HomeMy WebLinkAboutC-5231 - Service Agreement for Mooring Support Services for the Lower Newport Bay Dredging ProjectSERVICE AGREEMENT
WITH NEWPORT DREDGING COMPANY DBA SOUTH MOORING COMPANY
Vin\ FOR MOORING SUPPORT SERVICES FOR THE LOWER NEWPORT BAY
1 DREDGING PROJECT
THIS SERVICE AGREEMENT ( "Agreement') is made and entered into as of this
d
V) � y tr + W22012 ( "Effective Date ") by and between the CITY OF NEWPORT
c— BEACH, a California Municipal Corporation ( "City'), and NEWPORT DREDGING
v COMPANY, a California corporation doing business as ( "DBA ") SOUTH MOORING
COMPANY ( "Contractor "), whose address is P.O. Box 528, Newport Beach, CA 92661
and is made with reference to the following:
RECITALS
A. City is a municipal corporation duly organized and validly existing under the laws
of the State of California with the power to carry on its business as it is now being
conducted under the statutes of the State of California and the Charter of City.
B. City desires to engage Contractor to provide mooring support and relocation
services for the Lower Newport Bay Dredging Project ( "Project').
C. Contractor possesses the skill, experience, ability, background, certification and
knowledge to provide the services described in this Agreement.
D. The principal member of Contractor for purposes of Project shall be Chuck
South.
E. City has solicited and received a proposal from Contractor, has reviewed the
previous experience and evaluated the expertise of Contractor, and desires to
retain Contractor to render professional services under the terms and conditions
set forth in this Agreement.
NOW, THEREFORE, it is mutually agreed by and between the undersigned
parties as follows:
1. TERM
The term of this Agreement shall commence on the ( "Effective Date "), and shall
terminate on June 30, 2013 unless terminated earlier as set forth herein.
2. SERVICES TO BE PERFORMED
City and Contractor acknowledge that the above Recitals are true and correct
and are hereby incorporated by reference into this Agreement. Contractor shall
diligently perform all the services described in the Scope of Services attached hereto as
Exhibit A and incorporated herein by reference ( "Services" or "Work "). The City may
elect to delete certain Services within the Scope of Services at its sole discretion.
3. TIME OF PERFORMANCE
3.1 Time is of the essence in the performance of Services under this
Agreement and Contractor shall perform the Services in accordance with the schedule
included in Exhibit A. In the absence of a specific schedule, the Services shall be
performed to completion in a diligent and timely manner. The failure by Contractor to
strictly adhere to the schedule set forth in Exhibit A, if any, or perform the Services in a
diligent and timely manner may result in termination of this Agreement by City.
3.1.1 Notwithstanding the foregoing, Contractor shall not be responsible
for delays due to causes beyond Contractor's reasonable control. However, in the case
of any such delay in the Services to be provided for the Project, each party hereby
agrees to provide notice within two (2) days of the occurrence causing the delay to the
other party so that all delays can be addressed.
3.2 Contractor shall submit all requests for extensions of time for performance
in writing to the Project Administrator (as defined in Section 6 below) not later than ten
(10) calendar days after the start of the condition that purportedly causes a delay. The
Project Administrator shall review all such requests and may grant reasonable time
extensions for unforeseeable delays that are beyond Contractor's control.
3.3 For all time periods not specifically set forth herein, Contractor shall
respond in the most expedient and appropriate manner under the circumstances, by
fax, hand - delivery or mail.
4. COMPENSATION TO CONTRACTOR
4.1 City shall pay Contractor for the Services on a time and expense not -to-
exceed basis in accordance with the provisions of this Section and the Schedule of
Billing Rates or Progress Payments Schedule attached hereto as Exhibit B and
incorporated herein by reference. Contractor's compensation for all Work performed in
accordance with this Agreement, including all reimbursable items and subcontractor
fees, shall not exceed Seventy -Five Thousand Dollars and 00/100 ($75,000.00)
without prior written authorization from City. No billing rate changes shall be made
during the term of this Agreement without the prior written approval of City.
4.2 Contractor shall submit monthly invoices to City describing the Work
performed the preceding month. Contractor's bills shall include the name of the person
who performed the Work, a brief description of the Services performed and /or the
specific task in the Scope of Services to which it relates, the date the Services were
performed, the number of hours spent on all Work billed on an hourly basis, and a
description of any reimbursable expenditures. City shall pay Contractor no later than
thirty (30) days after approval of the monthly invoice by City staff.
4.3 City shall reimburse Contractor only for those costs or expenses
specifically identified in Exhibit B to this Agreement, or specifically approved in writing in
advance by City.
4.4 Contractor shall not receive any compensation for Extra Work performed
without the prior written authorization of City. As used herein, "Extra Work" means any
Newport Dredging Company DBA South Mooring Company Page 2
Work that is determined by City to be necessary for the proper completion of the
Project, but which is not included within the Scope of Services and which the parties did
not reasonably anticipate would be necessary at the execution of this Agreement.
Compensation for any authorized Extra Work shall be paid in accordance with the
Schedule of Billing Rates as set forth in Exhibit B.
5. PROJECT MANAGER
5.1 Contractor shall designate a Project Manager, who shall coordinate all
phases of the Project. This Project Manager shall be available to City at all reasonable
times during the Agreement term. Contractor has designated Chuck South to be its
Project Manager. Contractor shall not remove or reassign the Project Manager or any
personnel listed in Exhibit A or assign any new or replacement personnel to the Project
without the prior written consent of City. City's approval shall not be unreasonably
withheld with respect to the removal or assignment of non -key personnel.
5.2 Contractor, at the sole discretion of City, shall remove from the Project any
of its personnel assigned to the performance of Services upon written request of City.
Contractor warrants that it will continuously furnish the necessary personnel to complete
the Project on a timely basis as contemplated by this Agreement.
6. ADMINISTRATION
This Agreement will be administered by the Public Works Department. Chris
Miller, Harbor Resources Manager or his designee, shall be the Project Administrator
and shall have the authority to act for City under this Agreement. The Project
Administrator or his designee shall represent City in all matters pertaining to the
Services to be rendered pursuant to this Agreement.
7. CITY'S RESPONSIBILITIES
To assist Contractor in the execution of its responsibilities under this Agreement,
City agrees to provide access to and upon request of Contractor, one (1) copy of all
existing relevant information on file at City. City will provide all such materials in a
timely manner so as not to cause delays in Contractor's Work schedule.
8. STANDARD OF CARE
8.1 All of the Services shall be performed by Contractor or under Contractor's
supervision. Contractor represents that it possesses the professional and technical
personnel required to perform the Services required by this Agreement, and that it will
perform all Services in a manner commensurate with the highest industry standards.
For purposes of this Agreement, the phrase "highest industry standards" shall mean
those standards of practice recognized by one (1) or more first -class firms performing
similar work under similar circumstances.
