HomeMy WebLinkAbout06 - Approval of On-Call PSA for Marine Engineering and Harbor-Related ServicesQ �EwPpRT
CITY OF
s NEWPORT BEACH
`q4�:09 City Council Staff Report
April 12, 2022
Agenda Item No. 6
TO: HONORABLE MAYOR AND MEMBERS OF THE CITY COUNCIL
FROM: David A. Webb, Public Works Director - 949-644-3311,
dawebb@newportbeachca.gov
PREPARED BY: Chris Miller, Administrative Manager, cmiller@newportbeachca.gov,
PHONE: 949-644-3043
TITLE: Approval of On -Call Professional Services Agreements for Marine
Engineering and Harbor -Related Services
ABSTRACT:
Current and future harbor- and ocean -related capital projects necessitate assistance from
outside firms that can provide specialized engineering and professional services in marine
and coastal engineering, and other related fields. Staff has completed a competitive
Request for Proposal (RFP) process for On -Call Marine Engineering and Harbor -Related
Services, and is requesting the City Council's approval to enter into three, On -Call
Professional Services Agreements with the following companies: Anchor QEA, LLC,
Moffatt & Nichol, and Noble Consultants, Inc. Each contract would be for a term of three
years and a total not -to -exceed contracting authority amount of $300,000.
RECOMMENDATION:
a) Determine this action is exempt from the California Environmental Quality Act (CEQA)
pursuant to Sections 15060(c)(2) and 15060(c)(3) of the CEQA Guidelines because
this action will not result in a physical change to the environment, directly or indirectly;
and
b) Approve On -Call Professional Services Agreements with Anchor QEA, LLC, Moffatt &
Nichol, and Noble Consultants, Inc., with each agreement being for a term of three
years and a total not -to -exceed amount of $300,000, and authorize the Mayor and
City Clerk to execute the agreements.
DISCUSSION:
The City of Newport Beach (City) uses private -sector consultants to fulfill various marine
engineering and scientific -related work associated with projects and operations within
Newport Harbor and the ocean beach areas. Currently, there is a list of capital and
maintenance projects associated with the harbor and ocean beach areas such as
in -harbor sand management and dredging at various public beaches, assistance with the
City's dredging permit (RGP-54), seawall and bulkhead replacements, planning and
permitting for marina replacement, and other harbor -related projects through the Public
Works or Harbor Departments.
6-1
Approval of On -Call Professional Services Agreements for
Marine Engineering and Harbor -Related Services
April 12, 2022
Page 2
The City issued an RFP in February 2022 for On -Call Marine Engineering Services.
Services requested in the RFP included design and permitting of various pier, dock, and
bulkhead projects; permitting programs; sampling and analysis plans for dredging and
sand management; biological and toxicity sampling and testing; preparation of record
drawings; various survey work; project management assistance; and more. The RFP was
advertised on the City's PlanetBids Portal, and staff also informed current marine
engineering consultants of the RFP's availability.
The City received three responses to the RFP, and those firms are also the current three
on-call marine engineering services consultants presently contracted with the City. Those
firms are Anchor QEA, LLC, Moffatt & Nichol, and Noble Consultants, Inc. Since the City
originally intended to select three consulting firms for this RFP, and since the three
responsive firms are also on-call consultants presently working for the City, an
independent evaluation and ranking matrix was not performed by a review team.
However, staff did review the proposals to confirm responsiveness to the RFP. Each of
the consultant's proposals included the required background, experience and work history
to assist with meeting the City's needs in the delivery of services. The sealed fee
schedules were opened and reviewed for the three firms, and were confirmed to be
reasonable and feasible after some negotiation. Service costs provided on an hourly basis
per project all remain competitive and favorable to the City, and consistent with other
engineering services of the same nature.
Staff now requests approval of three separate On -Call Professional Services Agreements
with Anchor QEA, LLC, Moffatt and Nichol, and Noble Consultants, Inc. Each of the three
agreements will be for a three-year term and a total not -to -exceed amount of $300,000
each.
FISCAL IMPACT:
The adopted budget(s) includes funding for these on-call services. Services for individual
projects will be expensed to the corresponding Public Works Department Maintenance
and Operating Budget and/or Capital Improvement Program (CIP) Budget.
ENVIRONMENTAL REVIEW:
Staff recommends the City Council find this action is not subject to the California
Environmental Quality Act (CEQA) pursuant to Sections 15060(c)(2) (the activity will not
result in a direct or reasonably foreseeable indirect physical change in the environment)
and 15060(c)(3) (the activity is not a project as defined in Section 15378) of the CEQA
Guidelines, California Code of Regulations, Title 14, Chapter 3, because it has no
potential for resulting in physical change to the environment, directly or indirectly.
NOTICING:
The agenda item has been noticed according to the Brown Act (72 hours in advance of
the meeting at which the City Council considers the item).
6-2
Approval of On -Call Professional Services Agreements for
Marine Engineering and Harbor -Related Services
April 12, 2022
Page 3
ATTACHMENTS:
Attachment A — Professional Services Agreement with Anchor QEA, LLC
Attachment B — Professional Services Agreement with Moffatt & Nichol
Attachment C — Professional Services Agreement with Noble Consultants, Inc.
6-3
ATTACHMENT A
ON-CALL PROFESSIONAL SERVICES AGREEMENT
WITH ANCHOR QEA, LLC FOR
ON-CALL MARINE ENGINEERING SERVICES
THIS ON-CALL PROFESSIONAL SERVICES AGREEMENT ("Agreement") is
made and entered into as of this 12th day of April, 2022 ("Effective Date"), by and between
the CITY OF NEWPORT BEACH, a California municipal corporation and charter city
("City"), and ANCHOR QEA, LLC, a Washington limited liability company ("Consultant"),
whose address is 9700 Research Drive, Irvine, California 92618, and is made with
reference to the following:
RECITALS
A. City is a municipal corporation duly organized and validly existing under the laws
of the State of California with the power to carry on its business as it is now being
conducted under the statutes of the State of California and the Charter of City.
B. City desires to engage Consultant to provide on-call marine engineering services
("Project").
C. Consultant possesses the skill, experience, ability, background, certification and
knowledge to provide the professional services described in this Agreement.
D. City has solicited and received a proposal from Consultant, has reviewed the
previous experience and evaluated the expertise of Consultant, and desires to
retain Consultant to render professional services under the terms and conditions
set forth in this Agreement.
NOW, THEREFORE, it is mutually agreed by and between the undersigned parties
as follows:
1. TERM
The term of this Agreement shall commence on the Effective Date, and shall
terminate on April 30, 2025, unless terminated earlier as set forth herein.
2. SERVICES TO BE PERFORMED
2.1 Consultant shall perform the on-call services described in the Scope of
Services attached hereto as Exhibit A and incorporated herein by reference ("Services"
or "Work"). Upon written request from the Project Administrator as defined herein,
Consultant shall provide a letter proposal for Services requested by the City (hereinafter
referred to as the "Letter Proposal"). The Letter Proposal shall include the following:
2.1.1 A detailed description of the Services to be provided;
2.1.2 The position of each person to be assigned to perform the Services,
and the name of the individuals to be assigned, if available;
and
2.1.3 The estimated number of hours and cost to complete the Services;
2.1.4 The time needed to finish the specific project.
2.2 No Services shall be provided until the Project Administrator has provided
written acceptance of the Letter Proposal. Once authorized to proceed, Consultant shall
diligently perform the duties in the approved Letter Proposal.
3. TIME OF PERFORMANCE
3.1 Time is of the essence in the performance of Services under this Agreement
and Consultant shall perform the Services in accordance with the schedule included in
Exhibit A and the Letter Proposal. In the absence of a specific schedule, the Services
shall be performed to completion in a diligent and timely manner. The failure by
Consultant to strictly adhere to the schedule set forth in Exhibit A and the Letter Proposal,
if any, or perform the Services in a diligent and timely manner may result in termination
of this Agreement by City.
3.2 Notwithstanding the foregoing, Consultant shall not be responsible for
delays due to causes beyond Consultant's reasonable control. However, in the case of
any such delay in the Services to be provided for the Project, each party hereby agrees
to provide notice within two (2) calendar days of the occurrence causing the delay to the
other party so that all delays can be addressed.
3.3 Consultant shall submit all requests for extensions of time for performance
in writing to the Project Administrator as defined herein not later than ten (10) calendar
days after the start of the condition that purportedly causes a delay. The Project
Administrator shall review all such requests and may grant reasonable time extensions
for unforeseeable delays that are beyond Consultant's control.
3.4 For all time periods not specifically set forth herein, Consultant shall
respond in the most expedient and appropriate manner under the circumstances, by
hand -delivery or mail.
4. COMPENSATION TO CONSULTANT
4.1 City shall pay Consultant for the Services on a time and expense not -to -
exceed basis in accordance with the provisions of this Section and the Letter Proposal
and the Schedule of Billing Rates attached hereto as Exhibit B and incorporated herein
by reference. Consultant's compensation for all Work performed in accordance with this
Agreement, including all reimbursable items and subconsultant fees, shall not exceed
Three Hundred Thousand Dollars and 001100 ($300,000.00), without prior written
authorization from City. No billing rate changes shall be made during the term of this
Agreement without the prior written approval of City.
Anchor QEA, LLC Page 2
6-5
4.2 Consultant shall submit monthly invoices to City describing the Work
performed the preceding month. Consultant's bills shall include the name of the person
who performed the Work, a brief description of the Services performed and/or the specific
task in the Scope of Services to which it relates, the date the Services were performed,
the number of hours spent on all Work billed on an hourly basis, and a description of any
reimbursable expenditures. City shall pay Consultant no later than thirty (30) calendar
days after approval of the monthly invoice by City staff.
4.3 City shall reimburse Consultant only for those costs or expenses specifically
identified in Exhibit B to this Agreement and the Letter Proposal or specifically approved
in writing in advance by City.
4.4 Consultant shall not receive any compensation for Extra Work performed
without the prior written authorization of City. As used herein, "Extra Work" means any
Work that is determined by City to be necessary for the proper completion of the Project,
but which is not included within the Scope of Services and which the parties did not
reasonably anticipate would be necessary at the execution of this Agreement.
Compensation for any authorized Extra Work shall be paid in accordance with the
Schedule of Billing Rates as set forth in Exhibit B and the Letter Proposal.
5. PROJECT MANAGER
5.1 Consultant shall designate a Project Manager, who shall coordinate all
phases of the Project. This Project Manager shall be available to City at all reasonable
times during the Agreement term. Consultant has designated Adam Gale to be its Project
Manager. Consultant shall not remove or reassign the Project Manager or any personnel
listed in Exhibit A or assign any new or replacement personnel to the Project without the
prior written consent of City. City's approval shall not be unreasonably withheld with
respect to the removal or assignment of non -key personnel.
5.2 Consultant, at the sole discretion of City, shall remove from the Project any
of its personnel assigned to the performance of Services upon written request of City.
Consultant warrants that it will continuously furnish the necessary personnel to complete
the Project on a timely basis as contemplated by this Agreement.
5.3 If Consultant is performing inspection services for City, the Project Manager
and any other assigned staff shall be equipped with a cellular phone to communicate with
City staff. The Project Manager's cellular phone number shall be provided to City.
6. ADMINISTRATION
This Agreement will be administered by the Public Works Department. City's
Director of Public Works or designee shall be the Project Administrator and shall have the
authority to act for City under this Agreement. The Project Administrator shall represent
City in all matters pertaining to the Services to be rendered pursuant to this Agreement.
Anchor QEA, LLC Page 3
7. CITY'S RESPONSIBILITIES
To assist Consultant in the execution of its responsibilities under this Agreement,
City agrees to provide access to and upon request of Consultant, one copy of all existing
relevant information on file at City. City will provide all such materials in a timely manner
so as not to cause delays in Consultant's Work schedule.
8. STANDARD OF CARE
8.1 All of the Services shall be performed by Consultant or under Consultant's
supervision. Consultant represents that it possesses the professional and technical
personnel required to perform the Services required by this Agreement, and that it will
perform all Services in a manner commensurate with community professional standards
and with the ordinary degree of skill and care that would be used by other reasonably
competent practitioners of the same discipline under similar circumstances. All Services
shall be performed by qualified and experienced personnel who are not employed by City.
By delivery of completed Work, Consultant certifies that the Work conforms to the
requirements of this Agreement, all applicable federal, state and local laws, and legally
recognized professional standards.
8.2 Consultant represents and warrants to City that it has, shall obtain, and shall
keep in full force and effect during the term hereof, at its sole cost and expense, all
licenses, permits, qualifications, insurance and approvals of whatsoever nature that is
legally required of Consultant to practice its profession. Consultant shall maintain a City
of Newport Beach business license during the term of this Agreement.
8.3 Consultant shall not be responsible for delay, nor shall Consultant be
responsible for damages or be in default or deemed to be in default by reason of strikes,
lockouts, accidents, acts of God, or the failure of City to furnish timely information or to
approve or disapprove Consultant's Work promptly, or delay or faulty performance by
City, contractors, or governmental agencies.
9. HOLD HARMLESS
9.1 To the fullest extent permitted by law, Consultant shall indemnify, defend
and hold harmless City, its City Council, boards and commissions, officers, agents,
volunteers, employees and any person or entity owning or otherwise in legal control of
the property upon which Consultant performs the Project and/or Services contemplated
by this Agreement (collectively, the "Indemnified Parties"), from and against any and all
claims (including, without limitation, claims for bodily injury, death or damage to property),
demands, obligations, damages, actions, causes of action, suits, losses, judgments,
fines, penalties, liabilities, costs and expenses (including, without limitation, attorneys'
fees, disbursements and court costs) of every kind and nature whatsoever (individually,
a Claim; collectively, "Claims"), and which relate (directly or indirectly) to the negligence,
recklessness, or willful misconduct of the Consultant or its principals, officers, agents,
employees, vendors, suppliers, subconsultants, subcontractors, anyone employed
Anchor QEA, LLC Page 4
6-7
directly or indirectly by any of them or for whose acts they may be liable, or any or all of
them.
9.2 Notwithstanding the foregoing, nothing herein shall be construed to require
Consultant to indemnify the Indemnified Parties from any Claim arising from the sole
negligence, active negligence or willful misconduct of the Indemnified Parties. Nothing in
this indemnity shall be construed as authorizing any award of attorneys' fees in any action
on or to enforce the terms of this Agreement. This indemnity shall apply to all claims and
liability regardless of whether any insurance policies are applicable. The policy limits do
not act as a limitation upon the amount of indemnification to be provided by the
Consultant.
