absolute discretion and without cause, of terminating this Agreement at any time by
RK ENGINEERING GROUP, INC. Page 10
9-34
giving no less than seven (7) calendar days' prior written notice to Consultant. In the
event of termination under this Section, City shall pay Consultant for Services
satisfactorily performed and costs incurred up to the effective date of termination for which
Consultant has not been previously paid. On the effective date of termination, Consultant
shall deliver to City all reports, Documents and other information developed or
accumulated in the performance of this Agreement, whether in draft or final form.
29. STANDARD PROVISIONS
29.1 Recitals. City and Consultant acknowledge that the above Recitals are true
and correct and are hereby incorporated by reference into this Agreement.
29.2 Compliance with all Laws. Consultant shall, at its own cost and expense,
comply with all statutes, ordinances, regulations and requirements of all governmental
entities, including federal, state, county or municipal, whether now in force or hereinafter
enacted. In addition, all Work prepared by Consultant shall conform to applicable City,
county, state and federal laws, rules, regulations and permit requirements and be subject
to approval of the Project Administrator and City.
29.3 Waiver. A waiver by either party of any breach, of any term, covenant or
condition contained herein shall not be deemed to be a waiver of any subsequent breach
of the same or any other term, covenant or condition contained herein, whether of the
same or a different character.
29.4 Integrated Contract. This Agreement represents the full and complete
understanding of every kind or nature whatsoever between the parties hereto, and all
preliminary negotiations and agreements of whatsoever kind or nature are merged herein.
No verbal agreement or implied covenant shall be held to vary the provisions herein.
29.5 Conflicts or Inconsistencies. In the event there are any conflicts or
inconsistencies between this Agreement and the Scope of Services or any other
attachments attached hereto, the terms of this Agreement shall govern.
29.6 Interpretation. The terms of this Agreement shall be construed in
accordance with the meaning of the language used and shall not be construed for or
against either party by reason of the authorship of the Agreement or any other rule of
construction which might otherwise apply.
29.7 Amendments. This Agreement may be modified or amended only by a
written document executed by both Consultant and City and approved as to form by the
City Attorney.
29.8 Severability. If any term or portion of this Agreement is held to be invalid,
illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining
provisions of this Agreement shall continue in full force and effect.
29.9 Controlling Law and Venue. The laws of the State of California shall govern
this Agreement and all matters relating to it and any action brought relating to this
RK ENGINEERING GROUP, INC. Page 11
9-35
Agreement shall be adjudicated in a court of competent jurisdiction in the County of
Orange, State of California.
29.10 Equal Opportunity Employment. Consultant represents that it is an equal
opportunity employer and it shall not discriminate against any subcontractor, employee
or applicant for employment because race, religious creed, color, national origin,
ancestry, physical handicap, medical condition, marital status, sex, sexual orientation,
age or any other impermissible basis under law.
29.11 No Attorneys' Fees. In the event of any dispute or legal action arising under
this Agreement, the prevailing party shall not be entitled to attorneys' fees.
29.12 Counterparts. This Agreement may be executed in two (2) or more
counterparts, each of which shall be deemed an original and all of which together shall
constitute one (1) and the same instrument.
[SIGNATURES ON NEXT PAGE]
RK ENGINEERING GROUP, INC. Page 12
9-36
IN WITNESS WHEREOF, the parties have caused this Agreement to be executed
on the dates written below.
APPROVED AS TO FORM:
CITY ATTORNEY'S OFFICE
Date: q /[ l M
By:
aifon C. Harf�u
City Attorney
ATTEST:
Date:
Leilani I. Brown
City Clerk
CITY OF NEWPORT BEACH,
a California municipal corporation
Date:
By:
Diane B. Dixon
Mayor
CONSULTANT: RK ENGINEERING
GROUP, INC., a California corporation
Date:
By:
Robert Khan
Chief Executive Officer/
Chief Financial Officer
[END OF SIGNATURES]
Attachments: Exhibit A — Scope of Services
Exhibit B — Schedule of Billing Rates
Exhibit C — Insurance Requirements
RK ENGINEERING GROUP, INC. Page 13
9-37
EXHIBIT A
SCOPE OF SERVICES
RK ENGINEERING GROUP, INC. Page A-1 9.38
EXHIBIT A
SCOPE OF SERVICES
ON-CALL PROFESSIONAL ENGINEERING SERVICES—TRAFFIC/TRANSPORTATION ENGINEERING
The following is a list of professional traffic/transportation engineering services that may be
required:
• Provide full-sized plans, specifications, and estimates for traffic/transportation
engineering projects;
• Perform general traffic -related studies;
• Review/prepare traffic signal timing/coordination plans;
• Prepare conceptual design plans/exhibits;
• Provide cost estimating and value engineering services;
• Prepare/Review transportation impact studies;
• Prepare traffic calming (neighborhood) studies;
• Review/prepare traffic control plans;
• Provide bid support and preparation of record drawings; and
• Traffic signal operation observation, review and response (excluding physical traffic signal
maintenance and repair);
• Review City's traffic control devices and policies for State and Federal Compliance;
• Attend meetings as requested; and
• Other traffic/transportation engineering -related tasks, as requested by the City.
Consultant shall perform the on-call services described in the Scope of Work ("Services" or
"Work"). Upon written request from the Project Administrator as defined herein, Consultant shall
provide a Letter Proposal for Services requested by the City (hereinafter referred to as the "Letter
Proposal").
Consultant, its contractors, and subcontractors are prohibited from providing any Work or
Services under this Agreement that would require the payment of the prevailing wage rate
under any federal, state, or local laws.
9-39
EXHIBIT B
SCHEDULE OF BILLING RATES
RK ENGINEERING GROUP, INC. Page B-1 9-40
EXHIBIT B
FEE SCHEDULE
ON-CALL PROFESSIONAL ENGINEERING SERVICES —TRAFFIC/TRANSPORTATION ENGINEERING
engineering
group, inc.
Billing Rates for RK ENGINEERING GROUP, INC.