8.2
All Services shall be performed by qualified and experienced
personnel
who are not
employed
by City, nor have any contractual relationship with
City. By
delivery of
completed
Work, Contractor certifies that the Work conforms to the
Newport Dredging Company DBA South Mooring Company Page 3
requirements of this Agreement and all applicable federal, state and local laws and the
highest industry standard.
8.3 Contractor represents and warrants to City that it has, shall obtain, and
shall keep in full force and effect during the term hereof, at its sole cost and expense, all
licenses, permits, qualifications, insurance and approvals of whatsoever nature that is
legally required of Contractor to practice its profession. Contractor shall maintain a City
of Newport Beach business license during the term of this Agreement.
8.4 Contractor shall not be responsible for delay, nor shall Contractor be
responsible for damages or be in default or deemed to be in default by reason of strikes,
lockouts, accidents, or acts of God, or the failure of City to furnish timely information or
to approve or disapprove Contractor's Work promptly, or delay or faulty performance by
City, contractors, or governmental agencies.
9.1 To the fullest extent permitted by law, Contractor shall indemnify, defend
and hold harmless City, its City Council, boards and commissions, officers, agents and
employees (collectively, the 'Indemnified Parties ") from and against any and all claims
(including, without limitation, claims for bodily injury, death or damage to property),
demands, obligations, damages, actions, causes of action, suits, losses, judgments,
fines, penalties, liabilities, costs and expenses (including, without limitation, attorney's
fees, disbursements and court costs) of every kind and nature whatsoever (individually,
a Claim; collectively, "Claims'), which may arise from or in any manner relate (directly or
indirectly) to any breach of the terms and conditions of this Agreement, any Work
performed or Services provided under this Agreement including, without limitation,
defects in workmanship or materials or Contractor's presence or activities conducted on
the Project (including the negligent and /or willful acts, errors and /or omissions of
Contractor, its principals, officers, agents, employees, vendors, suppliers, consultants,
subcontractors, anyone employed directly or indirectly by any of them or for whose acts
they may be liable or any or all of them).
9.2 Notwithstanding the foregoing, nothing herein shall be construed to
require Contractor to indemnify the Indemnified Parties from any Claim arising from the
sole negligence or willful misconduct of the Indemnified Parties. Nothing in this
indemnity shall be construed as authorizing any award of attorney's fees in any action
on or to enforce the terms of this Agreement. This indemnity shall apply to all claims
and liability regardless of whether any insurance policies are applicable. The policy
limits do not act as a limitation upon the amount of indemnification to be provided by the
Contractor.
10. INDEPENDENT CONTRACTOR
It is understood that City retains Contractor on an independent contractor basis
and Contractor is not an agent or employee of City. The manner and means of
conducting the Work are under the control of Contractor, except to the extent they are
limited by statute, rule or regulation and the expressed terms of this Agreement. No
civil service status or other right of employment shall accrue to Contractor or its
Newport Dredging Company DBA South Mooring Company Page 4
employees. Nothing in this Agreement shall be deemed to constitute approval for
Contractor or any of Contractor's employees or agents, to be the agents or employees
of City. Contractor shall have the responsibility for and control over the means of
performing the Work, provided that Contractor is in compliance with the terms of this
Agreement. Anything in this Agreement that may appear to give City the right to direct
Contractor as to the details of the performance of the Work or to exercise a measure of
control over Contractor shall mean only that Contractor shall follow the desires of City
with respect to the results of the Services.
11. COOPERATION
Contractor agrees to work closely and cooperate fully with City's designated
Project Administrator and any other agencies that may have jurisdiction or interest in the
Work to be performed. City agrees to cooperate with the Contractor on the Project.
12. CITY POLICY
Contractor shall discuss and review all matters relating to policy and Project
direction with City's Project Administrator in advance of all critical decision points in
order to ensure the Project proceeds in a manner consistent with City goals and
policies.
ik3IIIIIIIIII11 :T01C3 :Jl4-*i
Contractor is responsible for keeping the Project Administrator and /or his /her
duly authorized designee informed on a regular basis regarding the status and progress
of the Project, activities performed and planned, and any meetings that have been
scheduled or are desired.
14. INSURANCE
14.1 Without limiting Contractor's indemnification of City, and prior to
commencement of Work Contractor shall obtain, provide and maintain at its own
expense during the term of this Agreement, policies of insurance of the type and
amounts described below and in a form satisfactory to City. The cost of such insurance
shall be included in Contractor's bid.
14.2 Coverage and Limit Requirements.
14.2.1 Workers' Compensation. Contractor shall maintain Workers'
Compensation Insurance providing statutory benefits and employer's liability insurance
with limits of at least one million dollars ($1,000,000) each type for Contractor's
employees in accordance with the laws of the State of California, Section 3700 of the
Labor Code. In addition, Contractor shall require each subcontractor to similarly
maintain Workers' Compensation Insurance and Employer's Liability Insurance in
accordance with the laws of the State of California, Section 3700 for all of the
subcontractor's employees. The insurer issuing the Workers' Compensation insurance
shall amend its policy by endorsement to waive all rights of subrogation against City, its
elected or appointed officers, agents, officials, employees and volunteers. Contractor
Newport Dredging Company DBA South Mooring Company Page 5
shall submit to City, along with the required certificate of insurance, a copy of such
waiver of subrogation endorsement.
14.2.2 General Liability. Contractor shall maintain commercial general
liability insurance in an amount not less than one million dollars ($1,000,000) per
occurrence, two million dollars ($2,000,000) General Aggregate and two million dollars
($2,000,000) Products and Completed Operations Aggregate for bodily injury, personal
injury, and property damage, including without limitation, blanket contractual liability.
Coverage shall be at least as broad as that provided by Insurance Services Office form
CG 00 01. None of the policies required herein shall be in compliance with these
requirements if they include any limiting endorsement that has not been first submitted
to City and approved in writing.
14.2.3 Automobile Liability. Contractor shall maintain automobile
insurance covering bodily injury and property damage for all activities of the Contractor
arising out of or in connection with Work to be performed under this Agreement,
including coverage for any owned, hired, non -owned or rented vehicles, in an amount
not less than one million dollars ($1,000,000) combined single limit for each accident.
14.2.4 Builders Risk. For Agreements or Contracts with
Construction /Builders Risk property exposures, Contractor shall maintain Builders Risk
insurance or an installation floater as directed by City, covering damages to the Work
for "all risk" or special form causes of loss with limits equal to one hundred percent
(100°/x) of the completed value of contract, with coverage to continue until final
acceptance of the Work by City. At the discretion of City, the requirement for such
coverage may include additional protection for Earthquake and /or Flood. City shall be
included as an insured on such policy, and Contractor shall provide the City with a copy
of the policy.