10. INDEPENDENT CONTRACTOR
It is understood that City retains Consultant on an independent contractor basis
and Consultant is not an agent or employee of City. The manner and means of
conducting the Work are under the control of Consultant, except to the extent they are
limited by statute, rule or regulation and the expressed terms of this Agreement. No civil
service status or other right of employment shall accrue to Consultant or its employees.
Nothing in this Agreement shall be deemed to constitute approval for Consultant or any
of Consultant's employees or agents, to be the agents or employees of City. Consultant
shall have the responsibility for and control over the means of performing the Work,
provided that Consultant is in compliance with the terms of this Agreement. Anything in
this Agreement that may appear to give City the right to direct Consultant as to the details
of the performance of the Work or to exercise a measure of control over Consultant shall
mean only that Consultant shall follow the desires of City with respect to the results of the
Services.
11. COOPERATION
Consultant agrees to work closely and cooperate fully with City's designated
Project Administrator and any other agencies that may have jurisdiction or interest in the
Work to be performed. City agrees to cooperate with the Consultant on the Project.
12. CITY POLICY
Consultant shall discuss and review all matters relating to policy and Project
direction with City's Project Administrator in advance of all critical decision points in order
to ensure the Project proceeds in a manner consistent with City goals and policies.
13. PROGRESS
Consultant is responsible for keeping the Project Administrator informed on a
regular basis regarding the status and progress of the Project, activities performed and
planned, and any meetings that have been scheduled or are desired.
Anchor QEA, LLC Page 5
6-8
14. INSURANCE
Without limiting Consultant's indemnification of City, and prior to commencement
of Work, Consultant shall obtain, provide and maintain at its own expense during the term
of this Agreement or for other periods as specified in this Agreement, policies of insurance
of the type, amounts, terms and conditions described in the Insurance Requirements
attached hereto as Exhibit C, and incorporated herein by reference.
15. PROHIBITION AGAINST ASSIGNMENTS AND TRANSFERS
Except as specifically authorized under this Agreement, the Services to be
provided under this Agreement shall not be assigned, transferred contracted or
subcontracted out without the prior written approval of City. Any of the following shall be
construed as an assignment: The sale, assignment, transfer or other disposition of any
of the issued and outstanding capital stock of Consultant, or of the interest of any general
partner or joint venturer or syndicate member or cotenant if Consultant is a partnership or
joint -venture or syndicate or co -tenancy, which shall result in changing the control of
Consultant. Control means fifty percent (50%) or more of the voting power or twenty-five
percent (25%) or more of the assets of the corporation, partnership or joint -venture.
16. SUBCONTRACTING
The subcontractors authorized by City, if any, to perform Work on this Project are
identified in Exhibit A and the Letter Proposal. Consultant shall be fully responsible to
City for all acts and omissions of any subcontractor. Nothing in this Agreement shall
create any contractual relationship between City and any subcontractor nor shall it create
any obligation on the part of City to pay or to see to the payment of any monies due to
any such subcontractor other than as otherwise required by law. City is an intended
beneficiary of any Work performed by the subcontractor for purposes of establishing a
duty of care between the subcontractor and City. Except as specifically authorized herein,
the Services to be provided under this Agreement shall not be otherwise assigned,
transferred, contracted or subcontracted out without the prior written approval of City.
17. OWNERSHIP OF DOCUMENTS
17.1 Each and every report, draft, map, record, plan, document and other writing
produced, including but not limited to, websites, blogs, social media accounts and
applications (hereinafter "Documents"), prepared or caused to be prepared by Consultant,
its officers, employees, agents and subcontractors, in the course of implementing this
Agreement, shall become the exclusive property of City, and City shall have the sole right
to use such materials in its discretion without further compensation to Consultant or any
other party. Additionally, all material posted in cyberspace by Consultant, its officers,
employees, agents and subcontractors, in the course of implementing this Agreement,
shall become the exclusive property of City, and City shall have the sole right to use such
materials in its discretion without further compensation to Consultant or any other party.
Consultant shall, at Consultant's expense, provide such Documents, including all logins
and password information to City upon prior written request.
Anchor QEA, LLC Page 6
6-9
17.2 Documents, including drawings and specifications, prepared by Consultant
pursuant to this Agreement are not intended or represented to be suitable for reuse by
City or others on any other project. Any use of completed Documents for other projects
and any use of incomplete Documents without specific written authorization from
Consultant will be at City's sole risk and without liability to Consultant. Further, any and
all liability arising out of changes made to Consultant's deliverables under this Agreement
by City or persons other than Consultant is waived against Consultant, and City assumes
full responsibility for such changes unless City has given Consultant prior notice and has
received from Consultant written consent for such changes.
17.3 Computer Aided Design and Drafting ("CADD") data delivered to City shall
include the professional stamp of the engineer or architect in charge of or responsible for
the Work. City agrees that Consultant shall not be liable for claims, liabilities or losses
arising out of, or connected with (a) the modification or misuse by City, or anyone
authorized by City, of CADD data, or (b) any use by City, or anyone authorized by City,
of CADD data for additions to this Project, for the completion of this Project by others, or
for any other Project, excepting only such use as is authorized, in writing, by Consultant.
By acceptance of CADD data, City agrees to indemnify Consultant for damages and
liability resulting from the modification or misuse of such CADD data. All original drawings
shall be submitted to City in the version of AutoCAD used by the City in .dwg file format,
and should comply with the City's digital submission requirements for improvement plans
available from the City's Public Works Department.
17.4 All improvement and/or construction plans shall be plotted on standard
twenty-four inch (24") by thirty-six inch (36") paper size. Consultant shall provide to City
digital 'As -Built' drawings in both AutoCAD and Adobe PDF file format within thirty (30)
days after finalization of the Project.
18. CONFIDENTIALITY
All Documents, including drafts, preliminary drawings or plans, notes and
communications that result from the Services in this Agreement, shall be kept confidential
unless City expressly authorizes in writing the release of information.
19. INTELLECTUAL PROPERTY INDEMNITY
Consultant shall defend and indemnify City, its agents, officers, representatives
and employees against any and all liability, including costs, for infringement or alleged
infringement of any United States' letters patent, trademark, or copyright, including costs,
contained in Consultant's Documents provided under this Agreement.
20. RECORDS
Consultant shall keep records and invoices in connection with the Services to be
performed under this Agreement. Consultant shall maintain complete and accurate
records with respect to the costs incurred under this Agreement and any Services,
expenditures and disbursements charged to City, for a minimum period of three (3) years,
or for any longer period required by law, from the date of final payment to Consultant
Anchor QEA, LLC Page 7
6-10
under this Agreement. All such records and invoices shall be clearly identifiable.
Consultant shall allow a representative of City to examine, audit and make transcripts or
copies of such records and invoices during regular business hours. Consultant shall allow
inspection of all Work, data, Documents, proceedings and activities related to the
Agreement for a period of three (3) years from the date of final payment to Consultant
under this Agreement.
21. WITHHOLDINGS
City may withhold payment to Consultant of any disputed sums until satisfaction of
the dispute with respect to such payment. Such withholding shall not be deemed to
constitute a failure to pay according to the terms of this Agreement. Consultant shall not
discontinue Work as a result of such withholding. Consultant shall have an immediate
right to appeal to the City Manager or designee with respect to such disputed sums.
Consultant shall be entitled to receive interest on any withheld sums at the rate of return
that City earned on its investments during the time period, from the date of withholding of
any amounts found to have been improperly withheld.
22. ERRORS AND OMISSIONS
In the event of errors or omissions that are due to the negligence or professional
inexperience of Consultant which result in expense to City greater than what would have
resulted if there were not errors or omissions in the Work accomplished by Consultant,
the additional design, construction and/or restoration expense shall be borne by
Consultant. Nothing in this Section is intended to limit City's rights under the law or any
other sections of this Agreement.
23. CITY'S RIGHT TO EMPLOY OTHER CONSULTANTS
City reserves the right to employ other Consultants in connection with the Project.
24. CONFLICTS OF INTEREST
24.1 Consultant or its employees may be subject to the provisions of the
California Political Reform Act of 1974 (the "Act") and/or Government Code §§ 1090 et
seq., which (1) require such persons to disclose any financial interest that may
foreseeably be materially affected by the Work performed under this Agreement, and (2)
prohibit such persons from making, or participating in making, decisions that will
foreseeably financially affect such interest.
24.2 If subject to the Act and/or Government Code §§ 1090 et seq., Consultant
shall conform to all requirements therein. Failure to do so constitutes a material breach
and is grounds for immediate termination of this Agreement by City. Consultant shall
indemnify and hold harmless City for any and all claims for damages resulting from
Consultant's violation of this Section.
Anchor QEA, LLC Page 8
6-11
25. NOTICES
25.1 All notices, demands, requests or approvals, including any change in
mailing address, to be given under the terms of this Agreement shall be given in writing,
and conclusively shall be deemed served when delivered personally, or on the third
business day after the deposit thereof in the United States mail, postage prepaid, first-
class mail, addressed as hereinafter provided.
25.2 All notices, demands, requests or approvals from Consultant to City shall
be addressed to City at:
Attn: Director of Public Works
Public Works Department
City of Newport Beach
100 Civic Center Drive
PO Box 1768
Newport Beach, CA 92658
25.3 All notices, demands, requests or approvals from City to Consultant shall
be addressed to Consultant at:
Attn: Adam Gale
Anchor QEA, LLC
1201 3rd Avenue, Suite 2600
Seattle, Washington 98101
26. CLAIMS
Unless a shorter time is specified elsewhere in this Agreement, before making its
final request for payment under this Agreement, Consultant shall submit to City, in writing,
all claims for compensation under or arising out of this Agreement. Consultant's
acceptance of the final payment shall constitute a waiver of all claims for compensation
under or arising out of this Agreement except those previously made in writing and
identified by Consultant in writing as unsettled at the time of its final request for payment.
Consultant and City expressly agree that in addition to any claims filing requirements set
forth in the Agreement, Consultant shall be required to file any claim Consultant may have
against City in strict conformance with the Government Claims Act (Government Code
sections 900 et seq.).
27. TERMINATION
27.1 In the event that either party fails or refuses to perform any of the provisions
of this Agreement at the time and in the manner required, that party shall be deemed in
default in the performance of this Agreement. If such default is not cured within a period
of two (2) calendar days, or if more than two (2) calendar days are reasonably required
to cure the default and the defaulting party fails to give adequate assurance of due
performance within two (2) calendar days after receipt of written notice of default,
specifying the nature of such default and the steps necessary to cure such default, and
Anchor QEA, LLC Page 9
6-12
thereafter diligently take steps to cure the default, the non -defaulting party may terminate
the Agreement forthwith by giving to the defaulting party written notice thereof.
27.2 Notwithstanding the above provisions, City shall have the right, at its sole
and absolute discretion and without cause, of terminating this Agreement at any time by
giving no less than seven (7) calendar days' prior written notice to Consultant. In the
event of termination under this Section, City shall pay Consultant for Services
satisfactorily performed and costs incurred up to the effective date of termination for which
Consultant has not been previously paid. On the effective date of termination, Consultant
shall deliver to City all reports, Documents and other information developed or
accumulated in the performance of this Agreement, whether in draft or final form.
28. STANDARD PROVISIONS
28.1 Recitals. City and Consultant acknowledge that the above Recitals are true
and correct and are hereby incorporated by reference into this Agreement.
28.2 Compliance with all Laws. Consultant shall, at its own cost and expense,
comply with all statutes, ordinances, regulations and requirements of all governmental
entities, including federal, state, county or municipal, whether now in force or hereinafter
enacted. In addition, all Work prepared by Consultant shall conform to applicable City,
county, state and federal laws, rules, regulations and permit requirements and be subject
to approval of the Project Administrator and City.
28.3 Waiver. A waiver by either party of any breach, of any term, covenant or
condition contained herein shall not be deemed to be a waiver of any subsequent breach
of the same or any other term, covenant or condition contained herein, whether of the
same or a different character.
28.4 Integrated Contract. This Agreement represents the full and complete
understanding of every kind or nature whatsoever between the parties hereto, and all
preliminary negotiations and agreements of whatsoever kind or nature are merged herein.
No verbal agreement or implied covenant shall be held to vary the provisions herein.
28.5 Conflicts or Inconsistencies. In the event there are any conflicts or
inconsistencies between this Agreement and the Scope of Services or any other
attachments attached hereto, the terms of this Agreement shall govern.
28.6 Interpretation. The terms of this Agreement shall be construed in
accordance with the meaning of the language used and shall not be construed for or
against either party by reason of the authorship of the Agreement or any other rule of
construction which might otherwise apply.
28.7 Amendments. This Agreement may be modified or amended only by a
written document executed by both Consultant and City and approved as to form by the
City Attorney.
Anchor QEA, LLC Page 10
6-13
28.8 Severability. If any term or portion of this Agreement is held to be invalid,
illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining
provisions of this Agreement shall continue in full force and effect.
28.9 Controllinq Law and Venue. The laws of the State of California shall govern
this Agreement and all matters relating to it and any action brought relating to this
Agreement shall be adjudicated in a court of competent jurisdiction in the County of
Orange, State of California.
28.10 Equal Opportunity Employment. Consultant represents that it is an equal
opportunity employer and it shall not discriminate against any subcontractor, employee
or applicant for employment because race, religious creed, color, national origin,
ancestry, physical handicap, medical condition, marital status, sex, sexual orientation,
age or any other impermissible basis under law.
28.11 No Attorneys' Fees. In the event of any dispute or legal action arising under
this Agreement, the prevailing party shall not be entitled to attorneys' fees.
28.12 Counterparts. This Agreement may be executed in two (2) or more
counterparts, each of which shall be deemed an original and all of which together shall
constitute one (1) and the same instrument.
[SIGNATURES ON NEXT PAGE]
Anchor QEA, LLC Page 11
6-14
IN WITNESS WHEREOF, the parties have caused this Agreement to be executed
on the dates written below.
