HomeMy WebLinkAbout09 - C-3333 - Balboa Village Improvements Phase ITO: Mayor and Members of the City Council
FROM: Public Works Department
September 11, 2001
CITY COUNCIL AGENDA
ITEM NO. 6
COUNCIL AGENDA
f4 0. a
q /�'5 /Ol
SUBJECT: CONSTRUCTION MANAGEMENT SERVICES FOR BALBOA VILLAGE
IMPROVEMENTS, PHASE 1 - CONTRACT NO. 3333
RECOMMENDATION:
Approve a $361,100.00 Professional Services Agreement with Harris & Associates to
provide construction management, inspection, and materials testing during Phase 1
construction, and authorize the Mayor and the City Clerk to execute the agreement.
DISCUSSION:
The total cost for the Balboa Village improvements is estimated to be $8.8 million and
will be constructed in three phases. Phase 1 is scheduled to begin in November 2001.
Each phase must be completed prior to the summer visitor season. Harris &
Associates will provide construction management oversight for the first phase of the
Balboa Village Rehabilitation Project, which is estimated to cost $3.3 million.
A list of Harris & Associates duties is attached and include:
• Ensuring the contractor maintains a safe worksite.
• Monitoring contractor progress in the meeting the project schedule.
• Observing, monitoring and inspecting construction activities including performing
material testing.
• Monitoring design changes and change orders to control cost overruns.
• Ensuring traffic control measures are safe and effective.
• Keeping the public informed on lane closures and sidewalk and driveway
construction.
The first phase of the project is the largest and most complicated involving
reconstruction of Balboa Boulevard and rehabilitation of the Pier Parking Lot and Pier
Plaza. Construction of a new storm drain and water main in Balboa Boulevard,
replacing the roadway, and constructing new sidewalks will require detailed traffic and
safety controls. These controls must be implemented on a daily basis to protect
pedestrians, allow adequate traffic flow, and maintain business access. Harris &
Associates will also provide construction management services for the reconstruction of
the Washington Street and Balboa Pier restrooms.
SUBJECT: CONSTRUCTION MANAGEMENT SERVICES FOR BALBOA VILLAGE IMPROVEMENTS, PHASE 1 -
CONTRACT NO. 3333
September 11, 2001
Page 2
The project's extensive decorative elements require a higher than usual level of quality
control, especially for the Lithocrete work, which has a number of finishing steps
beyond the cure time.
Some of the original improvements in this area were constructed over 80 years ago and
uhforeseen field conditions should be expected. Close monitoring of the construction is
required to identify conflicts between design assumptions and actual field conditions to
allow alternative designs to be developed in a timely manner to control cost overruns.
The Balboa Village construction is impacted by the following concurrent construction
projects:
1. Reconstruction of the Balboa Pier.
2. Reconstruction of the Balboa Theater.
3. Construction of a replacement sewer pump station at Balboa Boulevard and A
Street.
During Phase 1, parking will be at a premium making it imperative that work on the Pier
Parking Lot be constructed as scheduled.
Monitoring the control of dust, noise, and odor nuisances will be an important task for
this project. In addition to managing the construction, Harris & Associates will be the
first point of contact for responses to community comments and complaints and will
maintain a 24 -hour live- assistance hotline.
Respectfully submitted,
BLIC WORKS DEPARTMENT
Stephen G. Badum, Director
Robert S eI ', .E-
Senior Civil Engineer
Attachments: Professional Services Agreement
Project Location Map
PROFESSIONAL SERVICES AGREEMENT
FOR CONSTRUCTION MANAGEMENT SERVICES
FOR BALBOA VILLAGE IMPROVEMENTS PHASE 1
WITH HARRIS & ASSOCIATES
THIS AGREEMENT, entered into this day of , 2001, by and
between the City of Newport Beach, a Municipal Corporation (hereinafter referred to as
"City "), and Harris & Associates, whose address is 34 Executive Park, Suite 150,
Irvine, California, 92614, (hereinafter referred to as "Consultant'), is made with reference
to the following:
RECITALS
A. City is a Municipal Corporation duly organized and validly existing under the
laws of the State of California with the power to carry on its business as it is
now being conducted under the statutes of the State of California and the
Charter of City.
B. City is planning to implement construction management services for the
"Balboa Village Improvement Project. Phase 1," hereinafter referred to as
"Project."
C. City desires to engage Consultant to provide full construction management
activities for three phases of the Project upon the terms and conditions
contained in this Agreement.
D. The principal member of Consultant for purpose of Project is Byron G.
Tobey, P.E., Project Director.