14.3 Other Insurance Provisions or Requirements.
14.3.1 Evidence of Insurance. Contractor shall provide certificates of
insurance to City as evidence of the insurance coverage required herein, along with a
waiver of subrogation endorsement for workers' compensation and an additional
insured endorsement for general liability. Insurance certificates and endorsements
must be approved by City's Risk Manager prior to commencement of performance or
issuance of any permit. Current evidence of insurance shall be kept on file with City at
all times during the term of this Agreement. All of the executed documents referenced in
this Agreement must be returned within ten (10) working days after the date on the
"Notification of Award," so that the City may review and approve all insurance and bond
documentation. City reserves the right to require complete, certified copies of all
required insurance policies, at any time.
14.3.2 General liability insurance provisions. Primary and excess or
umbrella liability policies are to contain, or be endorsed to contain, the following
provisions:
14.3.2.1 City, its elected or appointed officers, agents, officials,
employees, and volunteers are to be covered as additional insureds as respects: liability
Newport Dredging Company DBA South Mooring Company Page 6
arising out of activities performed by or on behalf of Contractor, including the insured's
general supervision of Contractor; products and completed operations of Contractor;
premises owned, occupied or used by Contractor. The coverage shall contain no
special limitations on the scope of protection afforded to City, its elected or appointed
officers, officials, employees, agents or volunteers. Contractor shall submit to City a
copy of the additional insured endorsement along with the required certificates of
insurance.
14.3.2.2 Contractors insurance coverage shall be primary
insurance and /or primary source of recovery as respects City, its elected or appointed
officers, agents, officials, employees and volunteers as respects to all claims, losses, or
liability arising directly or indirectly from the Contractor's operations or services provided
to the City. Any insurance or self- insurance maintained by City, its officers, officials,
employees and volunteers shall be excess of the Contractor's insurance and shall not
contribute with it.
14.3.2.3 Contractor's insurance shall apply separately to each
insured against whom claim is made or suit is brought, except with respect to the limits
of the insurer's liability.
14.4 Acceptable Insurers. All insurance policies shall be issued by an
insurance company currently authorized by the Insurance Commissioner to transact
business of insurance in the State of California, with an assigned policyholders' Rating
of A- (or higher) and Financial Size Category Class VII (or larger) in accordance with the
latest edition of Best's Key Rating Guide, unless otherwise approved by the City's Risk
Manager.
14.5 Notice of Cancellation. Contractor agrees to oblige its insurance broker
and insurers to provide to City with 30 days notice of cancellation (except for
nonpayment for which 10 days notice is required) or nonrenewal of coverage for each
required coverage except for builder's risk insurance. The builder's risk policy will
contain or be endorsed to contain a provision providing for 30 days written notice to City
of cancellation or nonrenewal, except for nonpayment for which 10 days notice is
required.
14.6 Self - Insured Retentions. Contractor agrees not to self- insure or to use any
self- insured retentions on any portion of the insurance required herein and further
agrees that it will not allow any indemnifying party to self- insure its obligations to City. If
contractors existing coverage includes a self- insured retention, the self- insured
retention must be declared to City. City may review options with the contractor, which
may include reduction or elimination of the self- insured retention, substitution of other
coverage, or other solutions. Contractor agrees to be responsible for payment of any
deductibles on their policies.
14.7 Timely Notice of Claims. Contractor shall give City prompt and timely
notice of any claim made or suit instituted arising out of or resulting from Contractor's
performance under this agreement.
Newport Dredging Company DBA South Mooring Company Page 7
14.8 Waiver. All insurance coverage maintained or procured pursuant to this
agreement shall be endorsed to waive subrogation against City, its elected or appointed
officers, agents, officials, employees and volunteers, or shall specifically allow
Contractor or others providing insurance evidence in compliance with these
requirements to waive their right of recovery prior to a loss. Contractor hereby waives its
own right of recovery against City, and shall require similar written express waivers and
insurance clauses from each of its subcontractors.
14.9 Enforcement of Agreement Provisions. Contractor acknowledges and
agrees that any actual or alleged failure on the part of the City to inform Contractor of
non - compliance with any requirement imposes no additional obligations on the City nor
does it waive any rights hereunder.
14.10 Requirements not Limiting. Requirements of specific coverage features or
limits contained in this Section are not intended as a limitation on coverage, limits or
other requirements, or a waiver of any coverage normally provided by any insurance.
Specific reference to a given coverage feature is for purposes of clarification only as it
pertains to a given issue and is not intended by any party or insured to be all inclusive,
or to the exclusion of other coverage, or a waiver of any type.
14.11 City's Remedies. City shall have the right to order the Contractor to stop
Work under this Agreement and /or withhold any payment(s) that become due to
Contractor hereunder until Contractor demonstrates compliance with the requirements
of this article. In the alternative, City may purchase the required coverage and charge
Contractor the cost of the premiums or deduct the cost from Contractor's payments.
14.12 Coverage not Limited. All insurance coverage and limits provided by
contractor and available or applicable to this agreement are intended to apply to the full
extent of the policies. Nothing contained in this agreement or any other agreement
relating to the city or its operations limits the application of such insurance coverage.
14.13 Coverage Renewal. Contractor will renew the coverage required here
annually as long as Contractor continues to provide any Services under this or any
other contract or agreement with the City. Contractor shall provide proof that policies of
insurance required herein expiring during the term of this Agreement have been
renewed or replaced with other policies providing at least the same coverage. Proof that
such coverage has been ordered shall be submitted prior to expiration. A coverage
binder or letter from Contractor's insurance agent to this effect is acceptable. A
certificate of insurance and /or additional insured endorsement as required in these
specifications applicable to the renewing or new coverage must be provided to City
within five days of the expiration of the coverages.
15. PROHIBITION AGAINST ASSIGNMENTS AND TRANSFERS
Except as specifically authorized under this Agreement, the Services to be
provided under this Agreement shall not be assigned, transferred contracted or
subcontracted out without the prior written approval of City. Any of the following shall
be construed as an assignment: The sale, assignment, transfer or other disposition of
any of the issued and outstanding capital stock of Contractor, or of the interest of any
Newport Dredging Company DBA South Mooring Company Page 8
general partner or joint venturer or syndicate member or cotenant if Contractor is a
partnership or joint-venture or syndicate or cotenancy, which shall result in changing the
control of Contractor. Control means fifty percent (50 %) or more of the voting power, or
twenty -five percent (25 %) or more of the assets of the corporation, partnership or joint -
venture.