APPROVED AS TO FORM:
CITY ATTORNEY'S OFFICE
Date: 3 -91 -2 -2 -
By:
r2Ir22
By: 1
a n C. � asl�alzs
Atto e
ATTEST:
Date:
Leilani I. Brown
City Clerk
CITY OF NEWPORT BEACH,
a California municipal corporation
Date:
Bv:
Kevin Muldoon
Mayor
CONSULTANT: Anchor QEA, LLC, a
Washington limited liability company
Date:
By:
Steve Cappellino
Member
Date:
By:
John Verduin
Member
[END OF SIGNATURES]
Attachments: Exhibit A -- Scope of Services
Exhibit B — Schedule of Billing Rates
Exhibit C — Insurance Requirements
Anchor QEA, LLC Page 12
6-15
EXHIBIT
SCOPE OF SERVICES
The following is a list of the services requested as part of this agreement for on-call
marine engineering services. Consultant will be responsible for deploying and storing any
vessels or equipment related to the services provided under this agreement. The services
requested include, but are not limited to, the following:
1. Assist in the design and permitting of docks, piers, floats, wharfs, gangways for
public facilities, with attention to Americans with Disabilities Act (ADA) and
other regulatory requirements.
2. Assist in the design and permitting of dredging projects within docks, marinas,
small confined channels or larger main channels, using either the City's RGP-
54 dredging permit or the traditional Individual Permit process (California
Coastal Commission, Corps of Engineers, Water Board).
3. Collect sediment samples and generate grain size analysis reports.
4. Assist in the detailed management of the City's existing, five-year Regional
General Permit (RGP-54) as well as negotiating any intermediate
improvements to the program, as needed.
5. Provide various bathymetry surveys within docks, marinas, small confined
channels or larger main channels.
6. Prepare dredged material Sampling and Analysis Plans (SAP's) and Sampling
and Analysis Reports (SAR's) in support of permitting activities with regulatory
agencies including the Dredged Material Management Team (DMMT) and
individual regulatory and resources agencies, as needed.
7. Conduct field collection of marine sediments and marine test organisms as
required for chemical and biological testing during a typical permitting project
(usually dredging).
8. Conduct chemical, biological and toxicity testing/analyses of bulk sediments
and marine test organisms to support chemical and biological testing during a
typical permitting project (usually dredging).
9. Conduct Caulerpa and eelgrass surveys, or assist in managing these studies,
including the harbor -wide biennial eelgrass survey as part of the "Eelgrass
Protection and Mitigation Plan for Shallow Waters in Lower Newport Bay: An
Ecosystem Based Management Approach."
Anchor QEA, LLC Page A-1 6-16
10. Assist in the design and permitting of bulkheads and their structural
components for public facilities or property owned by the City.
11. Project management with various harbor related tasks to assist the Public
Works Department. Projects may include larger dock/bulkhead construction
projects, permitting programs, organizing public outreach campaigns, or other
projects as assigned by Public Works.
12. Depending upon the characteristics of a project and its potential for significant
environmental effects, a CEQA review may be needed. For the scope of such
work, Consultant may need to prepare an Initial Study.
13. Preparation of record drawings.
14. Present projects, findings, information etc. at various public meetings including
the City Council, Harbor Commission, various ad hoc committee meetings and
other outreach events as required.
15. Other marine and/or harbor related engineering and professional services as
needed.
Anchor QEA, LLC Page A-2 6-17
EXHIBIT B
SCHEDULE OF BILLING RATES
Anchor QEA, LLC Page B-1 6-18
EXHIBIT B
BILLING RATES
Professional Level Hourly Rates
Principal............................................................................................................................•-.---...............................................
$297
SeniorManager..................................................................................................................................................................
$265
Manager............. ...................................................................................................................................................................
$248
SeniorStaff...........................................................................................................................................................................
$219
Staff3.....................................................................................................................................................................................
$193
Staff2..................................................................................................................................................................................
$173
Staff1.....................................................................................................................................................................................
$146
SeniorCAD' Designer.........................................................................................................
........................................... $152
CADDesigner......................................................................................................................................................................
$129
Technician.......................................................................................................................................................
.................... $129
SeniorTechnical Editor....................................................................................................................................................
$155
TechnicalEditor..................................................................................................................................................................
$129
SeniorProject Coordinator............................................................................................................................................
$148
Project Coordinator.................................................................................................
. ............................. $122
...........................
Special Hourly Rates
Nationalexpert consultant............................................................................................................................................
5492
All work by a testifying expert. ............................
-- ................................................ 1.5 times professional level rate
ExpertAdvisor.....................................................................................................................................................................
$364
EXPENSE BILLING RATES
Expense Rates
Computer Modeling (per hour)...........................................•-------------.........----........-----......... ...........$10.00
.........................
Graphic Plots (varies with plot size).................................................................................................................... $3-$6/sf
Mileage (per mile) ..................... ........................................... .................................................... Current Federal Standard
FEE ON LABOR AND EXPENSE CHARGES
Subcontracts/subconsultants.........................................................................................................................................10%
Travel and other direct costs..........................................................................................................................................10%
Fieldequipment and supplies......................................................................................................................................10%
CAD: Computer Aided Design
6-19
EXHIBIT C
INSURANCE REQUIREMENTS — PROFESSIONAL SERVICES
Provision of Insurance. Without limiting Consultant's indemnification of City, and
prior to commencement of Work, Consultant shall obtain, provide and maintain at
its own expense during the term of this Agreement, policies of insurance of the
type and amounts described below and in a form satisfactory to City. Consultant
agrees to provide insurance in accordance with requirements set forth here. If
Consultant uses existing coverage to comply and that coverage does not meet
these requirements, Consultant agrees to amend, supplement or endorse the
existing coverage.
2. Acceptable Insurers. All insurance policies shall be issued by an insurance
company currently authorized by the Insurance Commissioner to transact
business of insurance in the State of California, with an assigned policyholders'
Rating of A- (or higher) and Financial Size Category Class VII (or larger) in
accordance with the latest edition of Best's Key Rating Guide, unless otherwise
approved by the City's Risk Manager.
3. Coverage Requirements.
A. Workers' Compensation Insurance. Consultant shall maintain Workers'
Compensation Insurance, statutory limits, and Employer's Liability
Insurance with limits of at least one million dollars ($1,000,000) each
accident for bodily injury by accident and each employee for bodily injury by
disease in accordance with the laws of the State of California, Section 3700
of the Labor Code.
Consultant shall submit to City, along with the certificate of insurance, a
Waiver of Subrogation endorsement in favor of City, its City Council, boards
and commissions, officers, agents, volunteers, employees and any person
or entity owning or otherwise in legal control of the property upon which
Consultant performs the Project and/or Services contemplated by this
Agreement.
B. General Liability Insurance. Consultant shall maintain commercial general
liability insurance, and if necessary umbrella liability insurance, with
coverage at least as broad as provided by Insurance Services Office form
CG 00 01, in an amount not less than one million dollars ($1,000,000) per
occurrence, two million dollars ($2,000,000) general aggregate. The policy
shall cover liability arising from premises, operations, personal and
advertising injury, and liability assumed under an insured contract (including
the tort liability of another assumed in a business contract).
C. Automobile Liability Insurance. Consultant shall maintain automobile
insurance at least as broad as Insurance Services Office form CA 00 01
covering bodily injury and property damage for all activities of Consultant
arising out of or in connection with Work to be performed under this
Anchor QEA, LLC Page C-1 6-20
Agreement, including coverage for any owned, hired, non -owned or rented
vehicles, in an amount not less than one million dollars ($1,000,000)
combined single limit each accident.
D. Professional Liability (Errors & Omissions) Insurance. Consultant shall
maintain professional liability insurance that covers the Services to be
performed in connection with this Agreement, in the minimum amount of
one million dollars ($1,000,000) per claim and two million dollars
($2,000,000) in the aggregate. Any policy inception date, continuity date,
or retroactive date must be before the Effective Date of this Agreement and
Consultant agrees to maintain continuous coverage through a period no
less than three years after completion of the Services required by this
Agreement.
4. Other Insurance Requirements. The policies are to contain, or be endorsed to
contain, the following provisions:
A. Waiver of Subrogation. All insurance coverage maintained or procured
pursuant to this Agreement shall be endorsed to waive subrogation against
City, its City Council, boards and commissions, officers, agents, volunteers,
employees and any person or entity owning or otherwise in legal control of
the property upon which Consultant performs the Project and/or Services
contemplated by this Agreement or shall specifically allow Consultant or
others providing insurance evidence in compliance with these requirements
to waive their right of recovery prior to a loss. Consultant hereby waives its
own right of recovery against City, and shall require similar written express
waivers from each of its subconsultants.
B. Additional Insured Status. All liability policies including general liability,
excess liability, pollution liability, and automobile liability, if required, but not
including professional liability, shall provide or be endorsed to provide that
City, its City Council, boards and commissions, officers, agents, volunteers,
employees and any person or entity owning or otherwise in legal control of
the property upon which Consultant performs the Project and/or Services
contemplated by this Agreement shall be included as insureds under such
policies.
C. Primary and Non Contributory. All liability coverage shall apply on a primary
basis and shall not require contribution from any insurance or self-insurance
maintained by City.
D. Notice of Cancellation. All policies shall provide City with thirty (30)
calendar days' notice of cancellation (except for nonpayment for which ten
(10) calendar days' notice is required) or nonrenewal of coverage for each
required coverage.
5. Additional Agreements Between the Parties. The parties hereby agree to the
following:
Anchor QEA, LLC Page C-2 6-21
A. Evidence of Insurance. Consultant shall provide certificates of insurance to
City as evidence of the insurance coverage required herein, along with a
waiver of subrogation endorsement for workers' compensation and other
endorsements as specified herein for each coverage. Insurance certificates
and endorsement must be approved by City's Risk Manager prior to
commencement of performance. Current certification of insurance shall be
kept on file with City at all times during the term of this Agreement. The
certificates and endorsements for each insurance policy shall be signed by
a person authorized by that insurer to bind coverage on its behalf. At least
fifteen (15) days prior to the expiration of any such policy, evidence of
insurance showing that such insurance coverage has been renewed or
extended shall be filed with the City. If such coverage is cancelled or
reduced, Consultant shall, within ten (10) days after receipt of written notice
of such cancellation or reduction of coverage, file with the City evidence of
insurance showing that the required insurance has been reinstated or has
been provided through another insurance company or companies. City
reserves the right to require complete, certified copies of all required
insurance policies, at any time.
B. Cit 's Right to Revise Requirements. City reserves the right at any time
during the term of the Agreement to change the amounts and types of
insurance required by giving Consultant sixty (60) calendar days' advance
written notice of such change. if such change results in substantial
additional cost to Consultant, City and Consultant may renegotiate
Consultant's compensation.
C. Right to Review Subcontracts. Consultant agrees that upon request, all
agreements with subcontractors or others with whom Consultant enters into
contracts with on behalf of City will be submitted to City for review. Failure
of City to request copies of such agreements will not impose any liability on
City, or its employees. Consultant shall require and verify that all
subcontractors maintain insurance meeting all the requirements stated
herein, and Consultant shall ensure that City is an additional insured on
insurance required from subcontractors. For CGL coverage,
subcontractors shall provide coverage with a format at least as broad as CG
20 38 04 13.
D. Enforcement of Agreement Provisions. Consultant acknowledges and
agrees that any actual or alleged failure on the park of City to inform
Consultant of non-compliance with any requirement imposes no additional
obligations on City nor does it waive any rights hereunder.
E. Requirements not Limiting. Requirements of specific coverage features or
limits contained in this Section are not intended as a limitation on coverage,
limits or other requirements, or a waiver of any coverage normally provided
by any insurance. Specific reference to a given coverage feature is for
purposes of clarification only as it pertains to a given issue and is not
intended by any party or insured to be all inclusive, or to the exclusion of
other coverage, or a waiver of any type. If the Consultant maintains higher
Anchor QEA, LLC Page C-3 6.22
limits than the minimums shown above, the City requires and shall be
entitled to coverage for higher limits maintained by the Consultant. Any
available insurance proceeds in excess of the specified minimum limits of
insurance and coverage shall be available to the City.
F. Self-insured Retentions. Any self-insured retentions must be declared to
and approved by City. City reserves the right to require that self-insured
retentions be eliminated, lowered, or replaced by a deductible. Self-
insurance will not be considered to comply with these requirements unless
approved by City.
G. City Remedies for Non -Compliance. If Consultant or any subconsultant fails
to provide and maintain insurance as required herein, then City shall have
the right but not the obligation, to purchase such insurance, to terminate this
Agreement, or to suspend Consultant's right to proceed until proper
evidence of insurance is provided. Any amounts paid by City shall, at City's
sole option, be deducted from amounts payable to Consultant or reimbursed
by Consultant upon demand.
H. Timely Notice of Claims. Consultant shall give City prompt and timely notice
of claims made or suits instituted that arise out of or result from Consultant's
performance under this Agreement, and that involve or may involve
coverage under any of the required liability policies. City assumes no
obligation or liability by such notice, but has the right (but not the duty) to
monitor the handling of any such claim or claims if they are likely to involve
City.
Consultant's Insurance. Consultant shall also procure and maintain, at its
own cost and expense, any additional kinds of insurance, which in its own
judgment may be necessary for its proper protection and prosecution of the
Work.
Anchor QEA, LLC Page C-4 6-23
ATTACHMENT B
ON-CALL PROFESSIONAL SERVICES AGREEMENT
WITH MOFFATT & NICHOL FOR
ON-CALL MARINE ENGINEERING SERVICES
THIS ON-CALL PROFESSIONAL SERVICES AGREEMENT ("Agreement") is
made and entered into as of this 12th day of April, 2022 ("Effective Date"), by and
between the CITY OF NEWPORT BEACH, a California municipal corporation and
charter city ("City"), and MOFFATT & NICHOL, a California corporation ("Consultant"),
whose address is 555 Anton Boulevard, Suite 400, Costa Mesa, California 92626, and
is made with reference to the following:
RECITALS
A. City is a municipal corporation duly organized and validly existing under the laws
of the State of California with the power to carry on its business as it is now being
conducted under the statutes of the State of California and the Charter of City.
B. City desires to engage Consultant to provide on-call marine engineering services
("Project").
C. Consultant possesses the skill, experience, ability, background, certification and
knowledge to provide the professional services described in this Agreement.
D. City has solicited and received a proposal from Consultant, has reviewed the
previous experience and evaluated the expertise of Consultant, and desires to
retain Consultant to render professional services under the terms and conditions
set forth in this Agreement.