Position Houdy Rate
Principal 5180.00
President 5165.00
Associate Principal 5165-00
Senior Associate Engineer/Planner/Designer 5155.00
Principal Engineer/Planner/Designer 5145.00
Associate Er,&.,eer/Planner/Designer 5130.00
Senior Erglreeri'Planner/Designer 5120-00
Engineer/Planner/iDesig.r:er III S1 15.00
Engineer/Planner/Designer II 5105.00
Engineer/Planner/Designer 1 5100.00
Assistant Engineer/Planner/Designer S 90.00
Transportation Analys- 5 70.00
Senior Engineering Technician S 85-00
Engineenrg Technician III S 75.00
Enaireerira Technician II S 65.00
Engineering Technician I S 55.00
E ngineering Aide S 50.00
Office Manager
S
70.00
Executive Assistant
S
70.00
Administrative Assistant
S
55.00
Administrative Aide
S
45.00
Clerical Aide
S
40.00
Gertera l
(t) Reimbursable directtusts, such as reprvductio . supp1 —, Sel+,+ry service, telephone. thavd and trafk Caunt%will
be biller dt cast plus ten ? =G) percent.
?2) f -curly r.rtes apply to work tire, travel tame and time spent at public iheamigsarid meeGnys. :as a•,-ertimL1vrark
and expert vsitne5s %•nark, the dbove rates may be Creased 50 percent.
9-41
EXHIBIT C
INSURANCE REQUIREMENTS — PROFESSIONAL SERVICES
1. Provision of Insurance. Without limiting Consultant's indemnification of City, and
prior to commencement of Work, Consultant shall obtain, provide and maintain at
its own expense during the term of this Agreement, policies of insurance of the
type and amounts described below and in a form satisfactory to City. Consultant
agrees to provide insurance in accordance with requirements set forth here. If
Consultant uses existing coverage to comply and that coverage does not meet
these requirements, Consultant agrees to amend, supplement or endorse the
existing coverage.
2. Acceptable Insurers. All insurance policies shall be issued by an insurance
company currently authorized by the Insurance Commissioner to transact
business of insurance in the State of California, with an assigned policyholders'
Rating of A- (or higher) and Financial Size Category Class VII (or larger) in
accordance with the latest edition of Best's Key Rating Guide, unless otherwise
approved by the City's Risk Manager.
3. Coverage Requirements.
A. Workers' Compensation Insurance. Consultant shall maintain Workers'
Compensation Insurance, statutory limits, and Employer's Liability
Insurance with limits of at least one million dollars ($1,000,000) each
accident for bodily injury by accident and each employee for bodily injury by
disease in accordance with the laws of the State of California, Section 3700
of the Labor Code.
Consultant shall submit to City, along with the certificate of insurance, a
Waiver of Subrogation endorsement in favor of City, its City Council, boards
and commissions, officers, agents, volunteers, employees and any person
or entity owning or otherwise in legal control of the property upon which
Consultant performs the Project and/or Services contemplated by this
Agreement.
B. General Liability Insurance. Consultant shall maintain commercial general
liability insurance, and if necessary umbrella liability insurance, with
coverage at least as broad as provided by Insurance Services Office form
CG 00 01, in an amount not less than one million dollars ($1,000,000) per
occurrence, two million dollars ($2,000,000) general aggregate. The policy
shall cover liability arising from premises, operations, personal and
advertising injury, and liability assumed under an insured contract (including
the tort liability of another assumed in a business contract).
C. Automobile Liability Insurance. Consultant shall maintain automobile
insurance at least as broad as Insurance Services Office form CA 00 01
covering bodily injury and property damage for all activities of Consultant
arising out of or in connection with Work to be performed under this
RK ENGINEERING GROUP, INC. Page C-1 9.42
Agreement, including coverage for any owned, hired, non -owned or rented
vehicles, in an amount not less than one million dollars ($1,000,000)
combined single limit each accident.
D. Professional Liability (Errors & Omissions) Insurance. Consultant shall
maintain professional liability insurance that covers the Services to be
performed in connection with this Agreement, in the minimum amount of
one million dollars ($1,000,000) per claim and two million dollars
($2,000,000) in the aggregate. Any policy inception date, continuity date,
or retroactive date must be before the Effective Date of this Agreement and
Consultant agrees to maintain continuous coverage through a period no
less than three years after completion of the Services required by this
Agreement.
4. Other Insurance Requirements. The policies are to contain, or be endorsed to
contain, the following provisions:
A. Waiver of Subrogation. All insurance coverage maintained or procured
pursuant to this Agreement shall be endorsed to waive subrogation against
City, its City Council, boards and commissions, officers, agents, volunteers,
employees and any person or entity owning or otherwise in legal control of
the property upon which Consultant performs the Project and/or Services
contemplated by this Agreement or shall specifically allow Consultant or
others providing insurance evidence in compliance with these requirements
to waive their right of recovery prior to a loss. Consultant hereby waives its
own right of recovery against City, and shall require similar written express
waivers from each of its subconsultants.
B. Additional Insured Status. All liability policies including general liability,
excess liability, pollution liability, and automobile liability, if required, but not
including professional liability, shall provide or be endorsed to provide that
City, its City Council, boards and commissions, officers, agents, volunteers,
employees and any person or entity owning or otherwise in legal control of
the property upon which Consultant performs the Project and/or Services
contemplated by this Agreement shall be included as insureds under such
policies.
C. Primary and Non Contributory. All liability coverage shall apply on a primary
basis and shall not require contribution from any insurance or self-insurance
maintained by City.
D. Notice of Cancellation. All policies shall provide City with thirty (30)
calendar days' notice of cancellation (except for nonpayment for which ten
(10) calendar days' notice is required) or nonrenewal of coverage for each
required coverage.
5. Additional Agreements Between the Parties. The parties hereby agree to the
following:
RK ENGINEERING GROUP, INC. Page C-2 9-43
A. Evidence of Insurance. Consultant shall provide certificates of insurance to
City as evidence of the insurance coverage required herein, along with a
waiver of subrogation endorsement for workers' compensation and other
endorsements as specified herein for each coverage. Insurance certificates
and endorsement must be approved by City's Risk Manager prior to
commencement of performance. Current certification of insurance shall be
kept on file with City at all times during the term of this Agreement. City
reserves the right to require complete, certified copies of all required
insurance policies, at any time.
B. City's Right to Revise Requirements. City reserves the right at any time
during the term of the Agreement to change the amounts and types of
insurance required by giving Consultant sixty (60) calendar days' advance
written notice of such change. If such change results in substantial
additional cost to Consultant, City and Consultant may renegotiate
Consultant's compensation.
C. Enforcement of Agreement Provisions. Consultant acknowledges and
agrees that any actual or alleged failure on the part of City to inform
Consultant of non-compliance with any requirement imposes no additional
obligations on City nor does it waive any rights hereunder.
