HomeMy WebLinkAbout10 - Approval of Professional Services Agreement with Coastal Frontiers for Oceanfront Sand Monitoring Program (22H04)Q �EwPpRT
O
c —
'9
TO:
FROM:
CITY OF
NEWPORT BEACH
City Council Staff Report
October 12, 2021
Agenda Item No. 10
HONORABLE MAYOR AND MEMBERS OF THE CITY COUNCIL
David A. Webb, Public Works Director - 949-644-3311,
dawebb@newportbeachca.gov
PREPARED BY: Michael J. Sinacori, P.E, Assistant City Engineer
msinacori@newportceachca.gov
PHONE: (949) 644-3342
TITLE: Approval of Professional Services Agreement with Coastal Frontiers
for Oceanfront Sand Monitoring Program (22H04)
ABSTRACT:
The City of Newport Beach's (City's) ocean beaches appear to have experienced
significant erosion, movement, and/or loss of sand in the past several years mostly due
to the larger and more consistent than normal south swells and the lack of winter storms
(La Nina condition). In years past, Coastal Frontiers has been contracted by the City to
perform beach surveys that are consistent with past Army Corps of Engineers (Army
Corps) surveys. Staff is requesting approval of a five-year professional services
agreement with Coastal Frontiers to collect annual beach profile survey information as
well as to provide necessary data to the Army Corps and other regulatory agencies to
support actions that may be necessary to replenish the sand lost within Newport Beach
coastlines. Coastal Frontiers is uniquely qualified to perform these surveys, is recognized
by the Army Corps, and is well respected in the coastal agency community.
RECOMMENDATION:
a) Determine this action is exempt from the California Environmental Quality Act (CEQA)
pursuant to Sections 15060(c)(2) and 15060(c)(3) of the CEQA Guidelines because
this action will not result in a physical change to the environment, directly or indirectly-,
and
b) Approve a Professional Services Agreement with Coastal Frontiers for Annual
Oceanfront Sand Monitoring at a total not -to -exceed price of $147,589, and authorize
the Mayor and City Clerk to execute the Agreement.
DISCUSSION:
City ocean beaches appear to have experienced significant erosion, movement and/or
loss of sand in the past several years due mostly to the larger and more consistent than
normal south swells and the lack of winter storms (La Nina condition).
10-1
Approval of Professional Services Agreement with Coastal Frontiers for
Oceanfront Sand Monitoring Program (22H04)
October 12, 2021
Page 2
Since 2006, Coastal Frontiers has been assisting the City and other regulatory agencies
in collecting data and evaluating the conditions of the ocean coastline to document and
understand the changing beach sand profile to assist with sand replenishment efforts.
Their survey efforts led to modifications to the Army Corps -led Surfside/Sunset Stage 12
project in 2009. During that project, sand was moved from the upper jetties back to the
lower jetties where the beaches had narrowed. This effort is referred to as back passing
in industry terms. The Army Corp has its planned Stage 13 project designed and ready
for implementation, which will include back passing efforts in Newport Beach. However,
funding has not yet been fully secured nor have the final agreements between partner
agencies been completed. In addition, the County of Orange (County) is starting its
annual Santa Ana River mouth sand management efforts later this month. For both
projects, a review of the coast by a recognized expert is important to direct the County
and the Army Corps on where to place the sand during its back pass operations.
The last annual survey completed by Coastal Frontiers was in Fall 2018. Staff had
planned to complete the next survey in the fall of 2020; however, due to budget concerns
during the COVID pandemic, the effort was postponed. Staff is requesting approval of a
five-year professional services agreement with Coastal Frontiers to provide data to the
Army Corps, County, and other regulatory agencies that demonstrates action may be
necessary to replenish the sand lost along the ocean coastline in Newport Beach. If
approved, this year's effort would start immediately and prior to the County sand
management efforts to the lower peninsula jetties. Coastal Frontiers is uniquely qualified
to perform these surveys and is well respected in the Coastal agency community.
FISCAL IMPACT:
The current Capital Improvement Project (CIP) adopted budget includes sufficient funding
for this year's survey efforts, $27,522. Services will be expensed to the Beach and Bay
Sand Management CIP Account No. 10001-980000-22H04. Future year's funding will be
requested during the annual budget process.
ENVIRONMENTAL REVIEW:
Staff recommends the City Council find this action is not subject to the California
Environmental Quality Act (CEQA) pursuant to Sections 15060(c)(2) (the activity will not
result in a direct or reasonably foreseeable indirect physical change in the environment)
and 15060(c)(3) (the activity is not a project as defined in Section 15378) of the CEQA
Guidelines, California Code of Regulations, Title 14, Chapter 3, because it has no
potential for resulting in physical change to the environment, directly or indirectly.
NOTICING:
The agenda item has been noticed according to the Brown Act (72 hours in advance of
the meeting at which the City Council considers the item).
ATTACHMENT:
Attachment A — Professional Services Agreement with Coastal Frontiers
10-2
ATTACHMENT A
PROFESSIONAL SERVICES AGREEMENT
WITH COASTAL FRONTIERS CORPORATION FOR
2021-2025 BEACH PROFILE SURVEY PROGRAM
THIS PROFESSIONAL SERVICES AGREEMENT ("Agreement") is made and
entered into as of this 12th day of October, 2021 ("Effective Date"), by and between the
CITY OF NEWPORT BEACH, a California municipal corporation and charter city ("City"),
and COASTAL FRONTIERS CORPORATION, a California corporation ("Consultant'),
whose address is 882 A Patriot Drive, Moorpark, California 93021, and is made with
reference to the following:
RECITALS
A. City is a municipal corporation duly organized and validly existing under the laws
of the State of California with the power to carry on its business as it is now being
conducted under the statutes of the State of California and the Charter of City.