NOW, THEREFORE, it is mutually agreed by and between the undersigned
parties as follows:
1. TERM
The term of this Agreement shall commence on the Effective Date, and shall
terminate on April 30, 2025, unless terminated earlier as set forth herein.
2. SERVICES TO BE PERFORMED
2.1 Consultant shall perform the on-call services described in the Scope of
Services attached hereto as Exhibit A and incorporated herein by reference ("Services"
or "Work"). Upon written request from the Project Administrator as defined herein,
Consultant shall provide a letter proposal for Services requested by the City (hereinafter
referred to as the "Letter Proposal"). The Letter Proposal shall include the following:
2.1.1 A detailed description of the Services to be provided;
2.1.2 The position of each person to be assigned to perform the
Services, and the name of the individuals to be assigned, if available;
6-24
and
2.1.3 The estimated number of hours and cost to complete the Services,
2.1.4 The time needed to finish the specific project.
2.2 No Services shall be provided until the Project Administrator has provided
written acceptance of the Letter Proposal. Once authorized to proceed, Consultant
shall diligently perform the duties in the approved Letter Proposal.
3. TIME OF PERFORMANCE
3.1 Time is of the essence in the performance of Services under this
Agreement and Consultant shall perform the Services in accordance with the schedule
included in Exhibit A and the Letter Proposal. In the absence of a specific schedule, the
Services shall be performed to completion in a diligent and timely manner. The failure
by Consultant to strictly adhere to the schedule set forth in Exhibit A and the Letter
Proposal, if any, or perform the Services in a diligent and timely manner may result in
termination of this Agreement by City.
3.2 Notwithstanding the foregoing, Consultant shall not be responsible for
delays due to causes beyond Consultant's reasonable control. However, in the case of
any such delay in the Services to be provided for the Project, each party hereby agrees
to provide notice within two (2) calendar days of the occurrence causing the delay to the
other party so that all delays can be addressed.
3.3 Consultant shall submit all requests for extensions of time for performance
in writing to the Project Administrator as defined herein not later than ten (10) calendar
days after the start of the condition that purportedly causes a delay. The Project
Administrator shall review all such requests and may grant reasonable time extensions
for unforeseeable delays that are beyond Consultant's control.
3.4 For all time periods not specifically set forth herein, Consultant shall
respond in the most expedient and appropriate manner under the circumstances, by
hand -delivery or mail.
4. COMPENSATION TO CONSULTANT
4.1 City shall pay Consultant for the Services on a time and expense not -to -
exceed basis in accordance with the provisions of this Section and the Letter Proposal
and the Schedule of Billing Rates attached hereto as Exhibit B and incorporated herein
by reference. Consultant's compensation for all Work performed in accordance with this
Agreement, including all reimbursable items and subconsultant fees, shall not exceed
Three Hundred Thousand Dollars and 001100 ($300,000.00), without prior written
authorization from City. No billing rate changes shall be made during the term of this
Agreement without the prior written approval of City.
Moffatt & Nichol Page 2
6-25
4.2 Consultant shall submit monthly invoices to City describing the Work
performed the preceding month. Consultant's bills shall include the name of the person
who performed the Work, a brief description of the Services performed and/or the
specific task in the Scope of Services to which it relates, the date the Services were
performed, the number of hours spent on all Work billed on an hourly basis, and a
description of any reimbursable expenditures. City shall pay Consultant no later than
thirty (30) calendar days after approval of the monthly invoice by City staff.
4.3 City shall reimburse Consultant only for those costs or expenses
specifically identified in Exhibit B to this Agreement and the Letter Proposal or
specifically approved in writing in advance by City.
4.4 Consultant shall not receive any compensation for Extra Work performed
without the prior written authorization of City. As used herein, "Extra Work" means any
Work that is determined by City to be necessary for the proper completion of the
Project, but which is not included within the Scope of Services and which the parties did
not reasonably anticipate would be necessary at the execution of this Agreement.
Compensation for any authorized Extra Work shall be paid in accordance with the
Schedule of Billing Rates as set forth in Exhibit B and the Letter Proposal.
5. PROJECT MANAGER
5.1 Consultant shall designate a Project Manager, who shall coordinate all
phases of the Project. This Project Manager shall be available to City at all reasonable
times during the Agreement term. Consultant has designated Kim Garvey to be its
Project Manager. Consultant shall not remove or reassign the Project Manager or any
personnel listed in Exhibit A or assign any new or replacement personnel to the Project
without the prior written consent of City. City's approval shall not be unreasonably
withheld with respect to the removal or assignment of non -key personnel.
5.2 Consultant, at the sole discretion of City, shall remove from the Project
any of its personnel assigned to the performance of Services upon written request of
City. Consultant warrants that it will continuously furnish the necessary personnel to
complete the Project on a timely basis as contemplated by this Agreement.
5.3 If Consultant is performing inspection services for City, the Project
Manager and any other assigned staff shall be equipped with a cellular phone to
communicate with City staff. The Project Manager's cellular phone number shall be
provided to City.
6. ADMINISTRATION
This Agreement will be administered by the Public Works Department. City's
Director of Public Works or designee shall be the Project Administrator and shall have
the authority to act for City under this Agreement. The Project Administrator shall
represent City in all matters pertaining to the Services to be rendered pursuant to this
Agreement.
Moffatt & Nichol Page 3
6-26
7. CITY'S RESPONSIBILITIES
To assist Consultant in the execution of its responsibilities under this Agreement,
City agrees to provide access to and upon request of Consultant, one copy of all
existing relevant information on file at City. City will provide all such materials in a
timely manner so as not to cause delays in Consultant's Work schedule.
8. STANDARD OF CARE
8.1 All of the Services shall be performed by Consultant or under Consultant's
supervision. Consultant represents that it possesses the professional and technical
personnel required to perform the Services required by this Agreement, and that it will
perform all Services in a manner commensurate with community professional standards
and with the ordinary degree of skill and care that would be used by other reasonably
competent practitioners of the same discipline under similar circumstances. All
Services shall be performed by qualified and experienced personnel who are not
employed by City. By delivery of completed Work, Consultant certifies that the Work
conforms to the requirements of this Agreement, all applicable federal, state and local
laws, and legally recognized professional standards.
8.2 Consultant represents and warrants to City that it has, shall obtain, and
shall keep in full force and effect during the term hereof, at its sole cost and expense, all
licenses, permits, qualifications, insurance and approvals of whatsoever nature that is
legally required of Consultant to practice its profession. Consultant shall maintain a City
of Newport Beach business license during the term of this Agreement.
8.3 Consultant shall not be responsible for delay, nor shall Consultant be
responsible for damages or be in default or deemed to be in default by reason of strikes,
lockouts, accidents, acts of God, or the failure of City to furnish timely information or to
approve or disapprove Consultant's Work promptly, or delay or faulty performance by
City, contractors, or governmental agencies.
9. HOLD HARMLESS
9.1 To the fullest extent permitted by law, Consultant shall indemnify, defend
and hold harmless City, its City Council, boards and commissions, officers, agents,
volunteers, employees and any person or entity owning or otherwise in legal control of
the property upon which Consultant performs the Project and/or Services contemplated
by this Agreement (collectively, the "Indemnified Parties"), from and against any and all
claims (including, without limitation, claims for bodily injury, death or damage to
property), demands, obligations, damages, actions, causes of action, suits, losses,
judgments, fines, penalties, liabilities, costs and expenses (including, without limitation,
attorneys' fees, disbursements and court costs) of every kind and nature whatsoever
(individually, a Claim; collectively, "Claims"), and which relate (directly or indirectly) to
the negligence, recklessness, or willful misconduct of the Consultant or its principals,
officers, agents, employees, vendors, suppliers, subconsultants, subcontractors,
Moffatt & Nichol Page 4
6-27
anyone employed directly or indirectly by any of them or for whose acts they may be
liable, or any or all of them.
9.2 Notwithstanding the foregoing, nothing herein shall be construed to
require Consultant to indemnify the Indemnified Parties from any Claim arising from the
sole negligence, active negligence or willful misconduct of the Indemnified Parties.
Nothing in this indemnity shall be construed as authorizing any award of attorneys' fees
in any action on or to enforce the terms of this Agreement. This indemnity shall apply to
all claims and liability regardless of whether any insurance policies are applicable. The
policy limits do not act as a limitation upon the amount of indemnification to be provided
by the Consultant.
10. INDEPENDENT CONTRACTOR
It is understood that City retains Consultant on an independent contractor basis
and Consultant is not an agent or employee of City. The manner and means of
conducting the Work are under the control of Consultant, except to the extent they are
limited by statute, rule or regulation and the expressed terms of this Agreement. No
civil service status or other right of employment shall accrue to Consultant or its
employees. Nothing in this Agreement shall be deemed to constitute approval for
Consultant or any of Consultant's employees or agents, to be the agents or employees
of City. Consultant shall have the responsibility for and control over the means of
performing the Work, provided that Consultant is in compliance with the terms of this
Agreement. Anything in this Agreement that may appear to give City the right to direct
Consultant as to the details of the performance of the Work or to exercise a measure of
control over Consultant shall mean only that Consultant shall follow the desires of City
with respect to the results of the Services.
11. COOPERATION
Consultant agrees to work closely and cooperate fully with City's designated
Project Administrator and any other agencies that may have jurisdiction or interest in the
Work to be performed. City agrees to cooperate with the Consultant on the Project.
12. CITY POLICY
Consultant shall discuss and review all matters relating to policy and Project
direction with City's Project Administrator in advance of all critical decision points in
order to ensure the Project proceeds in a manner consistent with City goals and
policies.
13. PROGRESS
Consultant is responsible for keeping the Project Administrator informed on a
regular basis regarding the status and progress of the Project, activities performed and
planned, and any meetings that have been scheduled or are desired.
Moffatt & Nichol Page 5
6-28
14. INSURANCE
Without limiting Consultant's indemnification of City, and prior to commencement
of Work, Consultant shall obtain, provide and maintain at its own expense during the
term of this Agreement or for other periods as specified in this Agreement, policies of
insurance of the type, amounts, terms and conditions described in the Insurance
Requirements attached hereto as Exhibit C, and incorporated herein by reference.
15. PROHIBITION AGAINST ASSIGNMENTS AND TRANSFERS
Except as specifically authorized under this Agreement, the Services to be
provided under this Agreement shall not be assigned, transferred contracted or
subcontracted out without the prior written approval of City. Any of the following shall
be construed as an assignment: The sale, assignment, transfer or other disposition of
any of the issued and outstanding capital stock of Consultant, or of the interest of any
general partner or joint venturer or syndicate member or cotenant if Consultant is a
partnership or joint -venture or syndicate or co -tenancy, which shall result in changing
the control of Consultant. Control means fifty percent (50%) or more of the voting
power or twenty-five percent (25%) or more of the assets of the corporation, partnership
or joint -venture.
16. SUBCONTRACTING
The subcontractors authorized by City, if any, to perform Work on this Project are
identified in Exhibit A and the Letter Proposal. Consultant shall be fully responsible to
City for all acts and omissions of any subcontractor. Nothing in this Agreement shall
create any contractual relationship between City and any subcontractor nor shall it
create any obligation on the part of City to pay or to see to the payment of any monies
due to any such subcontractor other than as otherwise required by law. City is an
intended beneficiary of any Work performed by the subcontractor for purposes of
establishing a duty of care between the subcontractor and City. Except as specifically
authorized herein, the Services to be provided under this Agreement shall not be
otherwise assigned, transferred, contracted or subcontracted out without the prior
written approval of City.
17. OWNERSHIP OF DOCUMENTS
17.1 Each and every report, draft, map, record, plan, document and other
writing produced, including but not limited to, websites, blogs, social media accounts
and applications (hereinafter "Documents"), prepared or caused to be prepared by
Consultant, its officers, employees, agents and subcontractors, in the course of
implementing this Agreement, shall become the exclusive property of City, and City
shall have the sole right to use such materials in its discretion without further
compensation to Consultant or any other party. Additionally, all material posted in
cyberspace by Consultant, its officers, employees, agents and subcontractors, in the
course of implementing this Agreement, shall become the exclusive property of City,
and City shall have the sole right to use such materials in its discretion without further
Moffatt & Nichol Page 6
6-29
compensation to Consultant or any other party. Consultant shall, at Consultant's
expense, provide such Documents, including all logins and password information to City
upon prior written request.
17.2 Documents, including drawings and specifications, prepared by
Consultant pursuant to this Agreement are not intended or represented to be suitable
for reuse by City or others on any other project. Any use of completed Documents for
other projects and any use of incomplete Documents without specific written
authorization from Consultant will be at City's sole risk and without liability to
Consultant. Further, any and all liability arising out of changes made to Consultant's
deliverables under this Agreement by City or persons other than Consultant is waived
against Consultant, and City assumes full responsibility for such changes unless City
has given Consultant prior notice and has received from Consultant written consent for
such changes.
17.3 Computer Aided Design and Drafting ("CADD") data delivered to City shall
include the professional stamp of the engineer or architect in charge of or responsible
for the Work. City agrees that Consultant shall not be liable for claims, liabilities or
losses arising out of, or connected with (a) the modification or misuse by City, or anyone
authorized by City, of CADD data; or (b) any use by City, or anyone authorized by City,
of CADD data for additions to this Project, for the completion of this Project by others, or
for any other Project, excepting only such use as is authorized, in writing, by Consultant.
By acceptance of CADD data, City agrees to indemnify Consultant for damages and
liability resulting from the modification or misuse of such CADD data. All original
drawings shall be submitted to City in the version of AutoCAD used by the City in .dwg
file format, and should comply with the City's digital submission requirements for
improvement plans available from the City's Public Works Department.
17.4 All improvement and/or construction plans shall be plotted on standard
twenty-four inch (24") by thirty-six inch (36") paper size. Consultant shall provide to City
digital `As -Built' drawings in both AutoCAD and Adobe PDF file format within thirty (30)
days after finalization of the Project.
18. CONFIDENTIALITY
All Documents, including drafts, preliminary drawings or plans, notes and
communications that result from the Services in this Agreement, shall be kept
confidential unless City expressly authorizes in writing the release of information.
19. INTELLECTUAL PROPERTY INDEMNITY
Consultant shall defend and indemnify City, its agents, officers, representatives
and employees against any and all liability, including costs, for infringement or alleged
infringement of any United States' letters patent, trademark, or copyright, including
costs, contained in Consultant's Documents provided under this Agreement.