16. SUBCONTRACTING
The subcontractors authorized by City, if any, to perform Work on this Project are
identified in Exhibit A. Contractor shall be fully responsible to City for all acts and
omissions of any subcontractor. Nothing in this Agreement shall create any contractual
relationship between City and any subcontractor nor shall it create any obligation on the
part of City to pay or to see to the payment of any monies due to any such
subcontractor other than as otherwise required by law. The City is an intended
beneficiary of any Work performed by the subcontractor for purposes of establishing a
duty of care between the subcontractor and the City. Except as specifically authorized
herein, the Services to be provided under this Agreement shall not be otherwise
assigned, transferred, contracted or subcontracted out without the prior written approval
of City.
17. OWNERSHIP OF DOCUMENTS
17.1 Each and every report, draft, map, record, plan, document and other
writing produced (hereinafter "Documents "), prepared or caused to be prepared by
Contractor, its officers, employees, agents and subcontractors, in the course of
implementing this Agreement, shall become the exclusive property of City, and City
shall have the sole right to use such materials in its discretion without further
compensation to Contractor or any other party. Contractor shall, at Contractor's
expense, provide such Documents to City upon prior written request.
17.2 Documents, including drawings and specifications, prepared by Contractor
pursuant to this Agreement are not intended or represented to be suitable for reuse by
City or others on any other project. Any use of completed Documents for other projects
and any use of incomplete Documents without specific written authorization from
Contractor will be at City's sole risk and without liability to Contractor. Further, any and
all liability arising out of changes made to Contractor's deliverables under this
Agreement by City or persons other than Contractor is waived against Contractor and
City assumes full responsibility for such changes unless City has given Contractor prior
notice and has received from Contractor written consent for such changes.
18. COMPUTER DELIVERABLES
All written documents shall be transmitted to City in the City's latest adopted
version of Microsoft Word, Excel or portable digital format (.pdf).
19. CONFIDENTIALITY
All Documents, including drafts, preliminary drawings or plans, notes and
communications that result from the Services in this Agreement, shall be kept
confidential unless City expressly authorizes in writing the release of information.
Newport Dredging Company DBA South Mooring Company Page 9
20. INTELLECTUAL PROPERTY INDEMNITY
The Contractor shall defend and indemnify City, its agents, officers,
representatives and employees against any and all liability, including costs, for
infringement or alleged infringement of any United States' letters patent, trademark, or
copyright, including costs, contained in Contractor's Documents provided under this
Agreement.
21. RECORDS
Contractor shall keep records and invoices in connection with the Services to be
performed under this Agreement. Contractor shall maintain complete and accurate
records with respect to the costs incurred under this Agreement and any Services,
expenditures and disbursements charged to City, for a minimum period of three (3)
years, or for any longer period required by law, from the date of final payment to
Contractor under this Agreement. All such records and invoices shall be clearly
identifiable. Contractor shall allow a representative of City to examine, audit and make
transcripts or copies of such records and invoices during regular business hours.
Contractor shall allow inspection of all Work, data, Documents, proceedings and
activities related to the Agreement for a period of three (3) years from the date of final
payment to Contractor under this Agreement.
22. WITHHOLDINGS
City may withhold payment to Contractor of any disputed sums until satisfaction
of the dispute with respect to such payment. Such withholding shall not be deemed to
constitute a failure to pay according to the terms of this Agreement. Contractor shall not
discontinue Work as a result of such withholding. Contractor shall have an immediate
right to appeal to the City Manager or his /her designee with respect to such disputed
sums. Contractor shall be entitled to receive interest on any withheld sums at the rate of
return that City earned on its investments during the time period, from the date of
withholding of any amounts found to have been improperly withheld.
23. ERRORS AND OMISSIONS
In the event of errors or omissions that are due to the negligence or professional
inexperience of Contractor which result in expense to City greater than what would have
resulted if there were not errors or omissions in the Work accomplished by Contractor,
the additional design, construction and /or restoration expense shall be borne by
Contractor. Nothing in this Section is intended to limit City's rights under the law or any
other sections of this Agreement.
24. CITY'S RIGHT TO EMPLOY OTHER CONTRACTORS
City reserves the right to employ other Contractors in connection with the Project.
25. CONFLICTS OF INTEREST
25.1 The Contractor or its employees may be subject to the provisions of the
California Political Reform Act of 1974 (the "Act "), which (1) requires such persons to
Newport Dredging Company DBA South Mooring Company Page 10
disclose any financial interest that may foreseeably be materially affected by the Work
performed under this Agreement, and (2) prohibits such persons from making, or
participating in making, decisions that will foreseeably financially affect such interest.
25.2 If subject to the Act, Contractor shall conform to all requirements of the
Act. Failure to do so constitutes a material breach and is grounds for immediate
termination of this Agreement by City. Contractor shall indemnify and hold harmless
City for any and all claims for damages resulting from Contractor's violation of this
Section.
26. NOTICES
26.1 All notices, demands, requests or approvals, including any change in
mailing address, to be given under the terms of this Agreement shall be given in writing,
and conclusively shall be deemed served when delivered personally, or on the third
business day after the deposit thereof in the United States mail, postage prepaid, first -
class mail, addressed as hereinafter provided. All notices, demands, requests or
approvals from Contractor to City shall be addressed to City at:
Attn: Chris Miller, Harbor Resources Manager
Public Works Department
City of Newport Beach
3300 Newport Boulevard
PO Box 1768
Newport Beach, CA 92658
Phone: (949) 644 -3043
Fax: (949) 723 -0589
26.2 All notices, demands, requests or approvals from City to Contractor shall
be addressed to Contractor at:
Attn: Chuck South
NEWPORT DREDGING COMPANY DBA SOUTH MOORING
COMPANY
PO Box 528
Newport Beach, CA 92661
Phone: (949) 645 -0334
Fax: (949) 645 -1041
27. CLAIMS
Unless a shorter time is specified elsewhere in this Agreement, before making its
final request for payment under this Agreement, Contractor shall submit to City, in
writing, all claims for compensation under or arising out of this Agreement.
Contractor's acceptance of the final payment shall constitute a waiver of all claims for
compensation under or arising out of this Agreement except those previously made in
writing and identified by Contractor in writing as unsettled at the time of its final request
for payment. The Contractor and the City expressly agree that in addition to any claims
filing requirements set forth in the Agreement, the Contractor shall be required to file
Newport Dredging Company DBA South Mooring Company Page 11
any claim the Contractor may have against the City in strict conformance with the Tort
Claims Act (Government Code sections 900 et seq.).
28. TERMINATION
28.1 In the event that either party fails or refuses to perform any of the
provisions of this Agreement at the time and in the manner required, that party shall be
deemed in default in the performance of this Agreement. If such default is not cured
within a period of two (2) calendar days, or if more than two (2) calendar days are
reasonably required to cure the default and the defaulting party fails to give adequate
assurance of due performance within two (2) calendar days after receipt of written
notice of default, specifying the nature of such default and the steps necessary to cure
such default, and thereafter diligently take steps to cure the default, the non - defaulting
party may terminate the Agreement forthwith by giving to the defaulting party written
notice thereof.