B. City desires to engage Consultant to provide beach profile surveys for 2021
through 2025 based on profile data obtained along 13 shore -perpendicular beach
profile transects located between the Santa Ana River and Corona del Mar
("Project").
C. Consultant possesses the skill, experience, ability, background, certification and
knowledge to provide the professional services described in this Agreement.
D. City has solicited and received a proposal from Consultant, has reviewed the
previous experience and evaluated the expertise of Consultant, and desires to
retain Consultant to render professional services under the terms and conditions
set forth in this Agreement.
NOW, THEREFORE, it is mutually agreed by and between the undersigned parties
as follows:
1. TERM
The term of this Agreement shall commence on the Effective Date, and shall
terminate on June 30, 2026, unless terminated earlier as set forth herein.
2. SERVICES TO BE PERFORMED
Consultant shall diligently perform all the services described in the Scope of
Services attached hereto as Exhibit A and incorporated herein by reference ("Services"
or "Work"). City may elect to delete certain Services within the Scope of Services at its
sole discretion.
10-3
3. TIME OF PERFORMANCE
3.1 Time is of the essence in the performance of Services under this Agreement
and Consultant shall perform the Services in accordance with the schedule included in
Exhibit A. In the absence of a specific schedule, the Services shall be performed to
completion in a diligent and timely manner. The failure by Consultant to strictly adhere to
the schedule set forth in Exhibit A, if any, or perform the Services in a diligent and timely
manner may result in termination of this Agreement by City.
3.2 Notwithstanding the foregoing, Consultant shall not be responsible for
delays due to causes beyond Consultant's reasonable control. However, in the case of
any such delay in the Services to be provided for the Project, each party hereby agrees
to provide notice within two (2) calendar days of the occurrence causing the delay to the
other party so that all delays can be addressed.
3.3 Consultant shall submit all requests for extensions of time for performance
in writing to the Project Administrator as defined herein not later than ten (10) calendar
days after the start of the condition that purportedly causes a delay. The Project
Administrator shall review all such requests and may grant reasonable time extensions
for unforeseeable delays that are beyond Consultant's control.
3.4 For all time periods not specifically set forth herein, Consultant shall
respond in the most expedient and appropriate manner under the circumstances, by
hand -delivery or mail.
4. COMPENSATION TO CONSULTANT
4.1 City shall pay Consultant for the Services on a fixed fee not -to -exceed basis
in accordance with the provisions of this Section and the Schedule of Billing Rates
attached hereto as Exhibit B and incorporated herein by reference. Consultant's
compensation for all Work performed in accordance with this Agreement, including all
reimbursable items and subconsultant fees, shall not exceed One Hundred Forty Seven
Thousand Five Hundred Eighty Nine Dollars and 001100 ($147,589.00), without prior
written authorization from City. No billing rate changes shall be made during the term of
this Agreement without the prior written approval of City.
4.2 Consultant shall submit invoices to City upon completion of each of the
tasks as outlined in Scope of Services, and a description of any reimbursable
expenditures. City shall pay Consultant no later than thirty (30) calendar days after
approval of the monthly invoice by City staff.
4.3 City shall reimburse Consultant only for those costs or expenses specifically
identified in Exhibit B to this Agreement or specifically approved in writing in advance by
City.
4.4 Consultant shall not receive any compensation for Extra Work performed
without the prior written authorization of City. As used herein, "Extra Work" means any
Work that is determined by City to be necessary for the proper completion of the Project,
Coastal Frontiers Corporation Page 2
10-4
but which is not included within the Scope of Services and which the parties did not
reasonably anticipate would be necessary at the execution of this Agreement.
Compensation for any authorized Extra Work shall be paid in accordance with the
Schedule of Billing Rates as set forth in Exhibit B.
5. PROJECT MANAGER
5.1 Consultant shall designate a Project Manager, who shall coordinate all
phases of the Project. This Project Manager shall be available to City at all reasonable
times during the Agreement term. Consultant has designated Christopher Scott to be its
Project Manager. Consultant shall not remove or reassign the Project Manager or any
personnel listed in Exhibit A or assign any new or replacement personnel to the Project
without the prior written consent of City. City's approval shall not be unreasonably
withheld with respect to the removal or assignment of non -key personnel.
5.2 Consultant, at the sole discretion of City, shall remove from the Project any
of its personnel assigned to the performance of Services upon written request of City.
Consultant warrants that it will continuously furnish the necessary personnel to complete
the Project on a timely basis as contemplated by this Agreement.
5.3 If Consultant is performing inspection services for City, the Project Manager
and any other assigned staff shall be equipped with a cellular phone to communicate with
City staff. The Project Manager's cellular phone number shall be provided to City.
6. ADMINISTRATION
This Agreement will be administered by the Public Works Department. City's
Public Works Director or designee shall be the Project Administrator and shall have the
authority to act for City under this Agreement. The Project Administrator shall represent
City in all matters pertaining to the Services to be rendered pursuant to this Agreement.
7. CITY'S RESPONSIBILITIES
To assist Consultant in the execution of its responsibilities under this Agreement,
City agrees to provide access to and upon request of Consultant, one copy of all existing
relevant information on file at City. City will provide all such materials in a timely manner
so as not to cause delays in Consultant's Work schedule.