D. Requirements not Limiting. Requirements of specific coverage features or
limits contained in this Section are not intended as a limitation on coverage,
limits or other requirements, or a waiver of any coverage normally provided
by any insurance. Specific reference to a given coverage feature is for
purposes of clarification only as it pertains to a given issue and is not
intended by any party or insured to be all inclusive, or to the exclusion of
other coverage, or a waiver of any type. If the Consultant maintains higher
limits than the minimums shown above, the City requires and shall be
entitled to coverage for higher limits maintained by the Consultant. Any
available insurance proceeds in excess of the specified minimum limits of
insurance and coverage shall be available to the City.
E. Self-insured Retentions. Any self-insured retentions must be declared to
and approved by City. City reserves the right to require that self-insured
retentions be eliminated, lowered, or replaced by a deductible. Self-
insurance will not be considered to comply with these requirements unless
approved by City.
F. City Remedies for Non -Compliance. If Consultant or any subconsultant fails
to provide and maintain insurance as required herein, then City shall have
the right but not the obligation, to purchase such insurance, to terminate this
Agreement, or to suspend Consultant's right to proceed until proper
evidence of insurance is provided. Any amounts paid by City shall, at City's
sole option, be deducted from amounts payable to Consultant or reimbursed
by Consultant upon demand.
RK ENGINEERING GROUP, INC. Page C-3 9-44
G. Timely Notice of Claims. Consultant shall give City prompt and timely notice
of claims made or suits instituted that arise out of or result from Consultant's
performance under this Agreement, and that involve or may involve
coverage under any of the required liability policies. City assumes no
obligation or liability by such notice, but has the right (but not the duty) to
monitor the handling of any such claim or claims if they are likely to involve
City.
H. Consultant's Insurance. Consultant shall also procure and maintain, at its
own cost and expense, any additional kinds of insurance, which in its own
judgment may be necessary for its proper protection and prosecution of the
Work.
RK ENGINEERING GROUP, INC. Page C-4 9-45
ATTACHMENT C
ON-CALL PROFESSIONAL SERVICES AGREEMENT
WITH GANDDINI GROUP, INC. FOR
TRAFFIC/TRANSPORTATION ENGINEERING
THIS ON-CALL PROFESSIONAL SERVICES AGREEMENT ("Agreement") is
made and entered into as of this 24th day of September, 2019 ("Effective Date"), by and
between the CITY OF NEWPORT BEACH, a California municipal corporation and charter
city ("City"), and GANDDINI GROUP, INC., a California corporation ("Consultant"), whose
address is 550 Parkcenter Drive, Suite 202, Santa Ana, CA 92705, and is made with
reference to the following:
RECITALS
A. City is a municipal corporation duly organized and validly existing under the laws
of the State of California with the power to carry on its business as it is now being
conducted under the statutes of the State of California and the Charter of City.
B. City desires to engage Consultant to provide professional traffic and/or
transportation engineering services on an on-call/as-needed basis ("Project").
C. Consultant possesses the skill, experience, ability, background, certification and
knowledge to provide the professional services described in this Agreement.
D. City has solicited and received a proposal from Consultant, has reviewed the
previous experience and evaluated the expertise of Consultant, and desires to
retain Consultant to render professional services under the terms and conditions
set forth in this Agreement.
NOW, THEREFORE, it is mutually agreed by and between the undersigned parties
as follows:
1. TERM
The term of this Agreement shall commence on the Effective Date, and shall
terminate on September 23, 2024, unless terminated earlier as set forth herein.
2. SERVICES TO BE PERFORMED
2.1 Consultant shall perform the on-call services described in the Scope of
Services attached hereto as Exhibit A and incorporated herein by reference ("Services"
or "Work"). Upon written request from the Project Administrator as defined herein,
Consultant shall provide a letter proposal for Services requested by the City (hereinafter
referred to as the "Letter Proposal"). The Letter Proposal shall include the following:
2.1.1 A detailed description of the Services to be provided;
2.1.2 The position of each person to be assigned to perform the Services,
and the name of the individuals to be assigned, if available;
Z ,,
and
2.1.3 The estimated number of hours and cost to complete the Services;
2.1.4 The time needed to finish the specific project.
2.2 No Services shall be provided until the Project Administrator has provided
written acceptance of the Letter Proposal. Once authorized to proceed, Consultant shall
diligently perform the duties in the approved Letter Proposal.
3. TIME OF PERFORMANCE
3.1 Time is of the essence in the performance of Services under this Agreement
and Consultant shall perform the Services in accordance with the schedule included in
Exhibit A and the Letter Proposal. In the absence of a specific schedule, the Services
shall be performed to completion in a diligent and timely manner. The failure by
Consultant to strictly adhere to the schedule set forth in Exhibit A and the Letter Proposal,
if any, or perform the Services in a diligent and timely manner may result in termination
of this Agreement by City.
3.2 Notwithstanding the foregoing, Consultant shall not be responsible for
delays due to causes beyond Consultant's reasonable control. However, in the case of
any such delay in the Services to be provided for the Project, each party hereby agrees
to provide notice within two (2) calendar days of the occurrence causing the delay to the
other party so that all delays can be addressed.
3.3 Consultant shall submit all requests for extensions of time for performance
in writing to the Project Administrator as defined herein not later than ten (10) calendar
days after the start of the condition that purportedly causes a delay. The Project
Administrator shall review all such requests and may grant reasonable time extensions
for unforeseeable delays that are beyond Consultant's control.
3.4 For all time periods not specifically set forth herein, Consultant shall
respond in the most expedient and appropriate manner under the circumstances, by
hand -delivery or mail.
4. COMPENSATION TO CONSULTANT
4.1 City shall pay Consultant for the Services on a time and expense not -to -
exceed basis in accordance with the provisions of this Section and the Letter Proposal
and the Schedule of Billing Rates attached hereto as Exhibit B and incorporated herein
by reference. Consultant's compensation for all Work performed in accordance with this
Agreement, including all reimbursable items and subconsultant fees, shall not exceed
Three Hundred Thousand Dollars and 001100 ($300,000.00), without prior written
authorization from City. Except as otherwise provided herein, no billing rate changes shall
be made during the term of this Agreement without the prior written approval of City.