28.2 Notwithstanding the above provisions, City shall have the right, at its sole
and absolute discretion and without cause, of terminating this Agreement at any time by
giving no less than seven (7) calendar days prior written notice to Contractor. In the
event of termination under this Section, City shall pay Contractor for Services
satisfactorily performed and costs incurred up to the effective date of termination for
which Contractor has not been previously paid. On the effective date of termination,
Contractor shall deliver to City all reports, Documents and other information developed
or accumulated in the performance of this Agreement, whether in draft or final form.
29. STANDARD PROVISIONS
29.1 Compliance with all Laws. Contractor shall at its own cost and expense
comply with all statutes, ordinances, regulations and requirements of all governmental
entities, including federal, state, county or municipal, whether now in force or hereinafter
enacted. In addition, all Work prepared by Contractor shall conform to applicable City,
county, state and federal laws, rules, regulations and permit requirements and be
subject to approval of the Project Administrator and City.
29.2 Waiver. A waiver by either party of any breach, of any term, covenant or
condition contained herein shall not be deemed to be a waiver of any subsequent
breach of the same or any other term, covenant or condition contained herein, whether
of the same or a different character.
29.3 Integrated Contract. This Agreement represents the full and complete
understanding of every kind or nature whatsoever between the parties hereto, and all
preliminary negotiations and agreements of whatsoever kind or nature are merged
herein. No verbal agreement or implied covenant shall be held to vary the provisions
herein.
29.4 Conflicts or Inconsistencies. In the event there are any conflicts or
inconsistencies between this Agreement and the Scope of Services or any other
attachments attached hereto, the terms of this Agreement shall govern.
Newport Dredging Company DBA South Mooring Company Page 12
29.5 Interpretation. The terms of this Agreement shall be construed in
accordance with the meaning of the language used and shall not be construed for or
against either party by reason of the authorship of the Agreement or any other rule of
construction which might otherwise apply.
29.6 Amendments. This Agreement may be modified or amended only by a
written document executed by both Contractor and City and approved as to form by the
City Attorney.
29.7 Severability. If any term or portion of this Agreement is held to be invalid,
illegal, or otherwise unenforceable by a court of corpetent jurisdiction, the remaining
provisions of this Agreement shall continue in fullfode and effect.
29.8 Controlling Law and Venue. The laws of the State of California shall
govern this Agreement and all matters relating to it and any action brought relating to
this Agreement shall be adjudicated in a court of competent jurisdiction in the County of
Orange, State of California.
29.9 Equal Opportunity Employment. Contractor represents that it is an equal
opportunity employer and it shall not discriminate against any subcontractor, employee
or-applicant for employment because of race, religion, color, national origin, handicap,
ancestry, sex, age or any other impermissible basis under law.
29.10 No Attorney's Fees. In the event of any dispute or legal action arising
under this Agreement, the prevailing party shall not be entitled to attorney's fees.
29.11 Counterparts. This Agreement may be executed in two (2) or more
counterparts, each of which shall be deemed an original and all of which together shall
constitute one (1) and the same instrument.
[SIGNATURES ON NEXT PAGE]
Newport Dredging Company DBA South Mooring Company Page 13
IN WITNESS WHEREOF, the parties have caused this Agreement to be
executed on the dates written below.
APPROVED AS TO FORM:
CITY ATTORNEY'S OFFICE
Date: / / Z -
Aaron C. Harp
City Attorney
ATTEST: 011.
Date:
By: A/t�����r
tt
(� - NA-/
Leilani I. Brown
City Clerk
CITY OF NEWPORT BEACH,
A California municipal corporation
Date: 51011 - _.
Pu c,/Works Director
CO,N RACTOR: NEWPORT DREDGING
COMPANY, a California corporation doing
business as ("DBA") SOUTH MOORING
COMPANY
Date: '/<<
By
Charles South `-
President
Date: l%��i 2
By/q9)z�
Thomas ee
Treasurer
[END OF SIGNATURES]
Attachments: Exhibit A - Scope of Services
Exhibit B - Schedule of Billing Rates
f:\apps\cat\cycom\wpdocs\d017\p005\00006706.doc
Newport Dredging Company DBA South Mooring Company Page 14
21
I
Website:
www.SouthMooriiig.com
License 9 957414
email: ablesouth @yahoo.com
J_
South Mooring Company
a division of Newport Dredging Co. Inc.
P.O. Box 528
Newport Beach, CA 92661
Direct: 949.645.0334
Fax: 949.645.1041
March 26, 2012
Harbor Resources
Attu. Chris Miller
829 Harbor Island Drive
Newport Beach, CA 92660
Scope:
Relocate moorings in sections C, D, F, & NHYC for dredging
As is the case when working with permittee's there will be questions and
concerns about the new locations. It will be necessary to realign boats to
accommodate permittee's needs and concerns.
Over 90% of the permittee's are already South Mooring Customers, and I believe
this will help alleviate many of their concerns and they will able to call me
directly with those concerns.
Inclusions:
G.P.S. each end of moorings before it is moved to it's temporary location, and as
it is returned to its new location.
Move each boat and mooring in a timely manner to a location to be determined by
Chris Miller at a later date.
Boats and moorings will be returned as dredging proceeds.
Harbor Resources and The Harbor Department will be involved in determining
the configuration and new permanent location of each mooring.
We will use the boundaries approved by the Army Corp of Engineers and sent to
NOAA.
We will be able to relocate 8 to 10 moorings a day depending on their proximity
to the temporary moorings
We can start this job at your convenience
website:
www.S o u thMoori ng. co m
License If 957414
email: ablesouth @yahoo.com
Cost:
P.O. Box 528
Newport Beach, CA 92661
Direct: 949.645.0334
Fax: 949.645.1041
South Mooring Company
a division of Newport Dredging Co. Inc.
Furnish and install lighted warning buoys with weight and chain $ 150.00 each
Move warning buoy to new location $ 50.00 each
Move mooring buoys and boats to temporary location (each end) $ 140.00
Move mooring buoys back to new location (each end)
Adjust mooring to accommodate permitfee (each end)
Sincerely, Accepted by
Chock South 949- 645 -0334
$ 140.00
$ 50.00
CERTIFICATE OF INSURANCE
CHECKLIST
Cary of Newport Beach
This checklist is comprised of requirements as outlined by the City of Newport Beach.
Date Received:
6 -15 -12 Dept. /Contact Received From:
Tania
Date Completed:
8/30/12 Sent to: Tania By:
Renee
Company /Person required to have certificate: South Mooring
Type of contract:
All Other
L PROTECTION
AND INDEMNITY
EFFECTIVE
/EXPIRATION DATE: 5/5/12 to 515/13
A.
INSURANCE COMPANY: _Atlantic Specialty Insurance Company
B.