8. STANDARD OF CARE
8.1 All of the Services shall be performed by Consultant or under Consultant's
supervision. Consultant represents that it possesses the professional and technical
personnel required to perform the Services required by this Agreement, and that it will
perform all Services in a manner commensurate with community professional standards
and with the ordinary degree of skill and care that would be used by other reasonably
competent practitioners of the same discipline under similar circumstances. All Services
shall be performed by qualified and experienced personnel who are not employed by City.
By delivery of completed Work, Consultant certifies that the Work conforms to the
Coastal Frontiers Corporation Page 3
10-5
requirements of this Agreement, all applicable federal, state and local laws, and legally
recognized professional standards.
8.2 Consultant represents and warrants to City that it has, shall obtain, and shall
keep in full force and effect during the term hereof, at its sole cost and expense, all
licenses, permits, qualifications, insurance and approvals of whatsoever nature that is
legally required of Consultant to practice its profession. Consultant shall maintain a City
of Newport Beach business license during the term of this Agreement.
8.3 Consultant shall not be responsible for delay, nor shall Consultant be
responsible for damages or be in default or deemed to be in default by reason of strikes,
lockouts, accidents, acts of God, or the failure of City to furnish timely information or to
approve or disapprove Consultant's Work promptly, or delay or faulty performance by
City, contractors, or governmental agencies.
9. HOLD HARMLESS
9.1 To the fullest extent permitted by law, Consultant shall indemnify, defend
and hold harmless City, its City Council, boards and commissions, officers, agents,
volunteers, employees and the State of California (collectively, the "Indemnified Parties"),
from and against any and all claims (including, without limitation, claims for bodily injury,
death or damage to property), demands, obligations, damages, actions, causes of action,
suits, losses, judgments, fines, penalties, liabilities, costs and expenses (including,
without limitation, attorneys' fees, disbursements and court costs) of every kind and
nature whatsoever (individually, a Claim; collectively, "Claims"), and which relate (directly
or indirectly) to the negligence, recklessness, or willful misconduct of the Consultant or
its principals, officers, agents, employees, vendors, suppliers, subconsultants,
subcontractors, anyone employed directly or indirectly by any of them or for whose acts
they may be liable, or any or all of them.
9.2 Notwithstanding the foregoing, nothing herein shall be construed to require
Consultant to indemnify the Indemnified Parties from any Claim arising from the sole
negligence, active negligence or willful misconduct of the Indemnified Parties. Nothing in
this indemnity shall be construed as authorizing any award of attorneys' fees in any action
on or to enforce the terms of this Agreement. This indemnity shall apply to all claims and
liability regardless of whether any insurance policies are applicable. The policy limits do
not act as a limitation upon the amount of indemnification to be provided by the
Consultant.
10. INDEPENDENT CONTRACTOR
It is understood that City retains Consultant on an independent contractor basis
and Consultant is not an agent or employee of City. The manner and means of
conducting the Work are under the control of Consultant, except to the extent they are
limited by statute, rule or regulation and the expressed terms of this Agreement. No civil
service status or other right of employment shall accrue to Consultant or its employees.
Nothing in this Agreement shall be deemed to constitute approval for Consultant or any
Coastal Frontiers Corporation Page 4
10-6
of Consultant's employees or agents, to be the agents or employees of City. Consultant
shall have the responsibility for and control over the means of performing the Work,
provided that Consultant is in compliance with the terms of this Agreement. Anything in
this Agreement that may appear to give City the right to direct Consultant as to the details
of the performance of the Work or to exercise a measure of control over Consultant shall
mean only that Consultant shall follow the desires of City with respect to the results of the
Services.
11. COOPERATION
Consultant agrees to work closely and cooperate fully with City's designated
Project Administrator and any other agencies that may have jurisdiction or interest in the
Work to be performed. City agrees to cooperate with the Consultant on the Project.
12. CITY POLICY
Consultant shall discuss and review all matters relating to policy and Project
direction with City's Project Administrator in advance of all critical decision points in order
to ensure the Project proceeds in a manner consistent with City goals and policies.
13. PROGRESS
Consultant is responsible for keeping the Project Administrator informed on a
regular basis regarding the status and progress of the Project, activities performed and
planned, and any meetings that have been scheduled or are desired.
14. INSURANCE
Without limiting Consultant's indemnification of City, and prior to commencement
of Work, Consultant shall obtain, provide and maintain at its own expense during the term
of this Agreement or for other periods as specified in this Agreement, policies of insurance
of the type, amounts, terms and conditions described in the Insurance Requirements
attached hereto as Exhibit C, and incorporated herein by reference.
15. PROHIBITION AGAINST ASSIGNMENTS AND TRANSFERS
Except as specifically authorized under this Agreement, the Services to be
provided under this Agreement shall not be assigned, transferred contracted or
subcontracted out without the prior written approval of City. Any of the following shall be
construed as an assignment: The sale, assignment, transfer or other disposition of any
of the issued and outstanding capital stock of Consultant, or of the interest of any general
partner or joint venturer or syndicate member or cotenant if Consultant is a partnership or
joint -venture or syndicate or co -tenancy, which shall result in changing the control of
Consultant. Control means fifty percent (50%) or more of the voting power or twenty-five
percent (25%) or more of the assets of the corporation, partnership or joint -venture.