4.2 Upon the first anniversary of the Effective Date and upon each anniversary
of the Effective Date thereafter, the billing rates set forth in Exhibit B ("Billing Rates") shall
GANDDINI GROUP, INC. Page 2
9-47
be adjusted in proportion to changes in the Consumer Price Index, subject to the
maximum adjustment set forth below. Such adjustment shall be made by multiplying the
Billing Rates in Exhibit B by a fraction, the numerator of which is the value of the
Consumer Price Index for the calendar month three (3) months preceding the calendar
month for which such adjustment is to be made, and the denominator of which is the value
of the Consumer Price Index for the same calendar month immediately prior to Effective
Date. The Consumer Price Index to be used in such calculation is the "Consumer Price
Index, All Items, 1982-84=100 for All Urban Consumers (CPI -U)", for the Los Angeles -
Riverside -Orange County Metropolitan Area, published by the United States Department
of Labor, Bureau of Labor Statistics. If both an official index and one or more unofficial
indices are published, the official index shall be used. If said Consumer Price Index is no
longer published at the adjustment date, it shall be constructed by conversion tables
included in such new index. In no event, however, shall the amount payable under this
Agreement be reduced below the Billing Rates in effect immediately preceding such
adjustment. The maximum adjustment increase to the Billing Rates, for any year where
an adjustment is made pursuant to this Section, shall not exceed the Consumer Price
Index or 2.0% of the Billing Rates in effect immediately preceding such adjustment,
whichever is less.
4.3 Consultant shall submit monthly invoices to City describing the Work
performed the preceding month. Consultant's bills shall include the name of the person
who performed the Work, a brief description of the Services performed and/or the specific
task in the Scope of Services to which it relates, the date the Services were performed,
the number of hours spent on all Work billed on an hourly basis, and a description of any
reimbursable expenditures. City shall pay Consultant no later than thirty (30) calendar
days after approval of the monthly invoice by City staff.
4.4 City shall reimburse Consultant only for those costs or expenses specifically
identified in Exhibit B to this Agreement and the Letter Proposal or specifically approved
in writing in advance by City.
4.5 Consultant shall not receive any compensation for Extra Work performed
without the prior written authorization of City. As used herein, "Extra Work" means any
Work that is determined by City to be necessary for the proper completion of the Project,
but which is not included within the Scope of Services and which the parties did not
reasonably anticipate would be necessary at the execution of this Agreement.
Compensation for any authorized Extra Work shall be paid in accordance with the
Schedule of Billing Rates as set forth in Exhibit B and the Letter Proposal.
5. PROJECT MANAGER
5.1 Consultant shall designate a Project Manager, who shall coordinate all
phases of the Project. This Project Manager shall be available to City at all reasonable
times during the Agreement term. Consultant has designated Giancarlo Jose Ganddini
to be its Project Manager. Consultant shall not remove or reassign the Project Manager
or any personnel listed in Exhibit A or assign any new or replacement personnel to the
GANDDINI GROUP, INC. Page 3
9-48
Project without the prior written consent of City. City's approval shall not be unreasonably
withheld with respect to the removal or assignment of non -key personnel.
5.2 Consultant, at the sole discretion of City, shall remove from the Project any
of its personnel assigned to the performance of Services upon written request of City.
Consultant warrants that it will continuously furnish the necessary personnel to complete
the Project on a timely basis as contemplated by this Agreement.
5.3 If Consultant is performing inspection services for City, the Project Manager
and any other assigned staff shall be equipped with a cellular phone to communicate with
City staff. The Project Manager's cellular phone number shall be provided to City.
6. ADMINISTRATION
This Agreement will be administered by the Public Works Department. City's
Public Works Director or designee shall be the Project Administrator and shall have the
authority to act for City under this Agreement. The Project Administrator shall represent
City in all matters pertaining to the Services to be rendered pursuant to this Agreement.
7. CITY'S RESPONSIBILITIES
To assist Consultant in the execution of its responsibilities under this Agreement,
City agrees to provide access to and upon request of Consultant, one copy of all existing
relevant information on file at City. City will provide all such materials in a timely manner
so as not to cause delays in Consultant's Work schedule.
8. STANDARD OF CARE
8.1 All of the Services shall be performed by Consultant or under Consultant's
supervision. Consultant represents that it possesses the professional and technical
personnel required to perform the Services required by this Agreement, and that it will
perform all Services in a manner commensurate with community professional standards
and with the ordinary degree of skill and care that would be used by other reasonably
competent practitioners of the same discipline under similar circumstances. All Services
shall be performed by qualified and experienced personnel who are not employed by City.
By delivery of completed Work, Consultant certifies that the Work conforms to the
requirements of this Agreement, all applicable federal, state and local laws, and legally
recognized professional standards.
8.2 Consultant represents and warrants to City that it has, shall obtain, and shall
keep in full force and effect during the term hereof, at its sole cost and expense, all
licenses, permits, qualifications, insurance and approvals of whatsoever nature that is
legally required of Consultant to practice its profession. Consultant shall maintain a City
of Newport Beach business license during the term of this Agreement.
8.3 Consultant shall not be responsible for delay, nor shall Consultant be
responsible for damages or be in default or deemed to be in default by reason of strikes,
lockouts, accidents, acts of God, or the failure of City to furnish timely information or to
GANDDINI GROUP, INC. Page 4
9-49
approve or disapprove Consultant's Work promptly, or delay or faulty performance by
City, contractors, or governmental agencies.
9. HOLD HARMLESS
9.1 To the fullest extent permitted by law, Consultant shall indemnify, defend
and hold harmless City, its City Council, boards and commissions, officers, agents,
volunteers, employees and any person or entity owning or otherwise in legal control of
the property upon which Consultant performs the Project and/or Services contemplated
by this (collectively, the "Indemnified Parties), from and against any and all claims
(including, without limitation, claims for bodily injury, death or damage to property),
demands, obligations, damages, actions, causes of action, suits, losses, judgments,
fines, penalties, liabilities, costs and expenses (including, without limitation, attorneys'
fees, disbursements and court costs) of every kind and nature whatsoever (individually,
a Claim; collectively, "Claims"), and which relate (directly or indirectly) to the negligence,
recklessness, or willful misconduct of the Consultant or its principals, officers, agents,
employees, vendors, suppliers, subconsultants, subcontractors, anyone employed
directly or indirectly by any of them or for whose acts they may be liable, or any or all of
them.
9.2 Notwithstanding the foregoing, nothing herein shall be construed to require
Consultant to indemnify the Indemnified Parties from any Claim arising from the sole
negligence, active negligence or willful misconduct of the Indemnified Parties. Nothing in
this indemnity shall be construed as authorizing any award of attorneys' fees in any action
on or to enforce the terms of this Agreement. This indemnity shall apply to all claims and
liability regardless of whether any insurance policies are applicable. The policy limits do
not act as a limitation upon the amount of indemnification to be provided by the
Consultant.