Moffatt & Nichol Page 7
6-30
20. RECORDS
Consultant shall keep records and invoices in connection with the Services to be
performed under this Agreement. Consultant shall maintain complete and accurate
records with respect to the costs incurred under this Agreement and any Services,
expenditures and disbursements charged to City, for a minimum period of three (3)
years, or for any longer period required by law, from the date of final payment to
Consultant under this Agreement. All such records and invoices shall be clearly
identifiable. Consultant shall allow a representative of City to examine, audit and make
transcripts or copies of such records and invoices during regular business hours.
Consultant shall allow inspection of all Work, data, Documents, proceedings and
activities related to the Agreement for a period of three (3) years from the date of final
payment to Consultant under this Agreement.
21. WITHHOLDINGS
City may withhold payment to Consultant of any disputed sums until satisfaction
of the dispute with respect to such payment. Such withholding shall not be deemed to
constitute a failure to pay according to the terms of this Agreement. Consultant shall
not discontinue Work as a result of such withholding. Consultant shall have an
immediate right to appeal to the City Manager or designee with respect to such disputed
sums. Consultant shall be entitled to receive interest on any withheld sums at the rate
of return that City earned on its investments during the time period, from the date of
withholding of any amounts found to have been improperly withheld.
22. ERRORS AND OMISSIONS
In the event of errors or omissions that are due to the negligence or professional
inexperience of Consultant which result in expense to City greater than what would
have resulted if there were not errors or omissions in the Work accomplished by
Consultant, the additional design, construction and/or restoration expense shall be
borne by Consultant. Nothing in this Section is intended to limit City's rights under the
law or any other sections of this Agreement.
23. CITY'S RIGHT TO EMPLOY OTHER CONSULTANTS
City reserves the right to employ other Consultants in connection with the
Project.
24. CONFLICTS OF INTEREST
24.1 Consultant or its employees may be subject to the provisions of the
California Political Reform Act of 1974 (the "Act") and/or Government Code §§ 1090 et
seq., which (1) require such persons to disclose any financial interest that may
foreseeably be materially affected by the Work performed under this Agreement, and (2)
prohibit such persons from making, or participating in making, decisions that will
foreseeably financially affect such interest.
Moffatt & Nichol Page 8
6-31
24.2 If subject to the Act and/or Government Code §§ 1090 et seq., Consultant
shall conform to all requirements therein. Failure to do so constitutes a material breach
and is grounds for immediate termination of this Agreement by City. Consultant shall
indemnify and hold harmless City for any and all claims for damages resulting from
Consultant's violation of this Section.
25. NOTICES
25.1 All notices, demands, requests or approvals, including any change in
mailing address, to be given under the terms of this Agreement shall be given in writing,
and conclusively shall be deemed served when delivered personally, or on the third
business day after the deposit thereof in the United States mail, postage prepaid, first-
class mail, addressed as hereinafter provided.
25.2 All notices, demands, requests or approvals from Consultant to City shall
be addressed to City at-
Attn: Director of Public Works
Public Works Department
City of Newport Beach
100 Civic Center Drive
PO Box 1768
Newport Beach, CA 92658
25.3 All notices, demands, requests or approvals from City to Consultant shall
be addressed to Consultant at-
Attn: Kim Garvey
Moffatt & Nichol
4225 E. Conant Street, Suite 101
Long Beach, CA 90808
26. CLAIMS
Unless a shorter time is specified elsewhere in this Agreement, before making its
final request for payment under this Agreement, Consultant shall submit to City, in
writing, all claims for compensation under or arising out of this Agreement. Consultant's
acceptance of the final payment shall constitute a waiver of all claims for compensation
under or arising out of this Agreement except those previously made in writing and
identified by Consultant in writing as unsettled at the time of its final request for
payment. Consultant and City expressly agree that in addition to any claims filing
requirements set forth in the Agreement, Consultant shall be required to file any claim
Consultant may have against City in strict conformance with the Government Claims Act
(Government Code sections 900 et seq.).
Moffatt & Nichol Page 9
6-32
27. TERMINATION
27.1 In the event that either party fails or refuses to perform any of the
provisions of this Agreement at the time and in the manner required, that party shall be
deemed in default in the performance of this Agreement. If such default is not cured
within a period of two (2) calendar days, or if more than two (2) calendar days are
reasonably required to cure the default and the defaulting party fails to give adequate
assurance of due performance within two (2) calendar days after receipt of written
notice of default, specifying the nature of such default and the steps necessary to cure
such default, and thereafter diligently take steps to cure the default, the non -defaulting
party may terminate the Agreement forthwith by giving to the defaulting party written
notice thereof.
27.2 Notwithstanding the above provisions, City shall have the right, at its sole
and absolute discretion and without cause, of terminating this Agreement at any time by
giving no less than seven (7) calendar days' prior written notice to Consultant. In the
event of termination under this Section, City shall pay Consultant for Services
satisfactorily performed and costs incurred up to the effective date of termination for
which Consultant has not been previously paid. On the effective date of termination,
Consultant shall deliver to City all reports, Documents and other information developed
or accumulated in the performance of this Agreement, whether in draft or final form.
28. STANDARD PROVISIONS
28.1 Recitals. City and Consultant acknowledge that the above Recitals are
true and correct and are hereby incorporated by reference into this Agreement.
28.2 Compliance with all Laws. Consultant shall, at its own cost and expense,
comply with all statutes, ordinances, regulations and requirements of all governmental
entities, including federal, state, county or municipal, whether now in force or hereinafter
enacted. In addition, all Work prepared by Consultant shall conform to applicable City,
county, state and federal laws, rules, regulations and permit requirements and be
subject to approval of the Project Administrator and City.
28.3 Waiver. A waiver by either party of any breach, of any term, covenant or
condition contained herein shall not be deemed to be a waiver of any subsequent
breach of the same or any other term, covenant or condition contained herein, whether
of the same or a different character.
28.4 Inteqrated Contract. This Agreement represents the full and complete
understanding of every kind or nature whatsoever between the parties hereto, and all
preliminary negotiations and agreements of whatsoever kind or nature are merged
herein. No verbal agreement or implied covenant shall be held to vary the provisions
herein.
28.5 Conflicts or Inconsistencies. In the event there are any conflicts or
inconsistencies between this Agreement and the Scope of Services or any other
attachments attached hereto, the terms of this Agreement shall govern.
Moffatt & Nichol Page 10
6-33
28.6 Interpretation. The terms of this Agreement shall be construed in
accordance with the meaning of the language used and shall not be construed for or
against either party by reason of the authorship of the Agreement or any other rule of
construction which might otherwise apply.
28.7 Amendments. This Agreement may be modified or amended only by a
written document executed by both Consultant and City and approved as to form by the
City Attorney.
28.8 Severability. If any term or portion of this Agreement is held to be invalid,
illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining
provisions of this Agreement shall continue in full force and effect.
28.9 Controlling Law and Venue. The laws of the State of California shall
govern this Agreement and all matters relating to it and any action brought relating to
this Agreement shall be adjudicated in a court of competent jurisdiction in the County of
Orange, State of California.
28.10 Equal Opportunity Employment. Consultant represents that it is an equal
opportunity employer and it shall not discriminate against any subcontractor, employee
or applicant for employment because race, religious creed, color, national origin,
ancestry, physical handicap, medical condition, marital status, sex, sexual orientation,
age or any other impermissible basis under law.
28.11 No Attorneys' Fees. In the event of any dispute or legal action arising
under this Agreement, the prevailing party shall not be entitled to attorneys' fees.
28.12 Counterparts. This Agreement may be executed in two (2) or more
counterparts, each of which shall be deemed an original and all of which together shall
constitute one (1) and the same instrument.
[SIGNATURES ON NEXT PAGE]
Moffatt & Nichol Page 11
6-34
IN WITNESS WHEREOF, the parties have caused this Agreement to be
executed on the dates written below.
APPROVED AS TO FORM:
CITY ATTORNEY'S OFFICE
Date: 3 rZ% - Z 2
By:
a n C. p O►k 01ultiti
ty Attorney
ATTEST:
Date:
By:
Leilani 1. Brown
City Clerk
CITY OF NEWPORT BEACH,
a California municipal corporation
Date:
By:
Kevin Muldoon
Mayor
CONSULTANT: Moffatt
California corporation
Date:
By:
Michelle Anghera
Vice President
Date:
By:
Omar Jaradat
Vice President
[END OF SIGNATURES]
Attachments: Exhibit A — Scope of Services
Exhibit B — Schedule of Billing Rates
Exhibit C — Insurance Requirements
& Nichol, a
Moffatt & Nichol Page 12
6-35
EXHIBIT A
SCOPE OF SERVICES
The following is a list of the services requested as part of this agreement for on-call
marine engineering services. Consultant shall be responsible for deploying and storing
any vessels or equipment related to the services provided under this agreement. The
services requested include, but are not limited to, the following:
1. Assist in the design and permitting of docks, piers, floats, wharfs, gangways
for public facilities, with attention to Americans with Disabilities Act (ADA) and
other regulatory requirements.
2. Assist in the design and permitting of dredging projects within docks, marinas,
small confined channels or larger main channels, using either the City's RGP-
54 dredging permit or the traditional Individual Permit process (California
Coastal Commission, Corps of Engineers, Water Board).
3. Collect sediment samples and generate grain size analysis reports.
4. Assist in the detailed management of the City's existing, five-year Regional
General Permit (RGP-54) as well as negotiating any intermediate
improvements to the program, as needed.
5. Provide various bathymetry surveys within docks, marinas, small confined
channels or larger main channels.
6. Prepare dredged material Sampling and Analysis Plans (SAPs) and Sampling
and Analysis Reports (SAR) in support of permitting activities with regulatory
agencies including the Dredged Material Management Team (DMMT) and
individual regulatory and resources agencies, as needed.
7. Conduct field collection of marine sediments and marine test organisms as
required for chemical and biological testing during a typical permitting project
(usually dredging).
8. Conduct chemical, biological and toxicity testing/analyses of bulk sediments
and marine test organisms to support chemical and biological testing during a
typical permitting project (usually dredging).
9. Conduct Caulerpa and eelgrass surveys, or assist in managing these studies,
including the harbor -wide biennial eelgrass survey as part of the "Eelgrass
Protection and Mitigation Plan for Shallow Waters in Lower Newport Bay: An
Ecosystem Based Management Approach."
Moffatt & Nichol Page A-1 6-36
10. Assist in the design and permitting of bulkheads and their structural
components for public facilities or property owned by the City.
11. Project management with various harbor related tasks to assist the Public
Works Department. Projects may include larger dock/bulkhead construction
projects, permitting programs, organizing public outreach campaigns, or other
projects as assigned by Public Works.
12. Depending upon the characteristics of a project and its potential for significant
environmental effects, a CEQA review may be needed. For the scope of this
proposal, the Consultant may prepare an Initial Study.
13. Preparation of record drawings.
14. Present projects, findings, information etc. at various public meetings
including the City Council, Harbor Commission, various ad hoc committee
meetings and other outreach events as required.
15. Other marine and/or harbor related engineering and professional services as
needed.
Moffatt & Nichol Page A-2 6-37
EXHIBIT B
SCHEDULE OF BILLING RATES
Moffatt & Nichol Page B-1 6-38
EXHIBIT B
BILLING RATES
PROFESSIONALS
Supervisory Engineer/Scientist
$
306.00
Vellum Plots (B/W)
Senior Engineer/Scientist
$
286.00
Drawing Reproduction
Engineer/Scientist III
$
271.00
-Outside Reproduction
Engineer/Scientist 1I
$
237.00
Rental Vehicle
Engineer/Scientist 1
$
213.00
Meals and Lodging
Staff Engineer/Scientist
$
171.00
TECHNICIANS
Senior Technician
$
231.00
Designer
$
218.00
CADD II
$
187.00
CADD I
$
139.00
CLERICAL
Project Controls/Word Processing
$
139.00
General Clerical
$
109.00
SPECIAL
Principal Engineer/Scientist
$
321.00
Deposition & Trial Testimony
$
574.00
REIMBURSABLE EXPENSES (Unless Otherwise Provided in Written Agreement)
Subcontracts or Outside Services Cost +10%
Reproductions -in House
Mylar Plots (B/W)
$2.50/SF
Color Plots
$4.50/SF
Vellum Plots (B/W)
$1.50/SF
Bond Plots (B/W)
$1.00/SF
Drawing Reproduction
Cost + 10%
Document Reproduction
$0.15/sheet
-Outside Reproduction
Cost +10%
Travel Company Auto
Prevailing IRS
Rental Vehicle
Cost
A irfare
Cost
Meals and Lodging
Cost
EXHIBIT C
INSURANCE REQUIREMENTS — PROFESSIONAL SERVICES
1. Provision of Insurance. Without limiting Consultant's indemnification of City, and
prior to commencement of Work, Consultant shall obtain, provide and maintain at
its own expense during the term of this Agreement, policies of insurance of the
type and amounts described below and in a form satisfactory to City. Consultant
agrees to provide insurance in accordance with requirements set forth here. If
Consultant uses existing coverage to comply and that coverage does not meet
these requirements, Consultant agrees to amend, supplement or endorse the
existing coverage.
2. Acceptable Insurers. All insurance policies shall be issued by an insurance
company currently authorized by the Insurance Commissioner to transact
business of insurance in the State of California, with an assigned policyholders'
Rating of A- (or higher) and Financial Size Category Class VII (or larger) in
accordance with the latest edition of Best's Key Rating Guide, unless otherwise
approved by the City's Risk Manager.
3. Coveraqe Requirements.
A. Workers' Compensation Insurance. Consultant shall maintain Workers'
Compensation Insurance, statutory limits, and Employer's Liability
Insurance with limits of at least one million dollars ($1,000,000) each
accident for bodily injury by accident and each employee for bodily injury
by disease in accordance with the laws of the State of California, Section
3700 of the Labor Code.
Consultant shall submit to City, along with the certificate of insurance, a
Waiver of Subrogation endorsement in favor of City, its City Council,
boards and commissions, officers, agents, volunteers, employees and any
person or entity owning or otherwise in legal control of the property upon
which Consultant performs the Project and/or Services contemplated by
this Agreement.