Coastal Frontiers Corporation Page 5
10-7
16. SUBCONTRACTING
The subcontractors authorized by City, if any, to perform Work on this Project are
identified in Exhibit A. Consultant shall be fully responsible to City for all acts and
omissions of any subcontractor. Nothing in this Agreement shall create any contractual
relationship between City and any subcontractor nor shall it create any obligation on the
part of City to pay or to see to the payment of any monies due to any such subcontractor
other than as otherwise required by law. City is an intended beneficiary of any Work
performed by the subcontractor for purposes of establishing a duty of care between the
subcontractor and City. Except as specifically authorized herein, the Services to be
provided under this Agreement shall not be otherwise assigned, transferred, contracted
or subcontracted out without the prior written approval of City.
17. OWNERSHIP OF DOCUMENTS
17.1 Each and every report, draft, map, record, plan, document and other writing
produced, including but not limited to, websites, blogs, social media accounts and
applications (hereinafter "Documents"), prepared or caused to be prepared by Consultant,
its officers, employees, agents and subcontractors, in the course of implementing this
Agreement, shall become the exclusive property of City, and City shall have the sole right
to use such materials in its discretion without further compensation to Consultant or any
other party. Additionally, all material posted in cyberspace by Consultant, its officers,
employees, agents and subcontractors, in the course of implementing this Agreement,
shall become the exclusive property of City, and City shall have the sole right to use such
materials in its discretion without further compensation to Consultant or any other party.
Consultant shall, at Consultant's expense, provide such Documents, including all logins
and password information to City upon prior written request.
17.2 Documents, including drawings and specifications, prepared by Consultant
pursuant to this Agreement are not intended or represented to be suitable for reuse by
City or others on any other project. Any use of completed Documents for other projects
and any use of incomplete Documents without specific written authorization from
Consultant will be at City's sole risk and without liability to Consultant. Further, any and
all liability arising out of changes made to Consultant's deliverables under this Agreement
by City or persons other than Consultant is waived against Consultant, and City assumes
full responsibility for such changes unless City has given Consultant prior notice and has
received from Consultant written consent for such changes.
17.3 CADD data delivered to City shall include the professional stamp of the
engineer or architect in charge of or responsible for the Work. City agrees that Consultant
shall not be liable for claims, liabilities or losses arising out of, or connected with (a) the
modification or misuse by City, or anyone authorized by City, of CADD data; (b) the
decline of accuracy or readability of CADD data due to inappropriate storage conditions
or duration; or (c) any use by City, or anyone authorized by City, of CADD data for
additions to this Project, for the completion of this Project by others, or for any other
Project, excepting only such use as is authorized, in writing, by Consultant. By
acceptance of CADD data, City agrees to indemnify Consultant for damages and liability
Coastal Frontiers Corporation Page 6
10-s
resulting from the modification or misuse of such CADD data. All original drawings shall
be submitted to City in the version of AutoCAD used by the City in .dwg file format, on a
CD, and should comply with the City's digital submission requirements for improvement
plans available from the City's Public Works Department. The City will provide Consultant
with City title sheets as AutoCAD file(s) in .dwg file format. All written documents shall
be transmitted to City in formats compatible with Microsoft Office and/or viewable with
Adobe Acrobat.
17.4 All improvement and/or construction plans shall be prepared with indelible
waterproof ink or electrostatically plotted on standard twenty-four inch (24") by thirty-six
inch (36") Mylar with a minimum thickness of three (3) mils. Consultant shall provide to
City 'As -Built' drawings and a copy of digital Computer Aided Design and Drafting
("CADD") and Tagged Image File Format (.tiff) files of all final sheets within ninety (90)
days after finalization of the Project. For more detailed requirements, a copy of the City
of Newport Beach Standard Design Requirements is available from the City's Public
Works Department.
18. CONFIDENTIALITY
All Documents, including drafts, preliminary drawings or plans, notes and
communications that result from the Services in this Agreement, shall be kept confidential
unless City expressly authorizes in writing the release of information.
19. INTELLECTUAL PROPERTY INDEMNITY
Consultant shall defend and indemnify City, its agents, officers, representatives
and employees against any and all liability, including costs, for infringement or alleged
infringement of any United States' letters patent, trademark, or copyright, including costs,
contained in Consultant's Documents provided under this Agreement.
20. RECORDS
Consultant shall keep records and invoices in connection with the Services to be
performed under this Agreement. Consultant shall maintain complete and accurate
records with respect to the costs incurred under this Agreement and any Services,
expenditures and disbursements charged to City, for a minimum period of three (3) years,
or for any longer period required by law, from the date of final payment to Consultant
under this Agreement. All such records and invoices shall be clearly identifiable.
Consultant shall allow a representative of City to examine, audit and make transcripts or
copies of such records and invoices during regular business hours. Consultant shall allow
inspection of all Work, data, Documents, proceedings and activities related to the
Agreement for a period of three (3) years from the date of final payment to Consultant
under this Agreement.
21. WITHHOLDINGS
City may withhold payment to Consultant of any disputed sums until satisfaction of
the dispute with respect to such payment. Such withholding shall not be deemed to
Coastal Frontiers Corporation Page 7
10-9
constitute a failure to pay according to the terms of this Agreement. Consultant shall not
discontinue Work as a result of such withholding. Consultant shall have an immediate
right to appeal to the City Manager or designee with respect to such disputed sums.
Consultant shall be entitled to receive interest on any withheld sums at the rate of return
that City earned on its investments during the time period, from the date of withholding of
any amounts found to have been improperly withheld.
22. ERRORS AND OMISSIONS
In the event of errors or omissions that are due to the negligence or professional
inexperience of Consultant which result in expense to City greater than what would have
resulted if there were not errors or omissions in the Work accomplished by Consultant,
the additional design, construction and/or restoration expense shall be borne by
Consultant. Nothing in this Section is intended to limit City's rights under the law or any
other sections of this Agreement.