10. INDEPENDENT CONTRACTOR
10.1 It is understood that City retains Consultant on an independent contractor
basis and Consultant is not an agent or employee of City. The manner and means of
conducting the Work are under the control of Consultant, except to the extent they are
limited by statute, rule or regulation and the expressed terms of this Agreement. No civil
service status or other right of employment shall accrue to Consultant or its employees.
Nothing in this Agreement shall be deemed to constitute approval for Consultant or any
of Consultant's employees or agents, to be the agents or employees of City. Consultant
shall have the responsibility for and control over the means of performing the Work,
provided that Consultant is in compliance with the terms of this Agreement. Anything in
this Agreement that may appear to give City the right to direct Consultant as to the details
of the performance of the Work or to exercise a measure of control over Consultant shall
mean only that Consultant shall follow the desires of City with respect to the results of the
Services.
10.2 Consultant agrees and acknowledges that no individual performing
Services or Work pursuant to this Agreement shall: work full-time for more than six (6)
GANDDINI GROUP, INC. Page 5
9-50
months; work regular part-time service of at least an average of twenty (20) hours per
week for one year or longer; work nine hundred sixty (960) hours in any fiscal year; or
already be a CalPERS member.
10.3 Consultant must submit to and pass a criminal background investigation by
providing a complete set of fingerprints to City prior to commencing or performing
Services or Work. Consultant is required to submit any fees for the criminal background
investigation according to the City's most current administrative fee schedule or
successor document. Fingerprints may be required to be updated every five (5) years.
11. COOPERATION
Consultant agrees to work closely and cooperate fully with City's designated
Project Administrator and any other agencies that may have jurisdiction or interest in the
Work to be performed. City agrees to cooperate with the Consultant on the Project.
12. CITY POLICY
Consultant shall discuss and review all matters relating to policy and Project
direction with City's Project Administrator in advance of all critical decision points in order
to ensure the Project proceeds in a manner consistent with City goals and policies.
13. PROGRESS
Consultant is responsible for keeping the Project Administrator informed on a
regular basis regarding the status and progress of the Project, activities performed and
planned, and any meetings that have been scheduled or are desired.
14. INSURANCE
Without limiting Consultant's indemnification of City, and prior to commencement
of Work, Consultant shall obtain, provide and maintain at its own expense during the term
of this Agreement or for other periods as specified in this Agreement, policies of insurance
of the type, amounts, terms and conditions described in the Insurance Requirements
attached hereto as Exhibit C, and incorporated herein by reference.
15. PROHIBITION AGAINST ASSIGNMENTS AND TRANSFERS
Except as specifically authorized under this Agreement, the Services to be
provided under this Agreement shall not be assigned, transferred contracted or
subcontracted out without the prior written approval of City. Any of the following shall be
construed as an assignment: The sale, assignment, transfer or other disposition of any
of the issued and outstanding capital stock of Consultant, or of the interest of any general
partner or joint venturer or syndicate member or cotenant if Consultant is a partnership or
joint -venture or syndicate or co -tenancy, which shall result in changing the control of
Consultant. Control means fifty percent (50%) or more of the voting power or twenty-five
percent (25%) or more of the assets of the corporation, partnership or joint -venture.
GANDDINI GROUP, INC. Page 6
9-51
16. SUBCONTRACTING
The subcontractors authorized by City, if any, to perform Work on this Project are
identified in Exhibit A and the Letter Proposal. Consultant shall be fully responsible to
City for all acts and omissions of any subcontractor. Nothing in this Agreement shall
create any contractual relationship between City and any subcontractor nor shall it create
any obligation on the part of City to pay or to see to the payment of any monies due to
any such subcontractor other than as otherwise required by law. City is an intended
beneficiary of any Work performed by the subcontractor for purposes of establishing a
duty of care between the subcontractor and City. Except as specifically authorized herein,
the Services to be provided under this Agreement shall not be otherwise assigned,
transferred, contracted or subcontracted out without the prior written approval of City.
17. OWNERSHIP OF DOCUMENTS
17.1 Each and every report, draft, map, record, plan, document and other writing
produced, including but not limited to, websites, blogs, social media accounts and
applications (hereinafter "Documents"), prepared or caused to be prepared by Consultant,
its officers, employees, agents and subcontractors, in the course of implementing this
Agreement, shall become the exclusive property of City, and City shall have the sole right
to use such materials in its discretion without further compensation to Consultant or any
other party. Additionally, all material posted in cyberspace by Consultant, its officers,
employees, agents and subcontractors, in the course of implementing this Agreement,
shall become the exclusive property of City, and City shall have the sole right to use such
materials in its discretion without further compensation to Consultant or any other party.
Consultant shall, at Consultant's expense, provide such Documents, including all logins
and password information to City upon prior written request.
17.2 Documents, including drawings and specifications, prepared by Consultant
pursuant to this Agreement are not intended or represented to be suitable for reuse by
City or others on any other project. Any use of completed Documents for other projects
and any use of incomplete Documents without specific written authorization from
Consultant will be at City's sole risk and without liability to Consultant. Further, any and
all liability arising out of changes made to Consultant's deliverables under this Agreement
by City or persons other than Consultant is waived against Consultant, and City assumes
full responsibility for such changes unless City has given Consultant prior notice and has
received from Consultant written consent for such changes.
17.3 CADD data delivered to City shall include the professional stamp of the
engineer or architect in charge of or responsible for the Work. City agrees that Consultant
shall not be liable for claims, liabilities or losses arising out of, or connected with (a) the
modification or misuse by City, or anyone authorized by City, of CADD data; (b) the
decline of accuracy or readability of CADD data due to inappropriate storage conditions
or duration; or (c) any use by City, or anyone authorized by City, of CADD data for
additions to this Project, for the completion of this Project by others, or for any other
Project, excepting only such use as is authorized, in writing, by Consultant. By
acceptance of CADD data, City agrees to indemnify Consultant for damages and liability
GANDDINI GROUP, INC. Page 7
9-52
resulting from the modification or misuse of such CADD data. All original drawings shall
be submitted to City in the version of AutoCAD used by the City in .dwg file format, on a
CD, and should comply with the City's digital submission requirements for improvement
plans available from the City's Public Works Department. The City will provide Consultant
with City title sheets as AutoCAD file(s) in .dwg file format. All written documents shall
be transmitted to City in formats compatible with Microsoft Office and/or viewable with
Adobe Acrobat.