B. General Liability Insurance. Consultant shall maintain commercial general
liability insurance, and if necessary umbrella liability insurance, with
coverage at least as broad as provided by Insurance Services Office form
CG 00 01, in an amount not less than one million dollars ($1,000,000) per
occurrence, two million dollars ($2,000,000) general aggregate. The
policy shall cover liability arising from premises, operations, personal and
advertising injury, and liability assumed under an insured contract
(including the tort liability of another assumed in a business contract).
C. Automobile Liability Insurance. Consultant shall maintain automobile
insurance at least as broad as Insurance Services Office form CA 00 01
covering bodily injury and property damage for all activities of Consultant
arising out of or in connection with Work to be performed under this
Moffatt & Nichol Page C-1 6-40
Agreement, including coverage for any owned, hired, non -owned or rented
vehicles, in an amount not less than one million dollars ($1,000,000)
combined single limit each accident.
D. Professional Liability (Errors & Omissions) Insurance. Consultant shall
maintain professional liability insurance that covers the Services to be
performed in connection with this Agreement, in the minimum amount of
one million dollars ($1,000,000) per claim and two million dollars
($2,000,000) in the aggregate. Any policy inception date, continuity date,
or retroactive date must be before the Effective Date of this Agreement
and Consultant agrees to maintain continuous coverage through a period
no less than three years after completion of the Services required by this
Agreement.
4. Other Insurance Requirements. The policies are to contain, or be endorsed to
contain, the following provisions:
A. Waiver of Subrogation. All insurance coverage maintained or procured
pursuant to this Agreement shall be endorsed to waive subrogation
against City, its City Council, boards and commissions, officers, agents,
volunteers, employees and any person or entity owning or otherwise in
legal control of the property upon which Consultant performs the Project
and/or Services contemplated by this Agreement or shall specifically allow
Consultant or others providing insurance evidence in compliance with
these requirements to waive their right of recovery prior to a loss.
Consultant hereby waives its own right of recovery against City, and shall
require similar written express waivers from each of its subconsultants.
B. Additional Insured Status. All liability policies including general liability,
excess liability, pollution liability, and automobile liability, if required, but
not including professional liability, shall provide or be endorsed to provide
that City, its City Council, boards and commissions, officers, agents,
volunteers, employees and any person or entity owning or otherwise in
legal control of the property upon which Consultant performs the Project
and/or Services contemplated by this Agreement shall be included as
insureds under such policies.
C. Primary and Non Contributory. All liability coverage shall apply on a
primary basis and shall not require contribution from any insurance or self-
insurance maintained by City.
D. Notice of Cancellation. All policies shall provide City with thirty (30)
calendar days' notice of cancellation (except for nonpayment for which ten
(10) calendar days' notice is required) or nonrenewal of coverage for each
required coverage.
5. Additional Agreements Between the Parties. The parties hereby agree to the
following:
Moffatt & Nichol Page C-2 6-41
A. Evidence of Insurance. Consultant shall provide certificates of insurance
to City as evidence of the insurance coverage required herein, along with
a waiver of subrogation endorsement for workers' compensation and other
endorsements as specified herein for each coverage. Insurance
certificates and endorsement must be approved by City's Risk Manager
prior to commencement of performance. Current certification of insurance
shall be kept on file with City at all times during the term of this
Agreement. The certificates and endorsements for each insurance policy
shall be signed by a person authorized by that insurer to bind coverage on
its behalf. At least fifteen (15) days prior to the expiration of any such
policy, evidence of insurance showing that such insurance coverage has
been renewed or extended shall be filed with the City. If such coverage is
cancelled or reduced, Consultant shall, within ten (10) days after receipt of
written notice of such cancellation or reduction of coverage, file with the
City evidence of insurance showing that the required insurance has been
reinstated or has been provided through another insurance company or
companies. City reserves the right to require complete, certified copies of
all required insurance policies, at any time.
B. City's Right to Revise Requirements. City reserves the right at any time
during the term of the Agreement to change the amounts and types of
insurance required by giving Consultant sixty (60) calendar days' advance
written notice of such change. If such change results in substantial
additional cost to Consultant, City and Consultant may renegotiate
Consultant's compensation.
C. Right to Review Subcontracts. Consultant agrees that upon request, all
agreements with subcontractors or others with whom Consultant enters
into contracts with on behalf of City will be submitted to City for review.
Failure of City to request copies of such agreements will not impose any
liability on City, or its employees. Consultant shall require and verify that
all subcontractors maintain insurance meeting all the requirements stated
herein, and Consultant shall ensure that City is an additional insured on
insurance required from subcontractors. For CGL coverage,
subcontractors shall provide coverage with a format at least as broad as
CG 20 38 04 13.
D. Enforcement of Agreement Provisions. Consultant acknowledges and
agrees that any actual or alleged failure on the part of City to inform
Consultant of non-compliance with any requirement imposes no additional
obligations on City nor does it waive any rights hereunder.
E. Requirements not Limiting. Requirements of specific coverage features or
limits contained in this Section are not intended as a limitation on
coverage, limits or other requirements, or a waiver of any coverage
normally provided by any insurance. Specific reference to a given
coverage feature is for purposes of clarification only as it pertains to a
given issue and is not intended by any party or insured to be all inclusive,
or to the exclusion of other coverage, or a waiver of any type. If the
Moffatt & Nichol Page C-3 6-42
Consultant maintains higher limits than the minimums shown above, the
City requires and shall be entitled to coverage for higher limits maintained
by the Consultant. Any available insurance proceeds in excess of the
specified minimum limits of insurance and coverage shall be available to
the City.
F. Self-insured Retentions. Any self-insured retentions must be declared to
and approved by City. City reserves the right to require that self-insured
retentions be eliminated, lowered, or replaced by a deductible. Self-
insurance will not be considered to comply with these requirements unless
approved by City.
G. City Remedies for Non -Compliance. If Consultant or any subconsultant
fails to provide and maintain insurance as required herein, then City shall
have the right but not the obligation, to purchase such insurance, to
terminate this Agreement, or to suspend Consultant's right to proceed until
proper evidence of insurance is provided. Any amounts paid by City shall,
at City's sole option, be deducted from amounts payable to Consultant or
reimbursed by Consultant upon demand.
H. Timely Notice of Claims. Consultant shall give City prompt and timely
notice of claims made or suits instituted that arise out of or result from
Consultant's performance under this Agreement, and that involve or may
involve coverage under any of the required liability policies. City assumes
no obligation or liability by such notice, but has the right (but not the duty)
to monitor the handling of any such claim or claims if they are likely to
involve City.
Consultant's Insurance. Consultant shall also procure and maintain, at its
own cost and expense, any additional kinds of insurance, which in its own
judgment may be necessary for its proper protection and prosecution of
the Work.
Moffatt & Nichol Page C-4 6-43
ATTACHMENT C
ON-CALL PROFESSIONAL SERVICES AGREEMENT
WITH NOBLE CONSULTANTS, INC. FOR
ON-CALL MARINE ENGINEERING SERVICES
THIS ON-CALL PROFESSIONAL SERVICES AGREEMENT ("Agreement") is
made and entered into as of this 12th day of April, 2022 ("Effective Date"), by and
between the CITY OF NEWPORT BEACH, a California municipal corporation and
charter city ("City"), and NOBLE CONSULTANTS, INC., a California corporation
("Consultant"), whose address is 2201 Dupont Drive, Suite 830, Irvine, California 92612,
and is made with reference to the following:
RECITALS
A. City is a municipal corporation duly organized and validly existing under the laws
of the State of California with the power to carry on its business as it is now being
conducted under the statutes of the State of California and the Charter of City.
B. City desires to engage Consultant to provide on-call marine engineering services
("Project").
C. Consultant possesses the skill, experience, ability, background, certification and
knowledge to provide the professional services described in this Agreement.
D. City has solicited and received a proposal from Consultant, has reviewed the
previous experience and evaluated the expertise of Consultant, and desires to
retain Consultant to render professional services under the terms and conditions
set forth in this Agreement.
NOW, THEREFORE, it is mutually agreed by and between the undersigned
parties as follows -
1 .
ollows:1. TERM
The term of this Agreement shall commence on the Effective Date, and shall
terminate on April 30, 2025, unless terminated earlier as set forth herein.
2. SERVICES TO BE PERFORMED
2.1 Consultant shall perform the on-call services described in the Scope of
Services attached hereto as Exhibit A and incorporated herein by reference ("Services"
or "Work"). Upon written request from the Project Administrator as defined herein,
Consultant shall provide a letter proposal for Services requested by the City (hereinafter
referred to as the "Letter Proposal"). The Letter Proposal shall include the following:
2.1.1 A detailed description of the Services to be provided,
2.1.2 The position of each person to be assigned to perform the
Services, and the name of the individuals to be assigned, if available;
and
2.1.3 The estimated number of hours and cost to complete the Services;
2.1.4 The time needed to finish the specific project.
2.2 No Services shall be provided until the Project Administrator has provided
written acceptance of the Letter Proposal. Once authorized to proceed, Consultant
shall diligently perform the duties in the approved Letter Proposal.
3. TIME OF PERFORMANCE
3.1 Time is of the essence in the performance of Services under this
Agreement and Consultant shall perform the Services in accordance with the schedule
included in Exhibit A and the Letter Proposal. In the absence of a specific schedule, the
Services shall be performed to completion in a diligent and timely manner. The failure
by Consultant to strictly adhere to the schedule set forth in Exhibit A and the Letter
Proposal, if any, or perform the Services in a diligent and timely manner may result in
termination of this Agreement by City.
3.2 Notwithstanding the foregoing, Consultant shall not be responsible for
delays due to causes beyond Consultant's reasonable control. However, in the case of
any such delay in the Services to be provided for the Project, each party hereby agrees
to provide notice within two (2) calendar days of the occurrence causing the delay to the
other party so that all delays can be addressed.
3.3 Consultant shall submit all requests for extensions of time for performance
in writing to the Project Administrator as defined herein not later than ten (10) calendar
days after the start of the condition that purportedly causes a delay. The Project
Administrator shall review all such requests and may grant reasonable time extensions
for unforeseeable delays that are beyond Consultant's control.
3.4 For all time periods not specifically set forth herein, Consultant shall
respond in the most expedient and appropriate manner under the circumstances, by
hand -delivery or mail.
4. COMPENSATION TO CONSULTANT
4.1 City shall pay Consultant for the Services on a time and expense not -to -
exceed basis in accordance with the provisions of this Section and the Letter Proposal
and the Schedule of Billing Rates attached hereto as Exhibit B and incorporated herein
by reference. Consultant's compensation for all Work performed in accordance with this
Agreement, including all reimbursable items and subconsultant fees, shall not exceed
Three Hundred Thousand Dollars and 001100 ($300,000.00), without prior written
authorization from City. No billing rate changes shall be made during the term of this
Agreement without the prior written approval of City.
Noble Consultants, Inc. Page 2 6-45
4.2 Consultant shall submit monthly invoices to City describing the Work
performed the preceding month. Consultant's bills shall include the name of the person
who performed the Work, a brief description of the Services performed and/or the
specific task in the Scope of Services to which it relates, the date the Services were
performed, the number of hours spent on all Work billed on an hourly basis, and a
description of any reimbursable expenditures. City shall pay Consultant no later than
thirty (30) calendar days after approval of the monthly invoice by City staff.
4.3 City shall reimburse Consultant only for those costs or expenses
specifically identified in Exhibit B to this Agreement and the Letter Proposal or
specifically approved in writing in advance by City.
4.4 Consultant shall not receive any compensation for Extra Work performed
without the prior written authorization of City. As used herein, "Extra Work" means any
Work that is determined by City to be necessary for the proper completion of the
Project, but which is not included within the Scope of Services and which the parties did
not reasonably anticipate would be necessary at the execution of this Agreement.
Compensation for any authorized Extra Work shall be paid in accordance with the
Schedule of Billing Rates as set forth in Exhibit B and the Letter Proposal.
5. PROJECT MANAGER
5.1 Consultant shall designate a Project Manager, who shall coordinate all
phases of the Project. This Project Manager shall be available to City at all reasonable
times during the Agreement term. Consultant has designated Thomas Fischetti to be
its Project Manager. Consultant shall not remove or reassign the Project Manager or
any personnel listed in Exhibit A or assign any new or replacement personnel to the
Project without the prior written consent of City. City's approval shall not be
unreasonably withheld with respect to the removal or assignment of non -key personnel.
5.2 Consultant, at the sole discretion of City, shall remove from the Project
any of its personnel assigned to the performance of Services upon written request of
City. Consultant warrants that it will continuously furnish the necessary personnel to
complete the Project on a timely basis as contemplated by this Agreement.
5.3 If Consultant is performing inspection services for City, the Project
Manager and any other assigned staff shall be equipped with a cellular phone to
communicate with City staff. The Project Manager's cellular phone number shall be
provided to City.
6. ADMINISTRATION
This Agreement will be administered by the Public Works Department. City's
Director of Public Works or designee shall be the Project Administrator and shall have
the authority to act for City under this Agreement. The Project Administrator shall
represent City in all matters pertaining to the Services to be rendered pursuant to this
Agreement.
Noble Consultants, Inc. Page 3
6-46
7. CITY'S RESPONSIBILITIES
To assist Consultant in the execution of its responsibilities under this Agreement,
City agrees to provide access to and upon request of Consultant, one copy of all
existing relevant information on file at City. City will provide all such materials in a
timely manner so as not to cause delays in Consultant's Work schedule.
8. STANDARD OF CARE
8.1 All of the Services shall be performed by Consultant or under Consultant's
supervision. Consultant represents that it possesses the professional and technical
personnel required to perform the Services required by this Agreement, and that it will
perform all Services in a manner commensurate with community professional standards
and with the ordinary degree of skill and care that would be used by other reasonably
competent practitioners of the same discipline under similar circumstances. All
Services shall be performed by qualified and experienced personnel who are not
employed by City. By delivery of completed Work, Consultant certifies that the Work
conforms to the requirements of this Agreement, all applicable federal, state and local
laws, and legally recognized professional standards.
8.2 Consultant represents and warrants to City that it has, shall obtain, and
shall keep in full force and effect during the term hereof, at its sole cost and expense, all
licenses, permits, qualifications, insurance and approvals of whatsoever nature that is
legally required of Consultant to practice its profession. Consultant shall maintain a City
of Newport Beach business license during the term of this Agreement.