23. CITY'S RIGHT TO EMPLOY OTHER CONSULTANTS
City reserves the right to employ other Consultants in connection with the Project.
24. CONFLICTS OF INTEREST
24.1 Consultant or its employees may be subject to the provisions of the
California Political Reform Act of 1974 (the "Act") and/or Government Code §§ 1090 et
seq., which (1) require such persons to disclose any financial interest that may
foreseeably be materially affected by the Work performed under this Agreement, and (2)
prohibit such persons from making, or participating in making, decisions that will
foreseeably financially affect such interest.
24.2 If subject to the Act and/or Government Code §§ 1090 et seq., Consultant
shall conform to all requirements therein. Failure to do so constitutes a material breach
and is grounds for immediate termination of this Agreement by City. Consultant shall
indemnify and hold harmless City for any and all claims for damages resulting from
Consultant's violation of this Section.
25. NOTICES
25.1 All notices, demands, requests or approvals, including any change in
mailing address, to be given under the terms of this Agreement shall be given in writing,
and conclusively shall be deemed served when delivered personally, or on the third
business day after the deposit thereof in the United States mail, postage prepaid, first-
class mail, addressed as hereinafter provided.
25.2 All notices, demands, requests or approvals from Consultant to City shall
be addressed to City at:
Coastal Frontiers Corporation Page 8
10-10
Attn: Public Works Director
Public Works Department
City of Newport Beach
100 Civic Center Drive
PO Box 1768
Newport Beach, CA 92658
25.3 All notices, demands, requests or approvals from City to Consultant shall
be addressed to Consultant at:
Attn: Christopher Scott
Coastal Frontiers Corporation
882 A Patriot Drive
Moorpark, CA 93021
26. CLAIMS
26.1 Unless a shorter time is specified elsewhere in this Agreement, before
making its final request for payment under this Agreement, Consultant shall submit to
City, in writing, all claims for compensation under or arising out of this Agreement.
Consultant's acceptance of the final payment shall constitute a waiver of all claims for
compensation under or arising out of this Agreement except those previously made in
writing and identified by Consultant in writing as unsettled at the time of its final request
for payment. Consultant and City expressly agree that in addition to any claims filing
requirements set forth in the Agreement, Consultant shall be required to file any claim
Consultant may have against City in strict conformance with the Government Claims Act
(Government Code sections 900 et seq.).
26.2 To the extent that Consultant's claim is a "Claim" as defined in Public
Contract Code section 9204 or any successor statute thereto, the Parties agree to follow
the dispute resolution process set forth therein. Any part of such "Claim" remaining in
dispute after completion of the dispute resolution process provided for in Public Contract
Code section 9204 or any successor statute thereto shall be subject to the Government
Claims Act requirements requiring Consultant to file a claim in strict conformance with the
Government Claims Act. To the extent that Contractor/Consultant's claim is not a "Claim"
as defined in Public Contract Code section 9204 or any successor statute thereto,
Consultant shall be required to file such claim with the City in strict conformance with the
Government Claims Act (Government Code sections 900 et seq.).
27. TERMINATION
27.1 In the event that either party fails or refuses to perform any of the provisions
of this Agreement at the time and in the manner required, that party shall be deemed in
default in the performance of this Agreement. If such default is not cured within a period
of two (2) calendar days, or if more than two (2) calendar days are reasonably required
to cure the default and the defaulting party fails to give adequate assurance of due
performance within two (2) calendar days after receipt of written notice of default,
Coastal Frontiers Corporation Page 9
10-11
specifying the nature of such default and the steps necessary to cure such default, and
thereafter diligently take steps to cure the default, the non -defaulting party may terminate
the Agreement forthwith by giving to the defaulting party written notice thereof.
27.2 Notwithstanding the above provisions, City shall have the right, at its sole
and absolute discretion and without cause, of terminating this Agreement at any time by
giving no less than seven (7) calendar days' prior written notice to Consultant. In the
event of termination under this Section, City shall pay Consultant for Services
satisfactorily performed and costs incurred up to the effective date of termination for which
Consultant has not been previously paid. On the effective date of termination, Consultant
shall deliver to City all reports, Documents and other information developed or
accumulated in the performance of this Agreement, whether in draft or final form.
28. STANDARD PROVISIONS
28.1 Recitals. City and Consultant acknowledge that the above Recitals are true
and correct and are hereby incorporated by reference into this Agreement.
28.2 Compliance with all Laws. Consultant shall, at its own cost and expense,
comply with all statutes, ordinances, regulations and requirements of all governmental
entities, including federal, state, county or municipal, whether now in force or hereinafter
enacted. In addition, all Work prepared by Consultant shall conform to applicable City,
county, state and federal laws, rules, regulations and permit requirements and be subject
to approval of the Project Administrator and City.
28.3 Waiver. A waiver by either party of any breach, of any term, covenant or
condition contained herein shall not be deemed to be a waiver of any subsequent breach
of the same or any other term, covenant or condition contained herein, whether of the
same or a different character.
28.4 Integrated Contract. This Agreement represents the full and complete
understanding of every kind or nature whatsoever between the parties hereto, and all
preliminary negotiations and agreements of whatsoever kind or nature are merged herein.
No verbal agreement or implied covenant shall be held to vary the provisions herein.
28.5 Conflicts or Inconsistencies. In the event there are any conflicts or
inconsistencies between this Agreement and the Scope of Services or any other
attachments attached hereto, the terms of this Agreement shall govern.
