Loading...
HomeMy WebLinkAbout08 - Balboa Village Fine Arts CenterTO: FROM PREPARED BY: PHONE: TITLE: ABSTRACT: CITY OF NEWPORT BEACH City Council Staff Report September 23, 2014 Agenda Item No. 8 HONORABLE MAYOR AND MEMBERS OF THE CITY COUNCIL David A. Webb, Public Works Director- (949) 644 -3330, dawebb @newportbeachca.gov Mark Vukojevic, Deputy Public Works Director /City Engineer (949) 644 -3319 Balboa Village Fine Arts Center Conceptual Design (Balboa Village Theatre) — Approval of Professional Services Agreement with Robert R. Coffee Architects + Associates The Public Works Department is proceeding with preparing some preliminary conceptual design material to facilitate further conversion and refinement of the Balboa Village Theatre into a Fine Arts Center. Staff is hopeful to return to City Council with this preliminary conceptual design material in October or November of 2014 for review and further direction. RECOMMENDATION a) Find that the transition of the Balboa Theater to a Balboa Village Fine Arts Center reflects the wishes of the Council at least to the extent that further design work, a program pro forma and cost estimation should be completed; and b) Approve a Professional Services Agreement (PSA) with Robert R. Coffee Architects + Associates of Newport Beach, California, for the Balboa Village Fine Arts Center Conceptual Design at a not -to- exceed price of $8,500, and authorize the Public Works Director to execute the Agreement. FUNDING REQUIREMENTS: The current adopted budget includes sufficient funding for this preliminary conceptual design work within the Master Facilities Plan Strategic Planning project fund (7415- C1002038). Upon approval of the conceptual design, staff will request the approval of additional capital project funds to design and construct later this fiscal year. DISCUSSION: At the August 12, 2014 City Council Study Session, City Council expressed its conceptual support for the conversion of the Balboa Village Theatre into a new Balboa Village Fine Arts Center and asked for staff to begin further project planning. The Theater is located at 707 East Balboa Boulevard on the Balboa Peninsula, and operated as a movie theater as far back as 1928. The Theater closed in 1992. Today, it is an empty shell with a sand floor, no restrooms, brick walls, no lobby, a deteriorated ceiling (down to studs), M and an arched wood roof with holes in it. The current building is about 6,000 square feet In an effort to revitalize the Balboa Village area, the City worked with the then - formed Theater Foundation to have the City purchase the theater for $480,000 in October 1998 using Community Development Block Grant ( "CDBG ") funds. The City then entered into a lease with the Foundation in November 1998 to manage and operate the theater. Over the years, various plans and proposals have come forward. However, the facility has remained unused, vacant and uninhabitable. In June 2014, the City asked for a 3rd party analysis for preliminary construction costs to rebuild the theater into a "tenant ready form." At the August 12, 2014 City Council Study Session, City Council studied a new concept as a Fine Arts Center focused primarily on arts and arts education, with live performances and films as a secondary priority. In order to quickly respond to Council's request, the Public Works Department solicited a proposal from Robert R. Coffee Architects to prepare and develop some preliminary conceptual designs for City Council and the Community's consideration. Coffee has extensive community facility design experience including 12 Community Centers designed in the last 8 years (including the City's new Oasis Community Center) as well as the Bowers Museum of Cultural Arts 30,000 SF expansion. Coffee proposed a scope of work including the preparation of a preliminary conceptual floor plan, an exterior elevation and several sketches /renderings illustrating the potential "look" for a new Fine Arts Center commensurate with the proposed activities as outlined in the attachments of the August 12, 2014 City Council meeting. Coffee proposes to perform these activities for a not -to- exceed professional fee of $8,500. City staff and Coffee plan to present the preliminary concepts for City Council consideration and further direction in October or November of this year as requested. Upon City Council direction and budgeting approval (currently no budget exists for this project), staff would move forward with a formal project initiation process to convert the theatre into its new proposed use. In addition, staff will prepare a plan to work with the Parks, Beaches and Recreation Commission, the City Arts Commission and to the overall Community. Although no formal project funding has been allocated for this project, the current adopted CIP budget includes $54,000 of General Fund monies for Master Facilities Plan Strategic Planning projects and is sufficient for this phase of work. ENVIRONMENTAL REVIEW: This action is not subject to the California Environmental Quality Act ( "CEQX) pursuant to Sections 15306 (Information Collection) and 15060(c)(3) (the activity is not a project as defined in Section 15378) of the CEQA Guidelines, California Code of Regulations, Title 14, Chapter 3. The retention of a design consultant does not authorize any specific development or project and would only provide preliminary conceptual design options for a potential future project that would be subject to CEQA. NOTICING: The agenda item has been noticed according to the Brown Act (72 hours in advance of the meeting at which the City Council considers the item). ATTACHMENTS: Description Attachment A - Robert R. Coffee Architects & Associates Professional