AM BEST RATING (A-: VII or greater): A Xff
C.
ADMITTED Company (Must be California Admitted):
Is Company admitted in California?
® Yes
❑ No
D.
LIMITS (Must be $1M or greater): What is limit provided?
$1,000,000
E.
ADDITIONAL INSURED ENDORSEMENT— please attach
® Yes
❑ No
N/A F.
PRODUCTS AND COMPLETED OPERATIONS (Must
include): Is it included? (completed Operations status does
not apply to Waste Haulers or Recreation)
❑ Yes
❑ No
N/A G.
ADDITIONAL INSURED FOR PRODUCTS AND
COMPLETED OPERATIONS ENDORSEMENT (completed
Operations status does not apply to Waste Haulers)
❑ Yes
❑ No
H.
ADDITIONAL INSURED WORDING TO INCLUDE (The City
its officers, officials, employees and volunteers): Is it
included?
® Yes
❑ No
N/A I.
PRIMARY & NON - CONTRIBUTORY WORDING (Must be
included): Is it included?
❑ Yes
❑ No
J.
CAUTION! (Confirm that loss or liability of the named insured
is not limited solely by their negligence) Does endorsement
include "solely by negligence" wording?
❑ Yes
®No
K.
ELECTED SCMAF COVERAGE (RECREATION ONLY):
® N/A
❑ Yes
❑ No
L.
NOTICE OF CANCELLATION:
❑ N/A
® Yes
❑ No
II. AUTOMOBILE LIABILITY
EFFECTIVE /EXPIRATION DATE: 4 -10- 12/10 -10 -12
A.
INSURANCE COMPANY: State Farm General Insurance Company
B.
AM BEST RATING (A-: VII or greater) A: XV
C.
ADMITTED COMPANY (Must be California Admitted):
Is Company admitted in California?
® Yes
❑ No
D.
LIMITS - If Employees (Must be $11M min. BI & PD and $500,000
UM, $2M min for Waste Haulers): What is limits provided?
$1,000,000
E
LIMITS Waiver of Auto Insurance / Proof of coverage (if individual)
(What is limits provided ?)
N/A
F.
PRIMARY & NON- CONTRIBUTORY WORDING (For Waste
Haulers only):
gl N/A
❑ Yes
❑ No
G.
HIRED AND NON -OWNED AUTO ONLY:
❑ N/A
❑ Yes
® No
H.
NOTICE OF CANCELLATION:
❑ N/A
0 Yes
❑ No
III.
WORKERS' COMPENSATION
EFFECTIVE /EXPIRATION DATE: 12- 20- 11/7 -16 -12
A. INSURANCE COMPANY: State Fund
B. AM BEST RATING (A-: VII or greater): Not Rated
C. ADMITTED Company (Must be California Admitted):
D. WORKERS' COMPENSATION LIMIT: Statutory
E. EMPLOYERS' LIABILITY LIMIT (Must be $1M or greater)
F. WAIVER OF SUBROGATION (To include): Is it included?
G. SIGNED WORKERS' COMPENSATION EXEMPTION FORM:
H. NOTICE OF CANCELLATION:
ADDITIONAL COVERAGE'S THAT MAYBE REQUIRED
IV. PROFESSIONAL LIABILITY
V POLLUTION LIABILITY
V BUILDERS RISK
HAVE ALL ABOVE REQUIREMENTS BEEN MET?
additional insured endorsement for this coverage.
Approved:
Agent of Alliant Insurance Services
Broker of record for the City of Newport Beach
8/30/12
Date
M Yes
❑ No
R Yes
❑ No
1,000, 000
R Yes
❑ No
M N/A ❑ Yes
❑ No
❑ N/A M Yes
❑ No
M N/A ❑ Yes ❑ No
M N/A ❑ Yes ❑ No
R N/A ❑ Yes ❑ No
R Yes ❑ No
RISK MANAGEMENT APPROVAL REQUIRED (Non- admitted carrier rated less than _
Self Insured Retention or Deductible greater than $ ) ❑ N/A ❑ Yes ❑ No
Reason for Risk Management approval/exception /waiver:
Approved:
Risk Management Date
* Subject to the terms of the contract.
Policy NUmbef:B5,TH71259 Date Entered: 06/14/2012
s�� ®® CERTIFICATE OF LIABILITY INSURANCE 6 /1(4/2D�YI
THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS
CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES
BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED
REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER.
IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to
the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the
certificate holder in lieu of such endorsement(s).
PRODUCER CONTACT
Mariner's General Insurance Group LJAME;_ ____ ,___ -,____
206 Riverside Avenue PRONE .(949)642 -5179 Ney(949)642 -0252
E -MAIL Ile ort(Imarinersins.com
Suite A ADDRESS: w . _
Newport Beach, CA 92663 INSURERIS)AFFORDINGCOVERAGE I NAIC_M___ _
INSURERA:ONE BEACON INSURANCE
IrvsuREO ABLE SOUTH, LLC b NEWPORT DREDGING COMPANY INSURER B:
INSURERC:
P.O. BOX 528
NEWPORT BEACH, CA 92661 INSURER
COVERAGES CERTIFICATE NUMBER: REVISION NIIMRFR-
THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD
INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS
CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,
EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
ILA
ADD E
POLICY EFF
POLIO E P
�J TYPE OFINSURANCE
V8A
INSR RNLI
POUCYNUMEER MMJD
MMIDDIYYM
LIMITS
GENERAWARIUN
E
I
EACH OCCURRENCE E
'—
COWAERCIAL G`NERAABILITY
j
O ELATED
p1EA11SES Le xwrzenc]_� S
`CLAIMS
MADE OCCUR
MED EXP(Am, one perspnl�_.E
PERSONAL B ADV INJURY 5
GENERAL AGGREGATE E
__..,___ _
IGEN'LAGGREGATE LIMIT APPLIES PER:
!
PRODUCTS COMPIOPAGG
POLICY PRO. LOC JEOT
AUTOMOBILE
LIABILITY
j
I '
I COMBINED SINGLE LIMIT I
Ea accldruu _ _ 5
ANY AUTO
j
I BODILY INJURY (Pet person) S
ALL OWNED SCHEDULED
BODILY INIURY /Per accident)
- --
AUTOS AUTOS
NON -OWNED
i
PROPERTY DAMAGE
S
HIRED AUTOS AUTOS
I
_LPgacdtlenl
L
S
UMBRELLA LIAS OCCUR
! EXCESSUAS
I
EACH OCCURRENCE is
AGGREGATE
CLAIMS -MADE
I
I
ETLIED RETENTION S
I
E
WORRERSCOMPEISATION
ANDEMPLOETCF. ABILRY
VJC STATU- OTH-
0$LLIMI?