28.6 Interpretation. The terms of this Agreement shall be construed in
accordance with the meaning of the language used and shall not be construed for or
against either parry by reason of the authorship of the Agreement or any other rule of
construction which might otherwise apply.
28.7 Amendments. This Agreement may be modified or amended only by a
written document executed by both Consultant and City and approved as to form by the
City Attorney.
Coastal Frontiers Corporation Page 10
10-12
28.8 Severability. If any term or portion of this Agreement is held to be invalid,
illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining
provisions of this Agreement shall continue in full force and effect.
28.9 Controlling Law and Venue. The laws of the State of California shall govern
this Agreement and all matters relating to it and any action brought relating to this
Agreement shall be adjudicated in a court of competent jurisdiction in the County of
Orange, State of California.
28.10 Equal Opportunity Employment. Consultant represents that it is an equal
opportunity employer and it shall not discriminate against any subcontractor, employee
or applicant for employment because race, religious creed, color, national origin,
ancestry, physical handicap, medical condition, marital status, sex, sexual orientation,
age or any other impermissible basis under law.
28.11 No Attorneys' Fees. In the event of any dispute or legal action arising under
this Agreement, the prevailing party shall not be entitled to attorneys' fees.
28.12 Counterparts. This Agreement may be executed in two (2) or more
counterparts, each of which shall be deemed an original and all of which together shall
constitute one (1) and the same instrument.
[SIGNATURES ON NEXT PAGE]
Coastal Frontiers Corporation Page 11
10-13
IN WITNESS WHEREOF, the parties have caused this Agreement to be executed
on the dates written below.
APPROVED AS TO FORM:
CITY ATTrz,
EY'S OFFICE
Date: �/
By'
Aar n C_ War Vim' R
City Attorney
ATTEST:
Date:
CITY OF NEWPORT BEACH,
a California municipal corporation
Date:
By:
Brad Avery
Mayor
CONSULTANT: Coastal Frontiers
Corporation, a California corporation
Date:
By:
Leilani I. Brown Craig B. Leidersdorf
City Clerk Chief Executive Officer
Date -
By:
Gregory E
Secretary
[END OF SIGNATURES]
Attachments: Exhibit A — Scope of Services
Exhibit B — Schedule of Billing Rates
Exhibit C — Insurance Requirements
Hearon
Coastal Frontiers Corporation Page 12
10 -14
EXHIBIT A
SCOPE OF SERVICES
CITY OF NEWPORT BEACH
2021-2025 BEACH PROFILE SURVEY PROGRAM
Beach profile data will be obtained along 13 shore -perpendicular beach profile transects
located between the Santa Ana River and Corona del Mar (Figure 1). The proposed
survey methods are similar to those employed on previous survey programs conducted
on behalf of the City. The data acquired along each transect will form a continuous profile
from the back beach to the offshore terminus, which will be the 45 -ft isobath, Mean Lower
Low Water (MLLW) Datum.
Figure 1. Location Map
The work will include up to five beach profile surveys to be conducted between Fall 2021
and Fall 2025. For the purposes of developing this scope and cost estimate, it is assumed
that each of the five surveys will be conducted in the fall, as shown below:
Task 1 —
Fall 2021 Beach Profile Survey
Task 2 —
Fall 2022 Beach Profile Survey
Task 3 —
Fall 2023 Beach Profile Survey
Task 4 —
Fall 2024 Beach Profile Survey
Task 5 —
Fall 2025 Beach Profile Survey
Each of the survey tasks will consist of field data acquisition, data reduction, and reporting
as described in the sub -sections that follow.
Coastal Frontiers Corporation Page A-1 10-15
Task la - Fall 2021 Field Data Acquisition
Bathymetric data will be collected with a single -beam echo sounder operated from a
shallow -draft survey vessel. A dynamic motion sensor, which filters the data record to
reduce the influence of wave contamination and vessel motion, will be used. The boat will
transit each transect from the offshore terminus to the surf zone. The position of each
sounding will be obtained using a GPS receiver with differential position corrections
(DGPS). The calibration of the echo sounder will be checked at the beginning and end of
the survey using a standard "bar check" procedure. In addition, the speed of sound in sea
water will be calculated at the offshore end of each transect using a device that measures
conductivity, temperature, and depth (CTD) along a vertical profile within the water
column.
The subaerial beach and surf zone will be surveyed using a total station and a survey
rodman. The total station will be operated from the beach to determine the position and
elevation at each location occupied by the rodman. The rodman will gather data through
the surf zone to the calmer waters offshore in an effort to obtain data overlap with the
survey vessel. It is assumed that the survey control used in prior monitoring programs is
in good condition. If the control markers are found to be destroyed, new control points will
be established at an additional cost.
Task lb — Fall 2021 Data Reduction and Reporting
The soundings will be adjusted to MLLW Datum utilizing tide measurements collected by
the U.S. Department of Commerce, NOAA, at Los Angeles Harbor. The water levels
recorded in Los Angeles will be adjusted using the time and height differences published
by NOAA for the study area.
Data collected with the total station will be reduced using proprietary survey software. The
wading data will be merged with the processed soundings, and the resulting information
will be used to create a continuous beach profile.
A concise letter report will be prepared which documents the survey methods and results.
The report shall include an assessment of short- and long-term changes in the following
parameters:
• Beach Profile Plots
• MSL Beach Width
• Shorezone Volume (back beach to depth -of -closure)
The report shall summarize recent beach management activities undertaken in the region
and the impacts (if any) that these activities had on the local beaches. Digital data files
containing the survey data shall be submitted with the report.