Services Agreement LIM ATTACHMENT A PROFESSIONAL SERVICES AGREEMENT WITH ROBERT R. COFFEE ARCHITECTS + ASSOCIATES FOR BALBOA VILLAGE FINE ARTS CENTER CONCEPTUAL DESIGN SERVICES THIS PROFESSIONAL SERVICES AGREEMENT ( "Agreement') is made and entered into as of this 24th day of September, 2014 ( "Effective Date "), by and between the CITY OF NEWPORT BEACH, a California municipal corporation and charter city ( "City "), and ROBERT R. COFFEE ARCHITECTS + ASSOCIATES, a sole proprietor doing business as ( "DBA ") ( "Consultant'), whose address is 20361 Irvine Avenue, Studio B -2, Newport Beach, California 92660, and is made with reference to the following: RECITALS A. City is a municipal corporation duly organized and validly existing under the laws of the State of California with the power to carry on its business as it is now being conducted under the statutes of the State of California and the Charter of City. B. City desires to engage Consultant to provide development of conceptual design studies for the conversion of the Balboa Theater into a Fine Arts Center ( "Project "). C. Consultant possesses the skill, experience, ability, background, certification and knowledge to provide the professional services described in this Agreement. D. City has solicited and received a proposal from Consultant, has reviewed the previous experience and evaluated the expertise of Consultant, and desires to retain Consultant to render professional services under the terms and conditions set forth in this Agreement. NOW, THEREFORE, it is mutually agreed by and between the undersigned parties as follows: TERM The term of this Agreement shall commence on the Effective Date, and shall terminate on June 30, 2015, unless terminated earlier as set forth herein. 2. SERVICES TO BE PERFORMED Consultant shall diligently perform all the services described in the Scope of Services attached hereto as Exhibit A and incorporated herein by reference ( "Services" or "Work "). City may elect to delete certain Services within the Scope of Services at its sole discretion. F-03 3. TIME OF PERFORMANCE 3.1 Time is of the essence in the performance of Services under this Agreement and Consultant shall perform the Services in accordance with the schedule included in Exhibit A. In the absence of a specific schedule, the Services shall be performed to completion in a diligent and timely manner. The failure by Consultant to strictly adhere to the schedule set forth in Exhibit A, if any, or perform the Services in a diligent and timely manner may result in termination of this Agreement by City. 3.2 Notwithstanding the foregoing, Consultant shall not be responsible for delays due to causes beyond Consultant's reasonable control. However, in the case of any such delay in the Services to be provided for the Project, each party hereby agrees to provide notice within two (2) calendar days of the occurrence causing the delay to the other party so that all delays can be addressed. 3.3 Consultant shall submit all requests for extensions of time for performance in writing to the Project Administrator as defined herein not later than ten (10) calendar days after the start of the condition that purportedly causes a delay. The Project Administrator shall review all such requests and may grant reasonable time extensions for unforeseeable delays that are beyond Consultant's control. 3.4 For all time periods not specifically set forth herein, Consultant shall respond in the most expedient and appropriate manner under the circumstances, by hand - delivery or mail. 4. COMPENSATION TO CONSULTANT 4.1 City shall pay Consultant for the Services on a time and expense not -to- exceed basis in accordance with the provisions of this Section and the Schedule of Billing Rates attached hereto as Exhibit B and incorporated herein by reference. Consultant's compensation for all Work performed in accordance with this Agreement, including all reimbursable items and subconsultant fees, shall not exceed Eight Thousand Five Hundred Dollars and 00/100 ($8,500.00), without prior written authorization from City. No billing rate changes shall be made during the term of this Agreement without the prior written approval of City. 4.2 Consultant shall submit monthly invoices to City describing the Work performed the preceding month. Consultant's bills shall include the name of the person who performed the Work, a brief description of the Services performed and /or the specific task in the Scope of Services to which it relates, the date the Services were performed, the number of hours spent on all Work billed on an hourly basis, and a description of any reimbursable expenditures. City shall pay Consultant no later than thirty (30) calendar days after approval of the monthly invoice by City staff. 4.3 City shall reimburse Consultant only for those costs or expenses specifically identified in Exhibit B to this Agreement or specifically approved in writing in advance by City. Robert R. Coffee Architects + Associates Page 2 lM 4.4 Consultant shall not receive any compensation for Extra Work performed without the prior written authorization of City. As used herein, "Extra Work" means any Work that is determined by City to be necessary for the proper completion of the Project, but which is not included within the Scope of Services and which the parties did not reasonably anticipate would be necessary at the execution of this Agreement. Compensation for any authorized Extra Work shall be paid in accordance with the Schedule of Billing Rates as set forth in Exhibit B. 5. PROJECT MANAGER 5.1 Consultant shall designate a Project Manager, who shall coordinate all phases of the Project. This Project Manager shall be available to City at all reasonable times during the Agreement term. Consultant has designated Robert R. Coffee to be its Project Manager. Consultant shall not remove or reassign the Project Manager or any personnel listed in Exhibit A or assign any new or replacement personnel to the Project without the prior written consent of City. City's approval shall not be unreasonably withheld with respect to the removal or assignment of non -key personnel. 