17.4 All improvement and/or construction plans shall be prepared with indelible
waterproof ink or electrostatically plotted on standard twenty-four inch (24") by thirty-six
inch (36") Mylar with a minimum thickness of three (3) mils. Consultant shall provide to
City 'As -Built' drawings and a copy of digital Computer Aided Design and Drafting
("CADD") and Tagged Image File Format (.tiff) files of all final sheets within ninety (90)
days after finalization of the Project. For more detailed requirements, a copy of the City
of Newport Beach Standard Design Requirements is available from the City's Public
Works Department.
18. OPINION OF COST
Any opinion of the construction cost prepared by Consultant represents the
Consultant's judgment as a design professional and is supplied for the general guidance
of City. Since Consultant has no control over the cost of labor and material, or over
competitive bidding or market conditions, Consultant does not guarantee the accuracy of
such opinions as compared to Consultant or contractor bids or actual cost to City.
19. CONFIDENTIALITY
All Documents, including drafts, preliminary drawings or plans, notes and
communications that result from the Services in this Agreement, shall be kept confidential
unless City expressly authorizes in writing the release of information.
20. INTELLECTUAL PROPERTY INDEMNITY
Consultant shall defend and indemnify City, its agents, officers, representatives
and employees against any and all liability, including costs, for infringement or alleged
infringement of any United States' letters patent, trademark, or copyright, including costs,
contained in Consultant's Documents provided under this Agreement.
21. RECORDS
Consultant shall keep records and invoices in connection with the Services to be
performed under this Agreement. Consultant shall maintain complete and accurate
records with respect to the costs incurred under this Agreement and any Services,
expenditures and disbursements charged to City, for a minimum period of three (3) years,
or for any longer period required by law, from the date of final payment to Consultant
under this Agreement. All such records and invoices shall be clearly identifiable.
Consultant shall allow a representative of City to examine, audit and make transcripts or
copies of such records and invoices during regular business hours. Consultant shall allow
GANDDINI GROUP, INC. Page 8
9-53
inspection of all Work, data, Documents, proceedings and activities related to the
Agreement for a period of three (3) years from the date of final payment to Consultant
under this Agreement.
22. WITHHOLDINGS
City may withhold payment to Consultant of any disputed sums until satisfaction of
the dispute with respect to such payment. Such withholding shall not be deemed to
constitute a failure to pay according to the terms of this Agreement. Consultant shall not
discontinue Work as a result of such withholding. Consultant shall have an immediate
right to appeal to the City Manager or designee with respect to such disputed sums.
Consultant shall be entitled to receive interest on any withheld sums at the rate of return
that City earned on its investments during the time period, from the date of withholding of
any amounts found to have been improperly withheld.
23. ERRORS AND OMISSIONS
In the event of errors or omissions that are due to the negligence or professional
inexperience of Consultant which result in expense to City greater than what would have
resulted if there were not errors or omissions in the Work accomplished by Consultant,
the additional design, construction and/or restoration expense shall be borne by
Consultant. Nothing in this Section is intended to limit City's rights under the law or any
other sections of this Agreement.
24. CITY'S RIGHT TO EMPLOY OTHER CONSULTANTS
City reserves the right to employ other Consultants in connection with the Project.
25. CONFLICTS OF INTEREST
25.1 Consultant or its employees may be subject to the provisions of the
California Political Reform Act of 1974 (the "Act") and/or Government Code §§ 1090 et
seq., which (1) require such persons to disclose any financial interest that may
foreseeably be materially affected by the Work performed under this Agreement, and (2)
prohibit such persons from making, or participating in making, decisions that will
foreseeably financially affect such interest.
25.2 If subject to the Act and/or Government Code §§ 1090 et seg., Consultant
shall conform to all requirements therein. Failure to do so constitutes a material breach
and is grounds for immediate termination of this Agreement by City. Consultant shall
indemnify and hold harmless City for any and all claims for damages resulting from
Consultant's violation of this Section.
26. NOTICES
26.1 All notices, demands, requests or approvals, including any change in
mailing address, to be given under the terms of this Agreement shall be given in writing,
and conclusively shall be deemed served when delivered personally, or on the third
GANDDINI GROUP, INC. Page 9
9-54
business day after the deposit thereof in the United States mail, postage prepaid, first-
class mail, addressed as hereinafter provided.
26.2 All notices, demands, requests or approvals from Consultant to City shall
be addressed to City at:
Attn: Public Works Director
Public Works Department
City of Newport Beach
100 Civic Center Drive
PO Box 1768
Newport Beach, CA 92658
26.3 All notices, demands, requests or approvals from City to Consultant shall
be addressed to Consultant at:
Attn: Giancarlo Jose Ganddini
GANDDINI GROUP, INC.
550 Parkcenter Drive, Suite 202
Santa Ana, CA 92705
27. CLAIMS
Unless a shorter time is specified elsewhere in this Agreement, before making its
final request for payment under this Agreement, Consultant shall submit to City, in writing,
all claims for compensation under or arising out of this Agreement. Consultant's
acceptance of the final payment shall constitute a waiver of all claims for compensation
under or arising out of this Agreement except those previously made in writing and
identified by Consultant in writing as unsettled at the time of its final request for payment.
Consultant and City expressly agree that in addition to any claims filing requirements set
forth in the Agreement, Consultant shall be required to file any claim Consultant may have
against City in strict conformance with the Government Claims Act (Government Code
sections 900 et seq.).
28. TERMINATION
28.1 In the event that either party fails or refuses to perform any of the provisions
of this Agreement at the time and in the manner required, that party shall be deemed in
default in the performance of this Agreement. If such default is not cured within a period
of two (2) calendar days, or if more than two (2) calendar days are reasonably required
to cure the default and the defaulting party fails to give adequate assurance of due
performance within two (2) calendar days after receipt of written notice of default,
specifying the nature of such default and the steps necessary to cure such default, and
thereafter diligently take steps to cure the default, the non -defaulting party may terminate
the Agreement forthwith by giving to the defaulting party written notice thereof.
28.2 Notwithstanding the above provisions, City shall have the right, at its sole
and absolute discretion and without cause, of terminating this Agreement at any time by
GANDDINI GROUP, INC. Page 10
9-55
giving no less than seven (7) calendar days' prior written notice to Consultant. In the
event of termination under this Section, City shall pay Consultant for Services
satisfactorily performed and costs incurred up to the effective date of termination forwhich
Consultant has not been previously paid. On the effective date of termination, Consultant
shall deliver to City all reports, Documents and other information developed or
accumulated in the performance of this Agreement, whether in draft or final form.
29. STANDARD PROVISIONS
29.1 Recitals. City and Consultant acknowledge that the above Recitals are true
and correct and are hereby incorporated by reference into this Agreement.