Task 2a — Fall 2022 Field Survey Activities
Identical to Task 1 a
Coastal Frontiers Corporation Page A-2 10-16
Task 2b — Fall 2022 Data Reduction and Reporting
Identical to Task 1 b
Task 3a — Fall 2023 Field Survey Activities
Identical to Task 1 a
Task 3b — Fall 2023 Data Reduction and Reporting
Identical to Task 1 b
Task 4a — Fall 2024 Field Survey Activities
Identical to Task 1 a
Task 4b — Fall 2024 Data Reduction and Reporting
Identical to Task 1 b
Task 5a — Fall 2025 Field Survey Activities
Identical to Task 1 a
Task 5b — Fall 2025 Data Reduction and Reporting
Identical to Task 1 b
DELIVERABLES
As noted above, the methods and results shall be documented in a concise letter report
following each survey. The report shall include beach profile plots developed from the
survey data and will contain select profiles from prior surveys to provide historical context.
Tabulated values of Mean Sea Level Beach Widths and Shorezone Volumes (back beach
to the depth -of -closure) will be provided. The report shall summarize recent beach
management activities undertaken in the region and the impacts (if any) that these
activities had on the local beaches. Digital data files containing the survey data shall be
submitted with the report.
It is assumed that the Fall surveys will be conducted in October. It should be noted that
field operations are typically limited to periods of favorable weather conditions, including
light winds and wave heights less than three feet. The final letter report will be delivered
to the City within 90 days of completing each survey.
Coastal Frontiers Corporation Page A-3 10-17
EXHIBIT B
SCHEDULE OF BILLING RATES
CITY OF NEWPORT BEACH
2021-2025 BEACH PROFILE SURVEY PROGRAM
Consultant shall conduct the 2021 Beach Profile Survey on a lump -sum (fixed price)
basis, with a cost of $27,522. The cost to conduct each of the four subsequent surveys
(Fall 2022 — Fall 2025) has been escalated by 3.5% per -year to account for inflation. The
net cost for the 2021-2025 Beach Profile Survey Program is $147,589. A cost summary
is provided below:
• Task 1 — Fall 2021 Beach Profile Survey: ................ $27,522.00
• Task 2 — Fall 2022 Beach Profile Survey: ................ $28,486.00
• Task 3 — Fall 2023 Beach Profile Survey: ................ $29,483.00
• Task 4 — Fall 2024 Beach Profile Survey: ................ $30,515.00
• Task 5 — Fall 2025 Beach Profile Survey: ................ $31,583.00
Not to ExceedTotal $147,589.00
As noted above, the lump -sum cost has been developed assuming that each of the five
surveys are conducted in the fall. Spring surveys, if requested, will be conducted at the
same cost as the fall survey for that year. Additionally, the fixed price above does not
include the cost to reestablish any destroyed survey control markers, if necessary.
Coastal Frontiers Corporation Page B-1 10-18
EXHIBIT C
INSURANCE REQUIREMENTS — PROFESSIONAL SERVICES
1. Provision of Insurance. Without limiting Consultant's indemnification of City, and
prior to commencement of Work, Consultant shall obtain, provide and maintain at
its own expense during the term of this Agreement, policies of insurance of the
type and amounts described below and in a form satisfactory to City. Consultant
agrees to provide insurance in accordance with requirements set forth here. If
Consultant uses existing coverage to comply and that coverage does not meet
these requirements, Consultant agrees to amend, supplement or endorse the
existing coverage.
2. Acceptable Insurers. All insurance policies shall be issued by an insurance
company currently authorized by the Insurance Commissioner to transact
business of insurance in the State of California, with an assigned policyholders'
Rating of A- (or higher) and Financial Size Category Class VII (or larger) in
accordance with the latest edition of Best's Key Rating Guide, unless otherwise
approved by the City's Risk Manager.
3. Coverage Requirements.
A. Workers' Compensation Insurance. Consultant shall maintain Workers'
Compensation Insurance, statutory limits, and Employer's Liability
Insurance with limits of at least one million dollars ($1,000,000) each
accident for bodily injury by accident and each employee for bodily injury by
disease in accordance with the laws of the State of California, Section 3700
of the Labor Code.
Consultant shall submit to City, along with the certificate of insurance, a
Waiver of Subrogation endorsement in favor of City, its City Council, boards
and commissions, officers, agents, volunteers, employees and the State of
California.
B. General Liability Insurance. Consultant shall maintain commercial general
liability insurance, and if necessary umbrella liability insurance, with
coverage at least as broad as provided by Insurance Services Office form
CG 00 01, in an amount not less than one million dollars ($1,000,000) per
occurrence, two million dollars ($2,000,000) general aggregate. The policy
shall cover liability arising from premises, operations, personal and
advertising injury, and liability assumed under an insured contract (including
the tort liability of another assumed in a business contract).
C. Automobile Liability Insurance. Consultant shall maintain automobile
insurance at least as broad as Insurance Services Office form CA 00 01
covering bodily injury and property damage for all activities of Consultant
arising out of or in connection with Work to be performed under this
Agreement, including coverage for any owned, hired, non -owned or rented
Coastal Frontiers Corporation Page C-1 10-19
vehicles, in an amount not less than one million dollars ($1,000,000)
combined single limit each accident.