5.2 Consultant, at the sole discretion of City, shall remove from the Project any of its personnel assigned to the performance of Services upon written request of City. Consultant warrants that it will continuously furnish the necessary personnel to complete the Project on a timely basis as contemplated by this Agreement. 5.3 If Consultant is performing inspection services for City, the Project Manager and any other assigned staff shall be equipped with a cellular phone to communicate with City staff. The Project Manager's cellular phone number shall be provided to City. 6. ADMINISTRATION This Agreement will be administered by the Public Works Department. City's Public Works Director or designee shall be the Project Administrator and shall have the authority to act for City under this Agreement. The Project Administrator shall represent City in all matters pertaining to the Services to be rendered pursuant to this Agreement. 7. CITY'S RESPONSIBILITIES To assist Consultant in the execution of its responsibilities under this Agreement, City agrees to provide access to and upon request of Consultant, one copy of all existing relevant information on file at City. City will provide all such materials in a timely manner so as not to cause delays in Consultant's Work schedule. 8. STANDARD OF CARE 8.1 All of the Services shall be performed by Consultant or under Consultant's supervision. Consultant represents that it possesses the professional and technical personnel required to perform the Services required by this Agreement, and that it will perform all Services in a manner commensurate with the highest professional Robert R. Coffee Architects + Associates Page 3 standards. For purposes of this Agreement, the phrase "highest professional standards" shall mean those standards of practice recognized by one (1) or more first - class firms performing similar work under similar circumstances. 8.2 All Services shall be performed by qualified and experienced personnel who are not employed by City. By delivery of completed Work, Consultant certifies that the Work conforms to the requirements of this Agreement, all applicable federal, state and local laws, and the highest professional standard. 8.3 Consultant represents and warrants to City that it has, shall obtain, and shall keep in full force and effect during the term hereof, at its sole cost and expense, all licenses, permits, qualifications, insurance and approvals of whatsoever nature that is legally required of Consultant to practice its profession. Consultant shall maintain a City of Newport Beach business license during the term of this Agreement. 8.4 Consultant shall not be responsible for delay, nor shall Consultant be responsible for damages or be in default or deemed to be in default by reason of strikes, lockouts, accidents, acts of God, or the failure of City to furnish timely information or to approve or disapprove Consultant's Work promptly, or delay or faulty performance by City, contractors, or governmental agencies. 9. HOLD HARMLESS 9.1 To the fullest extent permitted by law, Consultant shall indemnify, defend and hold harmless City, its City Council, boards and commissions, officers, agents, volunteers and employees (collectively, the "Indemnified Parties), from and against any and all claims (including, without limitation, claims for bodily injury, death or damage to property), demands, obligations, damages, actions, causes of action, suits, losses, judgments, fines, penalties, liabilities, costs and expenses (including, without limitation, attorneys' fees, disbursements and court costs) of every kind and nature whatsoever (individually, a Claim; collectively, "Claims "), which may arise under this Agreement or in any manner relate (directly or indirectly) to the negligence, recklessness, or willful misconduct of the Consultant or its principals, officers, agents, employees, vendors, suppliers, subconsultants, subcontractors, anyone employed directly or indirectly by any of them or for whose acts they may be liable, or any or all of them. 9.2 Notwithstanding the foregoing, nothing herein shall be construed to require Consultant to indemnify the Indemnified Parties from any Claim arising from the sole negligence, active negligence or willful misconduct of the Indemnified Parties. Nothing in this indemnity shall be construed as authorizing any award of attorneys' fees in any action on or to enforce the terms of this Agreement. This indemnity shall apply to all claims and liability regardless of whether any insurance policies are applicable. The policy limits do not act as a limitation upon the amount of indemnification to be provided by the Consultant. Robert R. Coffee Architects + Associates Page 4 to 10. INDEPENDENT CONTRACTOR It is understood that City retains Consultant on an independent contractor basis and Consultant is not an agent or employee of City. The manner and means of conducting the Work are under the control of Consultant, except to the extent they are limited by statute, rule or regulation and the expressed terms of this Agreement. No civil service status or other right of employment shall accrue to Consultant or its employees. Nothing in this Agreement shall be deemed to constitute approval for Consultant or any of Consultant's employees or agents, to be the agents or employees of City. Consultant shall have the responsibility for and control over the means of performing the Work, provided that Consultant is in compliance with the terms of this Agreement. Anything in this Agreement that may appear to give City the right to direct Consultant as to the details of the performance of the Work or to exercise a measure of control over Consultant shall mean only that Consultant shall follow the desires of City with respect to the results of the Services. 