8.3 Consultant shall not be responsible for delay, nor shall Consultant be
responsible for damages or be in default or deemed to be in default by reason of strikes,
lockouts, accidents, acts of God, or the failure of City to furnish timely information or to
approve or disapprove Consultant's Work promptly, or delay or faulty performance by
City, contractors, or governmental agencies.
9. HOLD HARMLESS
9.1 To the fullest extent permitted by law, Consultant shall indemnify, defend
and hold harmless City, its City Council, boards and commissions, officers, agents,
volunteers, employees and any person or entity owning or otherwise in legal control of
the property upon which Consultant performs the Project and/or Services contemplated
by this Agreement (collectively, the "Indemnified Parties"), from and against any and all
claims (including, without limitation, claims for bodily injury, death or damage to
property), demands, obligations, damages, actions, causes of action, suits, losses,
judgments, fines, penalties, liabilities, costs and expenses (including, without limitation,
attorneys' fees, disbursements and court costs) of every kind and nature whatsoever
(individually, a Claim; collectively, "Claims"), and which relate (directly or indirectly) to
the negligence, recklessness, or willful misconduct of the Consultant or its principals,
officers, agents, employees, vendors, suppliers, subconsultants, subcontractors,
Noble Consultants, Inc. Page 4 6-47
anyone employed directly or indirectly by any of them or for whose acts they may be
liable, or any or all of them.
9.2 Notwithstanding the foregoing, nothing herein shall be construed to
require Consultant to indemnify the Indemnified Parties from any Claim arising from the
sole negligence, active negligence or willful misconduct of the Indemnified Parties.
Nothing in this indemnity shall be construed as authorizing any award of attorneys' fees
in any action on or to enforce the terms of this Agreement. This indemnity shall apply to
all claims and liability regardless of whether any insurance policies are applicable. The
policy limits do not act as a limitation upon the amount of indemnification to be provided
by the Consultant.
10. INDEPENDENT CONTRACTOR
It is understood that City retains Consultant on an independent contractor basis
and Consultant is not an agent or employee of City. The manner and means of
conducting the Work are under the control of Consultant, except to the extent they are
limited by statute, rule or regulation and the expressed terms of this Agreement. No
civil service status or other right of employment shall accrue to Consultant or its
employees. Nothing in this Agreement shall be deemed to constitute approval for
Consultant or any of Consultant's employees or agents, to be the agents or employees
of City. Consultant shall have the responsibility for and control over the means of
performing the Work, provided that Consultant is in compliance with the terms of this
Agreement. Anything in this Agreement that may appear to give City the right to direct
Consultant as to the details of the performance of the Work or to exercise a measure of
control over Consultant shall mean only that Consultant shall follow the desires of City
with respect to the results of the Services.
11. COOPERATION
Consultant agrees to work closely and cooperate fully with City's designated
Project Administrator and any other agencies that may have jurisdiction or interest in the
Work to be performed. City agrees to cooperate with the Consultant on the Project.
12. CITY POLICY
Consultant shall discuss and review all matters relating to policy and Project
direction with City's Project Administrator in advance of all critical decision points in
order to ensure the Project proceeds in a manner consistent with City goals and
policies.
13. PROGRESS
Consultant is responsible for keeping the Project Administrator informed on a
regular basis regarding the status and progress of the Project, activities performed and
planned, and any meetings that have been scheduled or are desired.
Noble Consultants, Inc. Page 5 6-48
14. INSURANCE
Without limiting Consultant's indemnification of City, and prior to commencement
of Work, Consultant shall obtain, provide and maintain at its own expense during the
term of this Agreement or for other periods as specified in this Agreement, policies of
insurance of the type, amounts, terms and conditions described in the Insurance
Requirements attached hereto as Exhibit C, and incorporated herein by reference.
15. PROHIBITION AGAINST ASSIGNMENTS AND TRANSFERS
Except as specifically authorized under this Agreement, the Services to be
provided under this Agreement shall not be assigned, transferred contracted or
subcontracted out without the prior written approval of City. Any of the following shall
be construed as an assignment: The sale, assignment, transfer or other disposition of
any of the issued and outstanding capital stock of Consultant, or of the interest of any
general partner or joint venturer or syndicate member or cotenant if Consultant is a
partnership or joint -venture or syndicate or co -tenancy, which shall result in changing
the control of Consultant. Control means fifty percent (50%) or more of the voting
power or twenty-five percent (25%) or more of the assets of the corporation, partnership
or joint -venture.
16. SUBCONTRACTING
The subcontractors authorized by City, if any, to perform Work on this Project are
identified in Exhibit A and the Letter Proposal. Consultant shall be fully responsible to
City for all acts and omissions of any subcontractor. Nothing in this Agreement shall
create any contractual relationship between City and any subcontractor nor shall it
create any obligation on the part of City to pay or to see to the payment of any monies
due to any such subcontractor other than as otherwise required by law. City is an
intended beneficiary of any Work performed by the subcontractor for purposes of
establishing a duty of care between the subcontractor and City. Except as specifically
authorized herein, the Services to be provided under this Agreement shall not be
otherwise assigned, transferred, contracted or subcontracted out without the prior
written approval of City.
17. OWNERSHIP OF DOCUMENTS
17.1 Each and every report, draft, map, record, plan, document and other
writing produced, including but not limited to, websites, blogs, social media accounts
and applications (hereinafter "Documents"), prepared or caused to be prepared by
Consultant, its officers, employees, agents and subcontractors, in the course of
implementing this Agreement, shall become the exclusive property of City, and City
shall have the sole right to use such materials in its discretion without further
compensation to Consultant or any other party. Additionally, all material posted in
cyberspace by Consultant, its officers, employees, agents and subcontractors, in the
course of implementing this Agreement, shall become the exclusive property of City,
and City shall have the sole right to use such materials in its discretion without further
Noble Consultants, Inc. Page 6 6-49
compensation to Consultant or any other party. Consultant shall, at Consultant's
expense, provide such Documents, including all logins and password information to City
upon prior written request.
17.2 Documents, including drawings and specifications, prepared by
Consultant pursuant to this Agreement are not intended or represented to be suitable
for reuse by City or others on any other project. Any use of completed Documents for
other projects and any use of incomplete Documents without specific written
authorization from Consultant will be at City's sole risk and without liability to
Consultant. Further, any and all liability arising out of changes made to Consultant's
deliverables under this Agreement by City or persons other than Consultant is waived
against Consultant, and City assumes full responsibility for such changes unless City
has given Consultant prior notice and has received from Consultant written consent for
such changes.
17.3 Computer Aided Design and Drafting ("CADD") data delivered to City shall
include the professional stamp of the engineer or architect in charge of or responsible
for the Work. City agrees that Consultant shall not be liable for claims, liabilities or
losses arising out of, or connected with (a) the modification or misuse by City, or anyone
authorized by City, of CADD data; or (b) any use by City, or anyone authorized by City,
of CADD data for additions to this Project, for the completion of this Project by others, or
for any other Project, excepting only such use as is authorized, in writing, by Consultant.
By acceptance of CADD data, City agrees to indemnify Consultant for damages and
liability resulting from the modification or misuse of such CADD data. All original
drawings shall be submitted to City in the version of AutoCAD used by the City in .dwg
file format, and should comply with the City's digital submission requirements for
improvement plans available from the City's Public Works Department.
17.4 All improvement and/or construction plans shall be plotted on standard
twenty-four inch (24") by thirty-six inch (36") paper size. Consultant shall provide to City
digital `As -Built' drawings in both AutoCAD and Adobe PDF file format within thirty (30)
days after finalization of the Project.
18. CONFIDENTIALITY
All Documents, including drafts, preliminary drawings or plans, notes and
communications that result from the Services in this Agreement, shall be kept
confidential unless City expressly authorizes in writing the release of information.
19. INTELLECTUAL PROPERTY INDEMNITY
Consultant shall defend and indemnify City, its agents, officers, representatives
and employees against any and all liability, including costs, for infringement or alleged
infringement of any United States' letters patent, trademark, or copyright, including
costs, contained in Consultant's Documents provided under this Agreement.
Noble Consultants, Inc. Page 7
6-50
20. RECORDS
Consultant shall keep records and invoices in connection with the Services to be
performed under this Agreement. Consultant shall maintain complete and accurate
records with respect to the costs incurred under this Agreement and any Services,
expenditures and disbursements charged to City, for a minimum period of three (3)
years, or for any longer period required by law, from the date of final payment to
Consultant under this Agreement. All such records and invoices shall be clearly
identifiable. Consultant shall allow a representative of City to examine, audit and make
transcripts or copies of such records and invoices during regular business hours.
Consultant shall allow inspection of all Work, data, Documents, proceedings and
activities related to the Agreement for a period of three (3) years from the date of final
payment to Consultant under this Agreement.
21. WITHHOLDINGS
City may withhold payment to Consultant of any disputed sums until satisfaction
of the dispute with respect to such payment. Such withholding shall not be deemed to
constitute a failure to pay according to the terms of this Agreement. Consultant shall
not discontinue Work as a result of such withholding. Consultant shall have an
immediate right to appeal to the City Manager or designee with respect to such disputed
sums. Consultant shall be entitled to receive interest on any withheld sums at the rate
of return that City earned on its investments during the time period, from the date of
withholding of any amounts found to have been improperly withheld.
22. ERRORS AND OMISSIONS
In the event of errors or omissions that are due to the negligence or professional
inexperience of Consultant which result in expense to City greater than what would
have resulted if there were not errors or omissions in the Work accomplished by
Consultant, the additional design, construction and/or restoration expense shall be
borne by Consultant. Nothing in this Section is intended to limit City's rights under the
law or any other sections of this Agreement.
23. CITY'S RIGHT TO EMPLOY OTHER CONSULTANTS
City reserves the right to employ other Consultants in connection with the
Project.
24.1 Consultant or its employees may be subject to the provisions of the
California Political Reform Act of 1974 (the "Act") and/or Government Code §§ 1090 et
seq., which (1) require such persons to disclose any financial interest that may
foreseeably be materially affected by the Work performed under this Agreement, and (2)
prohibit such persons from making, or participating in making, decisions that will
foreseeably financially affect such interest.
Noble Consultants, Inc. Page 8
6-51
24.2 If subject to the Act and/or Government Code §§ 1090 et seq., Consultant
shall conform to all requirements therein. Failure to do so constitutes a material breach
and is grounds for immediate termination of this Agreement by City. Consultant shall
indemnify and hold harmless City for any and all claims for damages resulting from
Consultant's violation of this Section.
25. NOTICES
25.1 All notices, demands, requests or approvals, including any change in
mailing address, to be given under the terms of this Agreement shall be given in writing,
and conclusively shall be deemed served when delivered personally, or on the third
business day after the deposit thereof in the United States mail, postage prepaid, first-
class mail, addressed as hereinafter provided.
25.2 All notices, demands, requests or approvals from Consultant to City shall
be addressed to City at:
Attn: Director of Public Works
Public Works Department
City of Newport Beach
100 Civic Center Drive
PO Box 1768
Newport Beach, CA 92658
25.3 All notices, demands, requests or approvals from City to Consultant shall
be addressed to Consultant at:
Attn: Thomas Fischetti
Noble Consultants, Inc.
2201 Dupont Drive, Suite 830
Irvine, CA 92612
26. CLAIMS
Unless a shorter time is specified elsewhere in this Agreement, before making its
final request for payment under this Agreement, Consultant shall submit to City, in
writing, all claims for compensation under or arising out of this Agreement. Consultant's
acceptance of the final payment shall constitute a waiver of all claims for compensation
under or arising out of this Agreement except those previously made in writing and
identified by Consultant in writing as unsettled at the time of its final request for
payment. Consultant and City expressly agree that in addition to any claims filing
requirements set forth in the Agreement, Consultant shall be required to file any claim
Consultant may have against City in strict conformance with the Government Claims Act
(Government Code sections 900 of seq.).
Noble Consultants, Inc. Page 9
6-52
27. TERMINATION
27.1 In the event that either party fails or refuses to perform any of the
provisions of this Agreement at the time and in the manner required, that party shall be
deemed in default in the performance of this Agreement. If such default is not cured
within a period of two (2) calendar days, or if more than two (2) calendar days are
reasonably required to cure the default and the defaulting party fails to give adequate
assurance of due performance within two (2) calendar days after receipt of written
notice of default, specifying the nature of such default and the steps necessary to cure
such default, and thereafter diligently take steps to cure the default, the non -defaulting
party may terminate the Agreement forthwith by giving to the defaulting party written
notice thereof.
27.2 Notwithstanding the above provisions, City shall have the right, at its sole
and absolute discretion and without cause, of terminating this Agreement at any time by
giving no less than seven (7) calendar days' prior written notice to Consultant. In the
event of termination under this Section, City shall pay Consultant for Services
satisfactorily performed and costs incurred up to the effective date of termination for
which Consultant has not been previously paid. On the effective date of termination,
Consultant shall deliver to City all reports, Documents and other information developed
or accumulated in the performance of this Agreement, whether in draft or final form.
28. STANDARD PROVISIONS
28.1 Recitals. City and Consultant acknowledge that the above Recitals are
true and correct and are hereby incorporated by reference into this Agreement.
28.2 Compliance with all Laws. Consultant shall, at its own cost and expense,
comply with all statutes, ordinances, regulations and requirements of all governmental
entities, including federal, state, county or municipal, whether now in force or hereinafter
enacted. In addition, all Work prepared by Consultant shall conform to applicable City,
county, state and federal laws, rules, regulations and permit requirements and be
subject to approval of the Project Administrator and City.
28.3 Waiver. A waiver by either party of any breach, of any term, covenant or
condition contained herein shall not be deemed to be a waiver of any subsequent
breach of the same or any other term, covenant or condition contained herein, whether
of the same or a different character.
28.4 Integrated Contract. This Agreement represents the full and complete
understanding of every kind or nature whatsoever between the parties hereto, and all
preliminary negotiations and agreements of whatsoever kind or nature are merged
herein. No verbal agreement or implied covenant shall be held to vary the provisions
herein.
28.5 Conflicts or Inconsistencies. In the event there are any conflicts or
inconsistencies between this Agreement and the Scope of Services or any other
attachments attached hereto, the terms of this Agreement shall govern.
Noble Consultants, Inc. Page 10 6-53
28.6 Interpretation. The terms of this Agreement shall be construed in
accordance with the meaning of the language used and shall not be construed for or
against either party by reason of the authorship of the Agreement or any other rule of
construction which might otherwise apply.