D. Professional Liability (Errors & Omissions) Insurance. Consultant shall
maintain professional liability insurance that covers the Services to be
performed in connection with this Agreement, in the minimum amount of
one million dollars ($1,000,000) per claim and two million dollars
($2,000,000) in the aggregate. Any policy inception date, continuity date,
or retroactive date must be before the Effective Date of this Agreement and
Consultant agrees to maintain continuous coverage through a period no
less than three years after completion of the Services required by this
Agreement.
4. Other Insurance Requirements. The policies are to contain, or be endorsed to
contain, the following provisions:
A. Waiver of Subrogation. All insurance coverage maintained or procured
pursuant to this Agreement shall be endorsed to waive subrogation against
City, its City Council, boards and commissions, officers, agents, volunteers,
employees and the State of California or shall specifically allow Consultant
or others providing insurance evidence in compliance with these
requirements to waive their right of recovery prior to a loss. Consultant
hereby waives its own right of recovery against City, and shall require
similar written express waivers from each of its subconsultants.
B. Additional Insured Status. All liability policies including general liability,
excess liability, pollution liability, and automobile liability, if required, but not
including professional liability, shall provide or be endorsed to provide that
City, its City Council, boards and commissions, officers, agents, volunteers,
employees and the State of California shall be included as insureds under
such policies.
C. Primary and Non Contributory. All liability coverage shall apply on a primary
basis and shall not require contribution from any insurance or self-insurance
maintained by City.
D. Notice of Cancellation. All policies shall provide City with thirty (30)
calendar days' notice of cancellation (except for nonpayment for which ten
(10) calendar days' notice is required) or nonrenewal of coverage for each
required coverage.
5. Additional Agreements Between the Parties. The parties hereby agree to the
following:
A. Evidence of Insurance. Consultant shall provide certificates of insurance to
City as evidence of the insurance coverage required herein, along with a
waiver of subrogation endorsement for workers' compensation and other
endorsements as specified herein for each coverage. Insurance certificates
and endorsement must be approved by City's Risk Manager prior to
Coastal Frontiers Corporation Page C-2 10-20
commencement of performance. Current certification of insurance shall be
kept on file with City at all times during the term of this Agreement. The
certificates and endorsements for each insurance policy shall be signed by
a person authorized by that insurer to bind coverage on its behalf. At least
fifteen (15) days prior to the expiration of any such policy, evidence of
insurance showing that such insurance coverage has been renewed or
extended shall be filed with the City. If such coverage is cancelled or
reduced, Consultant shall, within ten (10) days after receipt of written notice
of such cancellation or reduction of coverage, file with the City evidence of
insurance showing that the required insurance has been reinstated or has
been provided through another insurance company or companies. City
reserves the right to require complete, certified copies of all required
insurance policies, at any time.
B. City's Right to Revise Requirements. City reserves the right at any time
during the term of the Agreement to change the amounts and types of
insurance required by giving Consultant sixty (60) calendar days' advance
written notice of such change. If such change results in substantial
additional cost to Consultant, City and Consultant may renegotiate
Consultant's compensation.
C. Right to Review Subcontracts. Consultant agrees that upon request, all
agreements with subcontractors or others with whom Consultant enters into
contracts with on behalf of City will be submitted to City for review. Failure
of City to request copies of such agreements will not impose any liability on
City, or its employees. Consultant shall require and verify that all
subcontractors maintain insurance meeting all the requirements stated
herein, and Consultant shall ensure that City is an additional insured on
insurance required from subcontractors. For CGL coverage,
subcontractors shall provide coverage with a format at least as broad as CG
20 38 04 13.
D. Enforcement of Agreement Provisions. Consultant acknowledges and
agrees that any actual or alleged failure on the part of City to inform
Consultant of non-compliance with any requirement imposes no additional
obligations on City nor does it waive any rights hereunder.
E. Requirements not Limiting. Requirements of specific coverage features or
limits contained in this Section are not intended as a limitation on coverage,
limits or other requirements, or a waiver of any coverage normally provided
by any insurance. Specific reference to a given coverage feature is for
purposes of clarification only as it pertains to a given issue and is not
intended by any party or insured to be all inclusive, or to the exclusion of
other coverage, or a waiver of any type. If the Consultant maintains higher
limits than the minimums shown above, the City requires and shall be
entitled to coverage for higher limits maintained by the Consultant. Any
available insurance proceeds in excess of the specified minimum limits of
insurance and coverage shall be available to the City.
Coastal Frontiers Corporation Page C-3 10-21
F. Self-insured Retentions. Any self-insured retentions must be declared to
and approved by City. City reserves the right to require that self-insured
retentions be eliminated, lowered, or replaced by a deductible. Self-
insurance will not be considered to comply with these requirements unless
approved by City.
G. City Remedies for Non -Compliance. If Consultant or any subconsultant fails
to provide and maintain insurance as required herein, then City shall have
the right but not the obligation, to purchase such insurance, to terminate this
Agreement, or to suspend Consultant's right to proceed until proper
evidence of insurance is provided. Any amounts paid by City shall, at City's
sole option, be deducted from amounts payable to Consultant or reimbursed
by Consultant upon demand.
H. Timely Notice of Claims. Consultant shall give City prompt and timely notice
of claims made or suits instituted that arise out of or result from Consultant's
performance under this Agreement, and that involve or may involve
coverage under any of the required liability policies. City assumes no
obligation or liability by such notice, but has the right (but not the duty) to
monitor the handling of any such claim or claims if they are likely to involve
City.
Consultant's Insurance. Consultant shall also procure and maintain, at its
own cost and expense, any additional kinds of insurance, which in its own
judgment may be necessary for its proper protection and prosecution of the
Work.
Coastal Frontiers Corporation Page C-4 10-22