11. COOPERATION Consultant agrees to work closely and cooperate fully with City's designated Project Administrator and any other agencies that may have jurisdiction or interest in the Work to be performed. City agrees to cooperate with the Consultant on the Project. 12. CITY POLICY Consultant shall discuss and review all matters relating to policy and Project direction with City's Project Administrator in advance of all critical decision points in order to ensure the Project proceeds in a manner consistent with City goals and policies. 13. PROGRESS Consultant is responsible for keeping the Project Administrator informed on a regular basis regarding the status and progress of the Project, activities performed and planned, and any meetings that have been scheduled or are desired. 14. INSURANCE Without limiting Consultant's indemnification of City, and prior to commencement of Work, Consultant shall obtain, provide and maintain at its own expense during the term of this Agreement or for other periods as specified in this Agreement, policies of insurance of the type, amounts, terms and conditions described in the Insurance Requirements attached hereto as Exhibit C, and incorporated herein by reference. 15. PROHIBITION AGAINST ASSIGNMENTS AND TRANSFERS Except as specifically authorized under this Agreement, the Services to be provided under this Agreement shall not be assigned, transferred contracted or subcontracted out without the prior written approval of City. Any of the following shall Robert R. Coffee Architects + Associates Page 5 E7 be construed as an assignment: The sale, assignment, transfer or other disposition of any of the issued and outstanding capital stock of Consultant, or of the interest of any general partner or joint venturer or syndicate member or cotenant if Consultant is a partnership or joint- venture or syndicate or co- tenancy, which shall result in changing the control of Consultant. Control means fifty percent (50 %) or more of the voting power or twenty -five percent (25 %) or more of the assets of the corporation, partnership or joint- venture. 16. SUBCONTRACTING The subcontractors authorized by City, if any, to perform Work on this Project are identified in Exhibit A. Consultant shall be fully responsible to City for all acts and omissions of any subcontractor. Nothing in this Agreement shall create any contractual relationship between City and any subcontractor nor shall it create any obligation on the part of City to pay or to see to the payment of any monies due to any such subcontractor other than as otherwise required by law. City is an intended beneficiary of any Work performed by the subcontractor for purposes of establishing a duty of care between the subcontractor and City. Except as specifically authorized herein, the Services to be provided under this Agreement shall not be otherwise assigned, transferred, contracted or subcontracted out without the prior written approval of City. 17. OWNERSHIP OF DOCUMENTS 17.1 Each and every report, draft, map, record, plan, document and other writing produced, including but not limited to, websites, blogs, social media accounts and applications (hereinafter "Documents "), prepared or caused to be prepared by Consultant, its officers, employees, agents and subcontractors, in the course of implementing this Agreement, shall become the exclusive property of City, and City shall have the sole right to use such materials in its discretion without further compensation to Consultant or any other party. Additionally, all material posted in cyberspace by Consultant, its officers, employees, agents and subcontractors, in the course of implementing this Agreement, shall become the exclusive property of City, and City shall have the sole right to use such materials in its discretion without further compensation to Consultant or any other party. Consultant shall, at Consultant's expense, provide such Documents, including all logins and password information to City upon prior written request. 17.2 Documents, including drawings and specifications, prepared by Consultant pursuant to this Agreement are not intended or represented to be suitable for reuse by City or others on any other project. Any use of completed Documents for other projects and any use of incomplete Documents without specific written authorization from Consultant will be at City's sole risk and without liability to Consultant. Further, any and all liability arising out of changes made to Consultant's deliverables under this Agreement by City or persons other than Consultant is waived against Consultant, and City assumes full responsibility for such changes unless City has given Consultant prior notice and has received from Consultant written consent for such changes. Robert R. Coffee Architects + Associates Page 6 ea3 17.3 All written documents shall be transmitted to City in formats compatible with Microsoft Office and /or viewable with Adobe Acrobat. 18. CONFIDENTIALITY All Documents, including drafts, preliminary drawings or plans, notes and communications that result from the Services in this Agreement, shall be kept confidential unless City expressly authorizes in writing the release of information. 