29.2 Compliance with all Laws. Consultant shall, at its own cost and expense,
comply with all statutes, ordinances, regulations and requirements of all governmental
entities, including federal, state, county or municipal, whether now in force or hereinafter
enacted. In addition, all Work prepared by Consultant shall conform to applicable City,
county, state and federal laws, rules, regulations and permit requirements and be subject
to approval of the Project Administrator and City.
29.3 Waiver. A waiver by either party of any breach, of any term, covenant or
condition contained herein shall not be deemed to be a waiver of any subsequent breach
of the same or any other term, covenant or condition contained herein, whether of the
same or a different character.
29.4 Integrated Contract. This Agreement represents the full and complete
understanding of every kind or nature whatsoever between the parties hereto, and all
preliminary negotiations and agreements of whatsoever kind or nature are merged herein.
No verbal agreement or implied covenant shall be held to vary the provisions herein.
29.5 Conflicts or Inconsistencies. In the event there are any conflicts or
inconsistencies between this Agreement and the Scope of Services or any other
attachments attached hereto, the terms of this Agreement shall govern.
29.6 Interpretation. The terms of this Agreement shall be construed in
accordance with the meaning of the language used and shall not be construed for or
against either party by reason of the authorship of the Agreement or any other rule of
construction which might otherwise apply.
29.7 Amendments. This Agreement may be modified or amended only by a
written document executed by both Consultant and City and approved as to form by the
City Attorney.
29.8 Severability. If any term or portion of this Agreement is held to be invalid,
illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining
provisions of this Agreement shall continue in full force and effect.
29.9 Controlling Law and Venue. The laws of the State of California shall govern
this Agreement and all matters relating to it and any action brought relating to this
GANDDINI GROUP, INC. Page 11
Agreement shall be adjudicated in a court of competent jurisdiction in the County of
Orange, State of California.
29.10 Equal Opportunity Employment. Consultant represents that it is an equal
opportunity employer and it shall not discriminate against any subcontractor, employee
or applicant for employment because race, religious creed, color, national origin,
ancestry, physical handicap, medical condition, marital status, sex, sexual orientation,
age or any other impermissible basis under law.
29.11 No Attorneys' Fees. In the event of any dispute or legal action arising under
this Agreement, the prevailing party shall not be entitled to attorneys' fees.
29.12 Counterparts. This Agreement may be executed in two (2) or more
counterparts, each of which shall be deemed an original and all of which together shall
constitute one (1) and the same instrument.
[SIGNATURES ON NEXT PAGE]
GANDDINI GROUP, INC. Page 12
9-57
IN WITNESS WHEREOF, the parties have caused this Agreement to be executed
on the dates written below.
APPROVED AS TO FORM:
CITY ATTORNEY'S OFFICE
Date:
By:
aron C. Harp
City Attorney`
ATTEST:
Date:
Leilani 1. Brown
City Clerk
CITY OF NEWPORT BEACH,
a California municipal corporation
Date:
By:
Diane B
Mayor
Dixon
CONSULTANT: GANDDINI GROUP,
INC., a California corporation
Date-
ate:
By-
By:
Giancarlo
Giancarlo Jose Ganddini
Chief Executive Officer/
Chief Financial Officer
[END OF SIGNATURES]
Attachments: Exhibit A — Scope of Services
Exhibit B — Schedule of Billing Rates
Exhibit C — Insurance Requirements
GANDDINI GROUP, INC. Page 13
U
EXHIBIT A
SCOPE OF SERVICES
GANDDINI GROUP, INC. Page A-1 9.59
EXHIBIT A
SCOPE OF SERVICES
ON-CALL PROFESSIONAL ENGINEERING SERVICES — TRAFFIC / TRANSPORTATION ENGINEERING
The following is a list of professional traffic/transportation engineering services that may be
required:
• Provide full-sized plans, specifications, and estimates for traffic/transportation
engineering projects;
• Perform general traffic -related studies;
• Review/prepare traffic signal timing/coordination plans;
• Prepare conceptual design plans/exhibits;
• Provide cost estimating and value engineering services;
• Prepare/Review transportation impact studies;
• Prepare traffic calming (neighborhood) studies;
• Review/prepare traffic control plans;
• Provide bid support and preparation of record drawings; and
• Traffic signal operation observation, review and response (excluding physical traffic signal
maintenance and repair);
• Review City's traffic control devices and policies for State and Federal Compliance;
• Attend meetings as requested; and
• Other traffic/transportation engineering -related tasks, as requested by the City.
Consultant shall perform the on-call services described in the Scope of Work ("Services" or
"Work"). Upon written request from the Project Administrator as defined herein, Consultant shall
provide a Letter Proposal for Services requested by the City (hereinafter referred to as the "Letter
Proposal").
Consultant, its contractors, and subcontractors are prohibited from providing any Work or
Services under this Agreement that would require the payment of the prevailing wage rate
under any federal, state, or local laws.
•• O
EXHIBIT B
SCHEDULE OF BILLING RATES
GANDDINI GROUP, INC. Page B-1 9.61
FEE SCHEDULE
ON-CALL PROFESSIONAL ENGINEERING SERVICES—TRAFFIC/TRANSPORTATION ENGINEERING
transportation r noise - air quality I GANDDINI GROUP
2419 STANDARD COMPENSATION SCHEDULE
CLASSIFICATION HOURLY RATE
Principal $ 150
Environmental Manager S150
Senior Engineer/Planner/Analyst $ 125
Associate Engineer/Planner/Analyst $ 100
Junior Engineer/Planner/Analyst $ 75
technician $ 40
Administrativc Assistant $ 40
9-62
EXHIBIT C
INSURANCE REQUIREMENTS — PROFESSIONAL SERVICES
Provision of Insurance. Without limiting Consultant's indemnification of City, and
prior to commencement of Work, Consultant shall obtain, provide and maintain at
its own expense during the term of this Agreement, policies of insurance of the
type and amounts described below and in a form satisfactory to City. Consultant
agrees to provide insurance in accordance with requirements set forth here. If
Consultant uses existing coverage to comply and that coverage does not meet
these requirements, Consultant agrees to amend, supplement or endorse the
existing coverage.
2. Acceptable Insurers. All insurance policies shall be issued by an insurance
company currently authorized by the Insurance Commissioner to transact
business of insurance in the State of California, with an assigned policyholders'
Rating of A- (or higher) and Financial Size Category Class VII (or larger) in
accordance with the latest edition of Best's Key Rating Guide, unless otherwise
approved by the City's Risk Manager.