28.7 Amendments. This Agreement may be modified or amended only by a
written document executed by both Consultant and City and approved as to form by the
City Attorney.
28.8 Severability. If any term or portion of this Agreement is held to be invalid,
illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining
provisions of this Agreement shall continue in full force and effect.
28.9 Controlling Law and Venue. The laws of the State of California shall
govern this Agreement and all matters relating to it and any action brought relating to
this Agreement shall be adjudicated in a court of competent jurisdiction in the County of
Orange, State of California.
28.10 Equal Opportunity Employment. Consultant represents that it is an equal
opportunity employer and it shall not discriminate against any subcontractor, employee
or applicant for employment because race, religious creed, color, national origin,
ancestry, physical handicap, medical condition, marital status, sex, sexual orientation,
age or any other impermissible basis under law.
28.11 No Attorneys' Fees. In the event of any dispute or legal action arising
under this Agreement, the prevailing party shall not be entitled to attorneys' fees.
28.12 Counterparts. This Agreement may be executed in two (2) or more
counterparts, each of which shall be deemed an original and all of which together shall
constitute one (1) and the same instrument.
[SIGNATURES ON NEXT PAGE]
Noble Consultants, Inc. Page 11
6-54
IN WITNESS WHEREOF, the parties have caused this Agreement to be
executed on the dates written below.
APPROVED AS TO FORM:
CITY ATTORNEY'S OFFICE
Date: 3 - 2 /_ z2
By:
of n C. H (AN,n1711M
qty Attey
ATTEST:
Date:
Leilani I. Brown
City Clerk
CITY OF NEWPORT BEACH,
a California municipal corporation
Date:
By:
Kevin Muldoon
Mayor
CONSULTANT: Noble Consultants, Inc., a
California corporation
Date:
By:
Thomas Fischetti
Vice President
[END OF SIGNATURES]
Attachments: Exhibit A — Scope of Services
Exhibit B — Schedule of Billing Rates
Exhibit C — Insurance Requirements
Noble Consultants, Inc. Page 12
6-55
EXHIBIT A
SCOPE OF SERVICES
The following is a list of the services requested as part of this agreement for on-call
marine engineering services. Consultant shall be responsible for deploying and storing
any vessels or equipment related to the services provided under this agreement. The
services requested include, but are not limited to, the following:
1. Assist in the design and permitting of docks, piers, floats, wharfs, gangways
for public facilities, with attention to Americans with Disabilities Act (ADA) and
other regulatory requirements.
2. Assist in the design and permitting of dredging projects within docks, marinas,
small confined channels or larger main channels, using either the City's RGP-
54 dredging permit or the traditional Individual Permit process (California
Coastal Commission, Corps of Engineers, Water Board).
3. Collect sediment samples and generate grain size analysis reports.
4. Assist in the detailed management of the City's existing, five-year Regional
General Permit (RGP-54) as well as negotiating any intermediate
improvements to the program, as needed.
5. Provide various bathymetry surveys within docks, marinas, small confined
channels or larger main channels.
6. Prepare dredged material Sampling and Analysis Plans (SAPs) and Sampling
and Analysis Reports (SAR) in support of permitting activities with regulatory
agencies including the Dredged Material Management Team (DMMT) and
individual regulatory and resources agencies, as needed.
7. Conduct field collection of marine sediments and marine test organisms as
required for chemical and biological testing during a typical permitting project
(usually dredging).
8. Conduct chemical, biological and toxicity testing/analyses of bulk sediments
and marine test organisms to support chemical and biological testing during a
typical permitting project (usually dredging).
9. Conduct Caulerpa and eelgrass surveys, or assist in managing these studies,
including the harbor -wide biennial eelgrass survey as part of the "Eelgrass
Protection and Mitigation Plan for Shallow Waters in Lower Newport Bay: An
Ecosystem Based Management Approach."
Noble Consultants, Inc. Page A-1 6-56
10. Assist in the design and permitting of bulkheads and their structural
components for public facilities or property owned by the City.
11. Project management with various harbor related tasks to assist the Public
Works Department. Projects may include larger dock/bulkhead construction
projects, permitting programs, organizing public outreach campaigns, or other
projects as assigned by Public Works.
12. Depending upon the characteristics of a project and its potential for significant
environmental effects, a CEQA review may be needed. For the scope of this
proposal, the Consultant may prepare an Initial Study.
13. Preparation of record drawings.
14. Present projects, findings, information etc. at various public meetings
including the City Council, Harbor Commission, various ad hoc committee
meetings and other outreach events as required.
15. Other marine and/or harbor related engineering and professional services as
needed.
Noble Consultants, Inc. Page A-2 6-57
EXHIBIT B
SCHEDULE OF BILLING RATES
Noble Consultants, Inc. Page B-1 6-58
Hourly Labor Charges
Principal Engineer
$290
Construction Cost Estimator
$168
Senior Associate Engineer
254
Senior Survey Engineer
168
Associate Engineer
238
Staff Engineer III
164
Associate Economist
238
Staff Engineer II
158
Senior Structural Engineer II
222
Staff Engineer I
142
Senior Structural Engineer I
206
Surveyor II
138
Senior Engineer II
222
Surveyor I
122
Senior Engineer I
206
Senior Construction Inspector
134
Structural Engineer
194
CADD Designer/Operator
134
Project Engineer II
182
Assistant Engineer
126
Project Engineer I
168
Construction Inspector
122
Construction Manager
178
Technician
104
Word Processing / Clerical
94
* Depositions, mediations, arbitrations, and court appearance labor is two times the rate
shown and billed in 1/2 -day increments.
Reimbursable Expenses
CADD Plots (24 x 36)
$2.00 per page Generator 50 per day
Photocopying
0.30 per page Inspector Boat 100 per day
Color Photocopy (8-1/2x11)
1.00 per page Automobile 1.00 per mile
Color Photocopy (11x17)
1.50 per page
Out -of -Pocket
Reimbursable expenses billed at cost plus 15%.
Invoices
Invoices are due and payable on presentation. Interest at 1.5% per month (but not
exceeding the maximum rate allowable by law) is payable on any amounts not paid within
30 days.
6-59
EXHIBIT C
INSURANCE REQUIREMENTS — PROFESSIONAL SERVICES
1. Provision of Insurance. Without limiting Consultant's indemnification of City, and
prior to commencement of Work, Consultant shall obtain, provide and maintain at
its own expense during the term of this Agreement, policies of insurance of the
type and amounts described below and in a form satisfactory to City. Consultant
agrees to provide insurance in accordance with requirements set forth here. If
Consultant uses existing coverage to comply and that coverage does not meet
these requirements, Consultant agrees to amend, supplement or endorse the
existing coverage.
2. Acceptable Insurers. All insurance policies shall be issued by an insurance
company currently authorized by the Insurance Commissioner to transact
business of insurance in the State of California, with an assigned policyholders'
Rating of A- (or higher) and Financial Size Category Class VII (or larger) in
accordance with the latest edition of Best's Key Rating Guide, unless otherwise
approved by the City's Risk Manager.
3. Coverage Requirements.
A. Workers' Compensation Insurance. Consultant shall maintain Workers'
Compensation Insurance, statutory limits, and Employer's Liability
Insurance with limits of at least one million dollars ($1,000,000) each
accident for bodily injury by accident and each employee for bodily injury
by disease in accordance with the laws of the State of California, Section
3700 of the Labor Code.
Consultant shall submit to City, along with the certificate of insurance, a
Waiver of Subrogation endorsement in favor of City, its City Council,
boards and commissions, officers, agents, volunteers, employees and any
person or entity owning or otherwise in legal control of the property upon
which Consultant performs the Project and/or Services contemplated by
this Agreement.
B. General Liability Insurance. Consultant shall maintain commercial general
liability insurance, and if necessary umbrella liability insurance, with
coverage at least as broad as provided by Insurance Services Office form
CG 00 01, in an amount not less than one million dollars ($1,000,000) per
occurrence, two million dollars ($2,000,000) general aggregate. The
policy shall cover liability arising from premises, operations, personal and
advertising injury, and liability assumed under an insured contract
(including the tort liability of another assumed in a business contract).
C. Automobile Liability Insurance. Consultant shall maintain automobile
insurance at least as broad as Insurance Services Office form CA 00 01
covering bodily injury and property damage for all activities of Consultant
arising out of or in connection with Work to be performed under this
Noble Consultants, Inc. Page C-1 6-60
Agreement, including coverage for any owned, hired, non -owned or rented
vehicles, in an amount not less than one million dollars ($1,000,000)
combined single limit each accident.
D. Professional Liability (Errors & Omissions) Insurance. Consultant shall
maintain professional liability insurance that covers the Services to be
performed in connection with this Agreement, in the minimum amount of
one million dollars ($1,000,000) per claim and two million dollars
($2,000,000) in the aggregate. Any policy inception date, continuity date,
or retroactive date must be before the Effective Date of this Agreement
and Consultant agrees to maintain continuous coverage through a period
no less than three years after completion of the Services required by this
Agreement.
4. Other Insurance Requirements. The policies are to contain, or be endorsed to
contain, the following provisions:
A. Waiver of Subrogation. All insurance coverage maintained or procured
pursuant to this Agreement shall be endorsed to waive subrogation
against City, its City Council, boards and commissions, officers, agents,
volunteers, employees and any person or entity owning or otherwise in
legal control of the property upon which Consultant performs the Project
and/or Services contemplated by this Agreement or shall specifically allow
Consultant or others providing insurance evidence in compliance with
these requirements to waive their right of recovery prior to a loss.
Consultant hereby waives its own right of recovery against City, and shall
require similar written express waivers from each of its subconsultants.
B. Additional Insured Status. All liability policies including general liability,
excess liability, pollution liability, and automobile liability, if required, but
not including professional liability, shall provide or be endorsed to provide
that City, its City Council, boards and commissions, officers, agents,
volunteers, employees and any person or entity owning or otherwise in
legal control of the property upon which Consultant performs the Project
and/or Services contemplated by this Agreement shall be included as
insureds under such policies.
C. Primary and Non Contributory. All liability coverage shall apply on a
primary basis and shall not require contribution from any insurance or self-
insurance maintained by City.
D. Notice of Cancellation. All policies shall provide City with thirty (30)
calendar days' notice of cancellation (except for nonpayment for which ten
(10) calendar days' notice is required) or nonrenewal of coverage for each
required coverage.
5. Additional Agreements Between the Parties. The parties hereby agree to the
following:
Noble Consultants, Inc. Page C-2 6-61
A. Evidence of Insurance. Consultant shall provide certificates of insurance
to City as evidence of the insurance coverage required herein, along with
a waiver of subrogation endorsement for workers' compensation and other
endorsements as specified herein for each coverage. Insurance
certificates and endorsement must be approved by City's Risk Manager
prior to commencement of performance. Current certification of insurance
shall be kept on file with City at all times during the term of this
Agreement. The certificates and endorsements for each insurance policy
shall be signed by a person authorized by that insurer to bind coverage on
its behalf. At least fifteen (15) days prior to the expiration of any such
policy, evidence of insurance showing that such insurance coverage has
been renewed or extended shall be filed with the City. If such coverage is
cancelled or reduced, Consultant shall, within ten (10) days after receipt of
written notice of such cancellation or reduction of coverage, file with the
City evidence of insurance showing that the required insurance has been
reinstated or has been provided through another insurance company or
companies. City reserves the right to require complete, certified copies of
all required insurance policies, at any time.
B. City's Right to Revise Requirements. City reserves the right at any time
during the term of the Agreement to change the amounts and types of
insurance required by giving Consultant sixty (60) calendar days' advance
written notice of such change. If such change results in substantial
additional cost to Consultant, City and Consultant may renegotiate
Consultant's compensation.
C. Right to Review Subcontracts. Consultant agrees that upon request, all
agreements with subcontractors or others with whom Consultant enters
into contracts with on behalf of City will be submitted to City for review.
Failure of City to request copies of such agreements will not impose any
liability on City, or its employees. Consultant shall require and verify that
all subcontractors maintain insurance meeting all the requirements stated
herein, and Consultant shall ensure that City is an additional insured on
insurance required from subcontractors. For CGL coverage,
subcontractors shall provide coverage with a format at least as broad as
CG 20 38 04 13.
D. Enforcement of Agreement Provisions. Consultant acknowledges and
agrees that any actual or alleged failure on the part of City to inform
Consultant of non-compliance with any requirement imposes no additional
obligations on City nor does it waive any rights hereunder.
E. Requirements not Limiting. Requirements of specific coverage features or
limits contained in this Section are not intended as a limitation on
coverage, limits or other requirements, or a waiver of any coverage
normally provided by any insurance. Specific reference to a given
coverage feature is for purposes of clarification only as it pertains to a
given issue and is not intended by any party or insured to be all inclusive,
or to the exclusion of other coverage, or a waiver of any type. If the
Noble Consultants, Inc. Page C-3 6-62
Consultant maintains higher limits than the minimums shown above, the
City requires and shall be entitled to coverage for higher limits maintained
by the Consultant. Any available insurance proceeds in excess of the
specified minimum limits of insurance and coverage shall be available to
the City.
F. Self-insured Retentions. Any self-insured retentions must be declared to
and approved by City. City reserves the right to require that self-insured
retentions be eliminated, lowered, or replaced by a deductible. Self-
insurance will not be considered to comply with these requirements unless
approved by City.
G. City Remedies for Non -Compliance. If Consultant or any subconsultant
fails to provide and maintain insurance as required herein, then City shall
have the right but not the obligation, to purchase such insurance, to
terminate this Agreement, or to suspend Consultant's right to proceed until
proper evidence of insurance is provided. Any amounts paid by City shall,
at City's sole option, be deducted from amounts payable to Consultant or
reimbursed by Consultant upon demand.
H. Timely Notice of Claims. Consultant shall give City prompt and timely
notice of claims made or suits instituted that arise out of or result from
Consultant's performance under this Agreement, and that involve or may
involve coverage under any of the required liability policies. City assumes
no obligation or liability by such notice, but has the right (but not the duty)
to monitor the handling of any such claim or claims if they are likely to
involve City.
Consultant's Insurance. Consultant shall also procure and maintain, at its
own cost and expense, any additional kinds of insurance, which in its own
judgment may be necessary for its proper protection and prosecution of
the Work.
Noble Consultants, Inc. Page C-4 6-63