19. INTELLECTUAL PROPERTY INDEMNITY Consultant shall defend and indemnify City, its agents, officers, representatives and employees against any and all liability, including costs, for infringement or alleged infringement of any United States' letters patent, trademark, or copyright, including costs, contained in Consultant's Documents provided under this Agreement. 20. RECORDS Consultant shall keep records and invoices in connection with the Services to be performed under this Agreement. Consultant shall maintain complete and accurate records with respect to the costs incurred under this Agreement and any Services, expenditures and disbursements charged to City, for a minimum period of three (3) years, or for any longer period required by law, from the date of final payment to Consultant under this Agreement. All such records and invoices shall be clearly identifiable. Consultant shall allow a representative of City to examine, audit and make transcripts or copies of such records and invoices during regular business hours. Consultant shall allow inspection of all Work, data, Documents, proceedings and activities related to the Agreement for a period of three (3) years from the date of final payment to Consultant under this Agreement. 21. WITHHOLDINGS City may withhold payment to Consultant of any disputed sums until satisfaction of the dispute with respect to such payment. Such withholding shall not be deemed to constitute a failure to pay according to the terms of this Agreement. Consultant shall not discontinue Work as a result of such withholding. Consultant shall have an immediate right to appeal to the City Manager or designee with respect to such disputed sums. Consultant shall be entitled to receive interest on any withheld sums at the rate of return that City earned on its investments during the time period, from the date of withholding of any amounts found to have been improperly withheld. 22. ERRORS AND OMISSIONS In the event of errors or omissions that are due to the negligence or professional inexperience of Consultant which result in expense to City greater than what would have resulted if there were not errors or omissions in the Work accomplished by Consultant, the additional design, construction and /or restoration expense shall be Robert R. Coffee Architects + Associates Page 7 Gel borne by Consultant. Nothing in this Section is intended to limit City's rights under the law or any other sections of this Agreement. 23. CITY'S RIGHT TO EMPLOY OTHER CONSULTANTS City reserves the right to employ other Consultants in connection with the Project. 24. CONFLICTS OF INTEREST 24.1 Consultant or its employees may be subject to the provisions of the California Political Reform Act of 1974 (the "Act "), which (1) requires such persons to disclose any financial interest that may foreseeably be materially affected by the Work performed under this Agreement, and (2) prohibits such persons from making, or participating in making, decisions that will foreseeably financially affect such interest. 24.2 If subject to the Act, Consultant shall conform to all requirements of the Act. Failure to do so constitutes a material breach and is grounds for immediate termination of this Agreement by City. Consultant shall indemnify and hold harmless City for any and all claims for damages resulting from Consultant's violation of this Section. 25. NOTICES 25.1 All notices, demands, requests or approvals, including any change in mailing address, to be given under the terms of this Agreement shall be given in writing, and conclusively shall be deemed served when delivered personally, or on the third business day after the deposit thereof in the United States mail, postage prepaid, first - class mail, addressed as hereinafter provided. 25.2 All notices, demands, requests or approvals from Consultant to City shall be addressed to City at: Attn: David A. Webb, Public Works Director Public Works Department City of Newport Beach 100 Civic Center Drive PO Box 1768 Newport Beach, CA 92658 25.3 All notices, demands, requests or approvals from City to Consultant shall be addressed to Consultant at: Attn: Robert R. Coffee Robert R. Coffee Architects + Associates 20361 Irvine Avenue, Studio B -2 Newport Beach, CA 92660 Robert R. Coffee Architects + Associates Page 8 G3[E 26. CLAIMS Unless a shorter time is specified elsewhere in this Agreement, before making its final request for payment under this Agreement, Consultant shall submit to City, in writing, all claims for compensation under or arising out of this Agreement. Consultant's acceptance of the final payment shall constitute a waiver of all claims for compensation under or arising out of this Agreement except those previously made in writing and identified by Consultant in writing as unsettled at the time of its final request for payment. Consultant and City expressly agree that in addition to any claims filing requirements set forth in the Agreement, Consultant shall be required to file any claim Consultant may have against City in strict conformance with the Government Claims Act (Government Code sections 900 et seq.). 27. TERMINATION 27.1 In the event that either party fails or refuses to perform any of the provisions of this Agreement at the time and in the manner required, that party shall be deemed in default in the performance of this Agreement. If such default is not cured within a period of two (2) calendar days, or if more than two (2) calendar days are reasonably required to cure the default and the defaulting party fails to give adequate assurance of due performance within two (2) calendar days after receipt of written notice of default, specifying the nature of such default and the steps necessary to cure such default, and thereafter diligently take steps to cure the default, the non - defaulting party may terminate the Agreement forthwith by giving to the defaulting party written notice thereof. 