I
ANYPROPRIETOR/PARTNEWEECUTIVE
OFFICERIMEMBER
NIA
EACH ACCIDENT
rEJ
E
(Mandatory in NH)
DISEASE - EA EMPLOYEE I
S
Ifyes.desrsbeonder
DESCRIPTIONOFOPERADONSIroIOw
L DISEASE - POLICY LIMIT
E
A :PSI LIABILITY �,`l;
;B5.TH71259
/aS /2012
/05/2012
$ 11000,000
, SRLL i
x
135rTH71260
I
is
p5103/2012
is
i s /o5 /2013 i
i
$ 1,000,000
DESCRIPTION OF OPERATIONS I LOCATIONS /VEHICLES (Attach ACORD 101, Additional Remarlm Schedule, it more space is required)
CERTIFICATE HOLDER IS NAMED AS ADDITIONAL INSURED '
CERTIFICATE HOLDER CANCELLATION
CITY OF NEWPORT BEACH
SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE
THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN
829 HARBOR ISLAND DRIVE
ACCORDANCE WITH THE POLICY PROVISIONS.
NEWPORT BEACH, CA 92660
AUTHORIZED REPRESENTATIVE
RAIG CHAMBERLAIN '-
U 1988 -2010 ACORD CORPORATION. All rights reserved.
ACORD 25 (2010105) The ACORD name and logo are registered marks of ACORD
Produced using Forms Boss Plus software. www.FormsBoss.com; Impressive Publishing 800- 208 -1977
OF UA®UTY SURA CE
ATE(C_ST-CATE
D06/28/2012
PRODUCER
ROBERT SULLIVAN
227 20TH ST SUITE 103
NEWPORT BEACH, CA 92663
THIS CERTIFICATE IS ISSUED AS MATTER OF INFORMATION
ONLY AND CONFERS. NO RIGHTS UPON THE CERTIFICATE
HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR
ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW.
INSURERS AFFORDING COVERAGE
NAIC #
INSURED
CHUCK SOUTH
177 RIVERSIDE AVE STE F
NEWPORT BCH, CA 92663-4080
INSURERA: State Farm General Insurance Company 25151
POLICYEFFECTIVE
INSURERS: State Farm Mutual Auto Insurance Company 25178
AUTHORIZED REPRESENTATIVE
INSURER C:
INSRD
,SURER D:
POLICYNUMBER
NSURER E:
DATE(MI•NDOIYY)
COVERAGES
THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE. FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING
ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR
MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH
POLICIES. AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
INSR
ADDT
IMPOSE NO OBLIGATION OR LIABILITY OF ANY KIND UPON THE INSURER, ITS AGENTS OR
POLICYEFFECTIVE
POLICY EXPIRATION
AUTHORIZED REPRESENTATIVE
LTR
INSRD
TYPE OF INSURANCE
POLICYNUMBER
DATE(MMIDDIYY)
DATE(MI•NDOIYY)
LIMITS
GENERAL
LIABILITY
EACH OCCURRENCE
S
AM I R NT86—
COMMERCIAL GENERAL LIABILITY
PREMISES Ea oc nrdnce
$
CI-AIMS MADE OCCUR
MEO EXP (Any one person)
S
PERSONAL B AOV INJURY
S
GENERAL AGGREGATE
$
GENLAGGREGATE UMRAPPUES PER
PRODUCTS- COMP/OPAGG
S
PRO -
POLICY JECT n LOC
A
Y
AUTOMOBILE
LIABILITY
268 4990. D10 75
04/10/2012
10/10/2012
COMBINED SINGLE LIMIT
(Ea accident)
$
ANY AUTO
X
BODILY INJURY
(Per person)
$ 250,000
ALL OWNED AUTOS
SCHEDULED AUTOS
BODILY INJURY
(Per acaden0
$ 500,000
HIRED AUTOS
NON -OWNED AUTOS
PROPERTY DAMAGE
(Per accident)
S 100,000
GARAGE LIABILITY
AUTO ONLY - EA ACCIDENT
S
OTHERTHAN EA ACC
S
ANYAUTO
AUTO ONLY:
AGG
$
EXCESSIUMBRELLA
LIABILITY
EACH OCCURRENCE
$
OCCUR CLAIMS MADE
AGGREGATE
$
S
S
DEOUCTIBLE
Is
REI'EMION $
WORKERS COMPENSATION AND
EMPLOYERS' LIABILITY
X WC STATU- OTH-
TORY LIMITS ER
E.L. EACH ACCIDENT
5
ANY PROPRIETOR /PARTNER /EXECUTIVE
OFFICER /MEMBER EXCLUDED?
E.L DISEASE- EA EMPLOYEE
$
It yes, describe under
SPECIAL PROVISIONS belovr
E.L DISEASE - POLICY LIMIT
S
OTHER
DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES / EXCLUSIONS ADDED BY ENDORSEMENT / SPECIAL PROVISIONS
CERTIFICATE HOLDER CANCELLATION
CITY OF NEWPORT BEACH
SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION
DATE THEREOF, THE ISSUING INSURER WILL ENDEAVOR TO MAIL 30 DAYS WRITTEN
NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT, BUT FAILURE TO DO SO SHALL
IMPOSE NO OBLIGATION OR LIABILITY OF ANY KIND UPON THE INSURER, ITS AGENTS OR
REPRESENTATIVES.
AUTHORIZED REPRESENTATIVE
ROBERT SULLIVAN
ACORD Z5 (ZUU7 /UB) I ne registration notices molcate ownersnlp of the marKS Dy tnelr respective owners VAGOKU I:UKYUKAI IUN I98H, ZUU7
132849 03 -13 -2007 All rights reserved
IMPORTANT
If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. A statement
on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s).
If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may
require an endorsement. A statement on this certificate does not confer rights to the certificate
holder in lieu of such endorsement(s).
DISCLAIMER
The Certificate of Insurance on the reverse side of this form does not constitute a contract between
the issuing insurer(s), authorized representative or producer, and the certificate holder, nor does it
affirmatively or negatively amend, extend or alter the coverage afforded by the policies listed thereon.
ACORD 26 (2001108)
CERTHOLDER COPY
SG
P.O. BOX 420807, SAN FRANCISCO,CA 94142 -0807
CERTIFICATE OF WORKERS' COMPENSATION INSURANCE
ISSUE DATE: 06 -28 -2012
CITY OF NEWPORT BEACH
ATTN SHANNON LEVIN
829 HARBOR ISLAND DR
NEWPORT BEACH CA 92660 -7235
SG
GROUP:
POLICY NUMBER: 0804781- 2011 -2
CERTIFICATE ID: 8
CERTIFICATE EXPIRES: 12 -20 -2012
12- 20- 2011/12 -20 -2012
THIS CERTIFICATE SUPERSEDES AND CORRECTS
CERTIFICATE # 7 DATED 06 -14 -2012
This is to certify that we have issued a valid Workers' Compensation insurance policy in a form approved by the
California Insurance Commissioner to the employer named below for the policy period indicated.