3. Coverage Requirements.
A. Workers' Compensation Insurance. Consultant shall maintain Workers'
Compensation Insurance, statutory limits, and Employer's Liability
Insurance with limits of at least one million dollars ($1,000,000) each
accident for bodily injury by accident and each employee for bodily injury by
disease in accordance with the laws of the State of California, Section 3700
of the Labor Code.
Consultant shall submit to City, along with the certificate of insurance, a
Waiver of Subrogation endorsement in favor of City, its City Council, boards
and commissions, officers, agents, volunteers, employees and any person
or entity owning or otherwise in legal control of the property upon which
Consultant performs the Project and/or Services contemplated by this
Agreement.
B. General Liability Insurance. Consultant shall maintain commercial general
liability insurance, and if necessary umbrella liability insurance, with
coverage at least as broad as provided by Insurance Services Office form
CG 00 01, in an amount not less than one million dollars ($1,000,000) per
occurrence, two million dollars ($2,000,000) general aggregate. The policy
shall cover liability arising from premises, operations, personal and
advertising injury, and liability assumed under an insured contract (including
the tort liability of another assumed in a business contract).
C. Automobile Liability Insurance. Consultant shall maintain automobile
insurance at least as broad as Insurance Services Office form CA 00 01
covering bodily injury and property damage for all activities of Consultant
arising out of or in connection with Work to be performed under this
GANDDINI GROUP, INC. Page C-1 9-63
Agreement, including coverage for any owned, hired, non -owned or rented
vehicles, in an amount not less than one million dollars ($1,000,000)
combined single limit each accident.
D. Professional Liability (Errors & Omissions) Insurance. Consultant shall
maintain professional liability insurance that covers the Services to be
performed in connection with this Agreement, in the minimum amount of
one million dollars ($1,000,000) per claim and two million dollars
($2,000,000) in the aggregate. Any policy inception date, continuity date,
or retroactive date must be before the Effective Date of this Agreement and
Consultant agrees to maintain continuous coverage through a period no
less than three years after completion of the Services required by this
Agreement.
4. Other Insurance Requirements. The policies are to contain, or be endorsed to
contain, the following provisions:
A. Waiver of Subrogation. All insurance coverage maintained or procured
pursuant to this Agreement shall be endorsed to waive subrogation against
City, its City Council, boards and commissions, officers, agents, volunteers,
employees and any person or entity owning or otherwise in legal control of
the property upon which Consultant performs the Project and/or Services
contemplated by this Agreement or shall specifically allow Consultant or
others providing insurance evidence in compliance with these requirements
to waive their right of recovery prior to a loss. Consultant hereby waives its
own right of recovery against City, and shall require similar written express
waivers from each of its subconsultants.
B. Additional Insured Status. All liability policies including general liability,
excess liability, pollution liability, and automobile liability, if required, but not
including professional liability, shall provide or be endorsed to provide that
City, its City Council, boards and commissions, officers, agents, volunteers,
employees and any person or entity owning or otherwise in legal control of
the property upon which Consultant performs the Project and/or Services
contemplated by this Agreement shall be included as insureds under such
policies.
C. Primary and Non Contributory. All liability coverage shall apply on a primary
basis and shall not require contribution from any insurance or self-insurance
maintained by City.
D. Notice of Cancellation. All policies shall provide City with thirty (30)
calendar days' notice of cancellation (except for nonpayment for which ten
(10) calendar days' notice is required) or nonrenewal of coverage for each
required coverage.
5. Additional Agreements Between the Parties. The parties hereby agree to the
following:
GANDDINI GROUP, INC. Page C-2 9-64
A. Evidence of Insurance. Consultant shall provide certificates of insurance to
City as evidence of the insurance coverage required herein, along with a
waiver of subrogation endorsement for workers' compensation and other
endorsements as specified herein for each coverage. Insurance certificates
and endorsement must be approved by City's Risk Manager prior to
commencement of performance. Current certification of insurance shall be
kept on file with City at all times during the term of this Agreement. City
reserves the right to require complete, certified copies of all required
insurance policies, at any time.
B. City's Right to Revise Requirements. City reserves the right at any time
during the term of the Agreement to change the amounts and types of
insurance required by giving Consultant sixty (60) calendar days' advance
written notice of such change. If such change results in substantial
additional cost to Consultant, City and Consultant may renegotiate
Consultant's compensation.
C. Enforcement of Agreement Provisions. Consultant acknowledges and
agrees that any actual or alleged failure on the part of City to inform
Consultant of non-compliance with any requirement imposes no additional
obligations on City nor does it waive any rights hereunder.
D. Requirements not Limiting. Requirements of specific coverage features or
limits contained in this Section are not intended as a limitation on coverage,
limits or other requirements, or a waiver of any coverage normally provided
by any insurance. Specific reference to a given coverage feature is for
purposes of clarification only as it pertains to a given issue and is not
intended by any party or insured to be all inclusive, or to the exclusion of
other coverage, or a waiver of any type. If the Consultant maintains higher
limits than the minimums shown above, the City requires and shall be
entitled to coverage for higher limits maintained by the Consultant. Any
available insurance proceeds in excess of the specified minimum limits of
insurance and coverage shall be available to the City.
E. Self-insured Retentions. Any self-insured retentions must be declared to
and approved by City. City reserves the right to require that self-insured
retentions be eliminated, lowered, or replaced by a deductible. Self-
insurance will not be considered to comply with these requirements unless
approved by City.
F. City Remedies for Non -Compliance. If Consultant or any subconsultant fails
to provide and maintain insurance as required herein, then City shall have
the right but not the obligation, to purchase such insurance, to terminate this
Agreement, or to suspend Consultant's right to proceed until proper
evidence of insurance is provided. Any amounts paid by City shall, at City's
sole option, be deducted from amounts payable to Consultant or reimbursed
by Consultant upon demand.
GANDDINI GROUP, INC. Page C-3 9-65
G. Timely Notice of Claims. Consultant shall give City prompt and timely notice
of claims made or suits instituted that arise out of or result from Consultant's
performance under this Agreement, and that involve or may involve
coverage under any of the required liability policies. City assumes no
obligation or liability by such notice, but has the right (but not the duty) to
monitor the handling of any such claim or claims if they are likely to involve
City.
H. Consultant's Insurance. Consultant shall also procure and maintain, at its
own cost and expense, any additional kinds of insurance, which in its own
judgment may be necessary for its proper protection and prosecution of the
Work.
GANDDINI GROUP, INC. Page C-4 9-66