27.2 Notwithstanding the above provisions, City shall have the right, at its sole and absolute discretion and without cause, of terminating this Agreement at any time by giving no less than seven (7) calendar days' prior written notice to Consultant. In the event of termination under this Section, City shall pay Consultant for Services satisfactorily performed and costs incurred up to the effective date of termination for which Consultant has not been previously paid. On the effective date of termination, Consultant shall deliver to City all reports, Documents and other information developed or accumulated in the performance of this Agreement, whether in draft or final form. 28. STANDARD PROVISIONS 28.1 Recitals. City and Consultant acknowledge that the above Recitals are true and correct and are hereby incorporated by reference into this Agreement. 28.2 Compliance with all Laws. Consultant shall, at its own cost and expense, comply with all statutes, ordinances, regulations and requirements of all governmental entities, including federal, state, county or municipal, whether now in force or hereinafter enacted. In addition, all Work prepared by Consultant shall conform to applicable City, county, state and federal laws, rules, regulations and permit requirements and be subject to approval of the Project Administrator and City. Robert R. Coffee Architects + Associates Page 9 G3fl 28.3 Waiver. A waiver by either party of any breach, of any term, covenant or condition contained herein shall not be deemed to be a waiver of any subsequent breach of the same or any other term, covenant or condition contained herein, whether of the same or a different character. 28.4 Integrated Contract. This Agreement represents the full and complete understanding of every kind or nature whatsoever between the parties hereto, and all preliminary negotiations and agreements of whatsoever kind or nature are merged herein. No verbal agreement or implied covenant shall be held to vary the provisions herein. 28.5 Conflicts or Inconsistencies. In the event there are any conflicts or inconsistencies between this Agreement and the Scope of Services or any other attachments attached hereto, the terms of this Agreement shall govern. 28.6 Interpretation. The terms of this Agreement shall be construed in accordance with the meaning of the language used and shall not be construed for or against either party by reason of the authorship of the Agreement or any other rule of construction which might otherwise apply. 28.7 Amendments. This Agreement may be modified or amended only by a written document executed by both Consultant and City and approved as to form by the City Attorney. 28.8 Severability. If any term or portion of this Agreement is held to be invalid, illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining provisions of this Agreement shall continue in full force and effect. 28.9 Controlling Law and Venue. The laws of the State of California shall govern this Agreement and all matters relating to it and any action brought relating to this Agreement shall be adjudicated in a court of competent jurisdiction in the County of Orange, State of California. 28.10 Equal Opportunity Employment. Consultant represents that it is an equal opportunity employer and it shall not discriminate against any subcontractor, employee or applicant for employment because of race, religion, color, national origin, handicap, ancestry, sex, age or any other impermissible basis under law. 28.11 No Attorneys' Fees. In the event of any dispute or legal action arising under this Agreement, the prevailing party shall not be entitled to attorneys' fees. 28.12 Counterparts. This Agreement may be executed in two (2) or more counterparts, each of which shall be deemed an original and all of which together shall constitute one (1) and the same instrument. [SIGNATURES ON NEXT PAGE] Robert R. Coffee Architects + Associates Page 10 8 -12 IN WITNESS WHEREOF, the parties have caused this Agreement to be executed on the dates written below. APPROVED AS TO FORM: CITY ATT R EY'S OFFICE Date: By. Aaron C. Harp City Attorney ATTEST: Date: CITY OF NEWPORT BEACH, a California municipal corporation Date: By: David A. Webb Public Works Director CONSULTANT: Robert R. Coffee Architects + Associates, a sole proprietor doing business as ( "DBA ") Date: By: By: Leilani I. Brown Robert R. Coffee City Clerk Owner /Principal [END OF SIGNATURES] Attachments: Exhibit A — Scope of Services Exhibit B — Schedule of Billing Rates Exhibit C — Insurance Requirements Robert R. Coffee Architects + Associates Page 11 8 -13 EXHIBIT A SCOPE OF SERVICES Conceptual Design Services for the Balboa Village Fine Arts Center Project Description: Develop conceptual design studies for the conversion of the Balboa Theater into a Fine Arts Center. The primary purpose of this effort is to develop a conceptual floor plan, an exterior elevation and several sketches /renderings illustrating the potential "look" for the new center commensurate with the proposed activities outlined in Attachment D to the City Council Staff report dated August 12, 2014. A presentation of the concept drawings will be made to the City Council at the last council meeting in October 2014. Task One: Information Gathering $1,000.00 Creating Working Base Information Plans Gather existing base information in the form of Autocad drawings and other available exhibits prepared for the previously