This policy is not subject to cancellation by the Fund except upon 30 days advance written notice to the employer.
We will also give you 30 days advance notice should this policy be cancelled prior to its normal expiration.
This certificate of insurance is not an insurance policy and does not amend, extend or alter the coverage afforded
by the .policy listed herein. Notwithstanding any requirement, term or condition of any contract or other document
with respect to which this certificate of insurance may be issued or to which it may pertain, the insurance
afforded by the policy described herein is subject to all the terms, exclusions, and conditions, of such policy.
f ' `HYNcra G
A Representative 6 President and CEO
EMPLOYER'S LIABILITY LIMIT INCLUDING DEFENSE COSTS: $1,000,000 PER OCCURRENCE.
ENDORSEMENT #2065 ENTITLED CERTIFICATE HOLDERS' NOTICE EFFECTIVE 01 -20 -2012 IS
ATTACHED TO AND FORMS A PART OF THIS POLICY.
® ENDORSEMENT #2570 ENTITLED WAIVER OF SUBROGATION EFFECTIVE 2012 -06 -28 IS
ATTACHED TO AND FORMS A PART OF THIS POLICY. THIRD PARTY NAME:
CITY OF NEWPORT BEACH
EMPLOYER
NEWPORT DREDGING COMPANY INC DBA: SOUTH
MOORING CO
PO BOX 528
NEWPORT BEACH CA 92661
SG
[GNC,CNj
PRINTED : 06 -28 -2012
(REV.a -20101
POLICYHOLDER COPY
SG
P.O. BOX 420807, SAN FRANCISCO,CA 94142 -0807
CERTIFICATE OF WORKERS' COMPENSATION INSURANCE
ISSUE DATE: 06 -28 -2012
CITY OF NEWPORT BEACH SG
ATTN SHANNON LEVIN
829 HARBOR ISLAND DR
NEWPORT BEACH CA 92660 -7235
GROUP:
POLICY NUMBER: 0804781- 2011 -2
CERTIFICATE ID: S
CERTIFICATE EXPIRES: 12 -20 -2012
12 -20- 2011/12 -20 -2012
THIS CERTIFICATE SUPERSEDES AND CORRECTS
CERTIFICATE X 7 DATED 06 -14 -2012
This is to certify that we have issued a valid Workers' Compensation insurance policy in a form approved by the
California Insurance Commissioner to the employer named below for the policy period indicated.
This policy is not subject to cancellation by the Fund except upon 30 days advance written notice to the employer.
We will also give you 30 days advance notice should this policy be cancelled prior to its normal expiration.
This certificate of insurance is not an insurance policy and does not amend, extend or alter the coverage afforded
by the policy listed herein. Notwithstanding any requirement, term or condition of any contract or other document
with respect to which this certificate of insurance may be issued or to which it may pertain, the insurance
afforded by the policy described herein is subject to all the terms, exclusions,
�
s_i�ons,, and conditions, of such policy.
6 Authorized Representative President and CEO
EMPLOYER'S LIABILITY LIMIT INCLUDING DEFENSE COSTS: $1,000,000 PER OCCURRENCE
ENDORSEMENT X2065 ENTITLED CERTIFICATE HOLDERS' NOTICE EFFECTIVE 01 -20 -2012 IS
ATTACHED TO AND FORMS A PART OF THIS POLICY.
ENDORSEMENT X2570 ENTITLED WAIVER OF SUBROGATION EFFECTIVE 2012 -06 -28 IS
ATTACHED TO AND FORMS A PART OF THIS POLICY. THIRD PARTY NAME:
CITY OF NEWPORT BEACH
EMPLOYER
NEWPORT DREDGING COMPANY INC DBA: SOUTH SG
MOORING CO
PO BOX 528
NEWPORT BEACH CA 92661
[GNC,CNj
PRINTED : 06 -28 -2012
(REV.8 -2010)
WAIVER OF SUBROGATION NOTICE
Enclosed is your copy of a certificate of insurance on which the certificate holder
required a waiver of subrogation:
1. Please be advised that a waiver of subrogation requires that a 3% surcharge
will be applied by State Fund ONLY to the premium assessed on the payroll
of your employees earned while engaged in work for that certificate holder
who requested the waiver. (Note: if you have no employee payroll on that job,
then there is no charge.)
2. To apply the 3% surcharge, you must also agree to maintain accurately
segregated payroll records for employees engaged in work on job /s for the
certificate holder who has the waiver. The payroll records are subject to
verification by an auditor.
Example:
Payroll for job:
Sample Rate:
Regular Premium equals:
Surcharge:
Additional Waiver charge
Total premium equals
$5,000.00
13.30%
$ 665.00
3.00%
$ 19.95
$ 684.95 (665.00 + 19.95)
CERTHOLDER COPY
YN
P.O. BOX 420807, SAN FRANCISCO,CA 94142 -0807
CERTIFICATE OF WORKERS' COMPENSATION INSURANCE
ISSUE DATE: 06 -14 -2012
CITY OF NEWPORT BEACH
829 HARBOR ISLAND DR
NEWPORT BEACH CA 92660 -7235
;.'IL
GROUP
POLICY NUMBER: 0804781- 2011 -2
CERTIFICATE 10: 7
CERTIFICATE EXPIRES:07 -16 -2012
12- 20- 2011/07 -16 -2012
THIS CERTIFICATE SUPERSEDES AND CORRECTS
CERTIFICATE # 6 DATED 06 -14 -2012
This is to certify that we have issued a valid Workers' Compensation insurance policy in a form approved by the
California Insurance Commissioner to the employer named below for the policy period that will expire or did
expire as indicated above.
This certificate of insurance is not an insurance policy and does not amend, extend or alter the coverage afforded
by the policy listed herein. Notwithstanding any requirement, term or condition of any contract or other document
with respect to which this certificate of insurance may be issued or to which it may pertain, the insurance
afforded by the policy described herein is subject to all the terms, exclusions, and conditions, of such policy.
Authorized Representative President and CEO
EMPLOYER'S LIABILITY LIMIT INCLUDING DEFENSE COSTS: $1,000,000 PER OCCURRENCE.
ENDORSEMENT #2065 ENTITLED CERTIFICATE HOLDERS' NOTICE EFFECTIVE 01 -20 -2012 IS
ATTACHED TO AND FORMS A PART OF THIS POLICY.
EMPLOYER
NEWPORT DREDGING COMPANY INC DBA: SOUTH
MOORING CO
PO BOX 528
NEWPORT BEACH CA 92661
SG
IALR,CNj
PRINTED : 06 -14 -2012
(REV.6 -2010)