proposed Balboa Theater Renovation. Visit the site and make a photographic record of the existing conditions. Prepare necessary accurate Site Plan, Floor Plan and Elevation Base Drawings. Investigate code issues and review existing floor plans for required exiting. Deliverables: Site Plan Elevation and Section Drawings Narrative of Code Review Task Two: Concept Design and Planning $5,000.00 Develop conceptual design studies illustrating potential ideas for the planning of the interior space and the exterior elevation. Prepare an image board of similar spaces and design details. Review the initial studies with the City Staff to solicit input and refine the ideas based on their input into a single concept for the council presentation. Deliverables: Image Board Floor Plan Conceptual Elevation and Section Studies Three Dimensional Studies of Exterior and Interior Meetings: One -two meetings. Robert R. Coffee Architects + Associates Page A -1 I=% Task Three: City Council Presentation $1.000.00 Prepare final exhibits and a power point for presentation to the City Council. If necessary, work with City Staff and consultants to refine budget to reflect the new design concept. Deliverables: Power Point Presentation Image Board Illustrative Floor Plan Illustrative Elevations and Sections Three Dimensional Studies of Exterior and Interior Meetings: One -two meetings Robert R. Coffee Architects + Associates Page A -2 W&I EXHIBIT B SCHEDULE OF BILLING RATES Conceptual Design Services for the Balboa Village Fine Arts Center Task One (Information Gathering): Task Two (Concept Design and Planning: Task Three (City Council Presentation): Subtotal: Reimbursable Expenses: Additional Services (as- needed): Total Agreement Amount: $1,000.00 $5,000.00 $1,000.00 $7,000.00 $500.00 Not to exceed $1,000.00 Reimbursable Expenses (Not to Exceed: $500.00): Reimbursable expenses are difficult to predict and as such Consultant reserves the right to request the City to increase this amount if necessary. Consultant will bill all reimbursable expenses separately and provide the City with a copy of all expenses for review with each billing. Reimbursable expenses will include: 1. Plotting and Document Reproduction 2. Postage and Overnight Mail 3. Deliveries 4. Photography 5. Models and Renderings 6. All governmental agency fees Additional Services (Not to Exceed: $500.00): City may request additional tasks on an as- needed basis in order to complete the scope of work should the need arise. Additional services would be billed at the following published hourly rates or negotiated to a fixed fee depending on the services required. Principal: $160.00 /hour Project Architect: $130.00 /hour Project Manager: $120.00 /hour Job Captain: $90.00 /hour Drafting: $80.00 /hour Clerical: $50.00 1hour Robert R. Coffee Architects + Associates Page B -1 no EXHIBIT C INSURANCE REQUIREMENTS — PROFESSIONAL SERVICES 1. Provision of Insurance. Without limiting Consultant's indemnification of City, and prior to commencement of Work, Consultant shall obtain, provide and maintain at its own expense during the term of this Agreement, policies of insurance of the type and amounts described below and in a form satisfactory to City. Consultant agrees to provide insurance in accordance with requirements set forth here. If Consultant uses existing coverage to comply and that coverage does not meet these requirements, Consultant agrees to amend, supplement or endorse the existing coverage. 2. Acceptable Insurers. All insurance policies shall be issued by an insurance company currently authorized by the Insurance Commissioner to transact business of insurance in the State of California, with an assigned policyholders' Rating of A- (or higher) and Financial Size Category Class VII (or larger) in accordance with the latest edition of Best's Key Rating Guide, unless otherwise approved by the City's Risk Manager. 3. Coverage Requirements. A. Workers' Compensation Insurance. Consultant shall maintain Workers' Compensation Insurance, statutory limits, and Employer's Liability Insurance with limits of at least one million dollars ($1,000,000) each accident for bodily injury by accident and each employee for bodily injury by disease in accordance with the laws of the State of California, Section 3700 of the Labor Code. Consultant shall submit to City, along with the certificate of insurance, a Waiver of Subrogation endorsement in favor of City, its officers, agents, employees and volunteers. B. General Liability Insurance. Consultant shall maintain commercial general liability insurance, and if necessary umbrella liability insurance, with coverage at least as broad as provided by Insurance Services Office form CG 00 01, in an amount not less than one million dollars ($1,000,000) per occurrence, two million dollars ($2,000,000) general aggregate. The policy shall cover liability arising from premises, operations, personal and advertising injury, and liability assumed under an insured contract (including the tort liability of another assumed in a business contract). C. Automobile Liability Insurance. Consultant shall maintain automobile insurance at least as broad as Insurance Services Office form CA 00 01 covering bodily injury and property damage for all activities of Consultant arising out of or in connection with Work to be performed under this Agreement, including coverage for any owned, hired, non -owned or rented vehicles, in an amount not less than one million dollars ($1,000,000) combined single limit each accident. Robert R. Coffee Architects + Associates Page C -1 8 -17 D. Professional Liability (Errors & Omissions) Insurance. Consultant shall maintain professional liability insurance that covers the Services to be performed in connection with this Agreement, in the minimum amount of one million dollars ($1,000,000) per claim and two million dollars ($2,000,000) in the aggregate. Any policy inception date, continuity date, or retroactive date must be before the Effective Date of this Agreement and Consultant agrees to maintain continuous coverage through a period no less than three years after completion of the Services required by this Agreement. 4. Other Insurance Requirements. The policies are to contain, or be endorsed to contain, the following provisions: A. Waiver of Subrogation. All insurance coverage maintained or procured pursuant to this Agreement shall be endorsed to waive subrogation against City, its elected or appointed officers, agents, officials, employees and volunteers or shall specifically allow Consultant or others providing insurance evidence in compliance with these requirements to waive their right of recovery prior to a loss. Consultant hereby waives its own right of recovery against City, and shall require similar written express waivers from each of its subconsultants. B. Additional Insured Status. All liability policies including general liability, excess liability, pollution liability, and automobile liability, if required, but not including professional liability, shall provide or be endorsed to provide that City and its officers, officials, employees, and agents shall be included as insureds under such policies. C. Primary and Non Contributory. All liability coverage shall apply on a primary basis and shall not require contribution from any insurance or self - insurance maintained by City. D. Notice of Cancellation. All policies shall provide City with thirty (30) calendar days notice of cancellation (except for nonpayment for which ten (10) calendar days notice is required) or nonrenewal of coverage for each required coverage. 5. Additional Agreements Between the Parties. The parties hereby agree to the following: A. Evidence of Insurance. Consultant shall provide certificates of insurance to City as evidence of the insurance coverage required herein, along with a waiver of subrogation endorsement for workers' compensation and other endorsements as specified herein for each coverage. Insurance certificates and endorsement must be approved by City's Risk Manager prior to commencement of performance. Current certification of insurance shall be kept on file with City at all times during the term of this Agreement. City reserves the right to require complete, certified copies of all required insurance policies, at any time. Robert R. Coffee Architects + Associates Page C -2 ME B. City's Right to Revise Requirements. City reserves the right at any time during the term of the Agreement to change the amounts and types of insurance required by giving Consultant sixty (60) calendar days advance written notice of such change. If such change results in substantial additional cost to Consultant, City and Consultant may renegotiate Consultant's compensation. C. Enforcement of Agreement Provisions. Consultant acknowledges and agrees that any actual or alleged failure on the part of City to inform Consultant of non - compliance with any requirement imposes no additional obligations on City nor does it waive any rights hereunder. D. Requirements not Limiting. Requirements of specific coverage features or limits contained in this Section are not intended as a limitation on coverage, limits or other requirements, or a waiver of any coverage normally provided by any insurance. Specific reference to a given coverage feature is for purposes of clarification only as it pertains to a given issue and is not intended by any party or insured to be all inclusive, or to the exclusion of other coverage, or a waiver of any type. If the Consultant maintains higher limits than the minimums shown above, the City requires and shall be entitled to coverage for higher limits maintained by the Consultant. Any available insurance proceeds in excess of the specified minimum limits of insurance and coverage shall be available to the City. E. Self- insured Retentions. Any self- insured retentions must be declared to and approved by City. City reserves the right to require that self- insured retentions be eliminated, lowered, or replaced by a deductible. Self - insurance will not be considered to comply with these requirements unless approved by City. F. City Remedies for Non - Compliance. If Consultant or any subconsultant fails to provide and maintain insurance as required herein, then City shall have the right but not the obligation, to purchase such insurance, to terminate this Agreement, or to suspend Consultant's right to proceed until proper evidence of insurance is provided. Any amounts paid by City shall, at City's sole option, be deducted from amounts payable to Consultant or reimbursed by Consultant upon demand. G. Timely Notice of Claims. Contractor shall give City prompt and timely notice of claims made or suits instituted that arise out of or result from Contractor's performance under this Contract, and that involve or may involve coverage under any of the required liability policies. City assumes no obligation or liability by such notice, but has the right (but not the duty) to monitor the handling of any such claim or claims if they are likely to involve City. H. Consultant's Insurance. Consultant shall also procure and maintain, at its own cost and expense, any additional kinds of insurance, which in its own Robert R. Coffee Architects + Associates Page C -3 [3E!] judgment may be necessary for its proper protection and prosecution of the Work. Robert R. Coffee Architects + Associates Page C -4 I