-1-
E. City has solicited and received a proposal from Consultant, has reviewed
the previous experience and evaluated the expertise of Consultant, and
desires to contract with Consultant under the terms and conditions provided
in this Agreement.
NOW, THEREFORE, it is mutually agreed by and between the undersigned
parties as follows:
1. TERM
The term of this Agreement shall commence on the 12th day of September, 2001,
and shall terminate on the 12th day of September, 2002, unless terminated earlier as set
forth herein.
2. SERVICES TO BE PERFORMED
Consultant shall diligently perform all the duties set forth in the scope of services,
attached hereto as Exhibit "A" and incorporated herein by reference.
3. COMPENSATION TO CONSULTANT
City shall pay Consultant for the services in accordance with the provisions of this
Section and the scheduled billing rates set forth in Exhibit "B" attached hereto and
incorporated herein by reference. No rate changes shall be made during the term of this
Agreement without prior written approval of City. Consultant's compensation for all work
performed in accordance with this Agreement shall not exceed the total contract price of
three hundred sixty -one thousand, one hundred and 001100 Dollars ($361,100.00).
3.1 Consultant shall maintain accounting records of its billings which includes
the name of the employee, type of work performed, times and dates of all work which is
-2-
billed on an hourly basis and all approved incidental expenses including reproductions,
computer printing, postage and mileage.
3.2 Consultant shall submit monthly progress invoices to City payable by City
within thirty (30) days of receipt of invoice.
3.3 Consultant shall not receive any compensation for extra work without prior
written authorization of City. Any authorized compensation shall be paid in accordance
with the schedule of the billing rates as set forth in Exhibit "B ".
3.4 City shall reimburse Consultant only for those costs or expenses which
have been specifically approved in this Agreement, or specifically approved in advance by
City. Such cost shall be limited and shall include nothing more than the following costs
incurred by Consultant:
A. The actual costs of subconsultants for performance of any of the services
which Consultant agrees to render pursuant to this Agreement which have
been approved in advance by City and awarded in accordance with the
terms and conditions of this Agreement.
B. Approved reproduction charges.
C. Actual costs and /or other costs and /or payments specifically authorized in
advance in writing and incurred by Consultant in the performance of this
Agreement.
4. STANDARD OF CARE
4.1 All of the services shall be performed by Consultant or under Consultant's
supervision. Consultant represents that it possesses the professional and technical
-3-
personnel required to perform the services required by this Agreement and that it will
perform all services in a manner commensurate with the community professional
standards. All services shall be performed by qualified and experienced personnel who
are not employed by City nor have any contractual relationship with City. Consultant
represents to City that it has or shall obtain all licenses, permits, qualifications and
approvals required of its profession. Consultant further represents that it shall keep in
effect all such licenses, permits and other approvals during the term of this Agreement.
4.2 Consultant shall not be responsible for delay, nor shall Consultant be
responsible for damages or be in default or deemed to be in default by reason of strikes,
lockouts, accidents, acts of God, failure of City to furnish timely information or to promptly
approve or disapprove Consultant's work, delay or faulty performance by City,
contractors, or governmental agencies, or any other delays beyond Consultant's control.
4.3 The term Construction Management or Construction Manager does not
imply that Consultant is engaged in any aspect of the physical work of construction
contracting. Consultant shall not have control over or charge of, and shall not be
responsible for Project's design, Project's contractor (hereinafter referred to as
"Contractor'), construction means, methods, techniques, sequences or procedures, or for
any health or safety precautions and programs in connection the work. These duties are
and shall remain the sole responsibility of the Contractor. Consultant shall not be
responsible for the Contractors schedules or failure to carry out the work in accordance
with the contract documents. Consultant shall not have control over or charge of acts or
omissions of City, Design Engineer, Contractor, Subcontractors, or their Agents or
me
employees, or of any other persons performing portions of the work.
5. INDEPENDENT PARTIES
City retains Consultant on an independent contractor basis and Consultant is not
an employee of City. The manner and means of conducting the work are under the
control of Consultant, except to the extent they are limited by statute, rule or regulation
and the expressed terms of this Agreement. Nothing in this Agreement shall be deemed
to constitute Consultant or any of Consultant's employees or agents to be the agents or
employees of City. Consultant shall have the responsibility for and control over the details
and means of performing the work provided that Consultant is in compliance with the
terms of this Agreement. Anything in this Agreement which may appear to give City the
right to direct Consultant as to the details of the performance of the services or to
exercise a measure of control over Consultant shall mean that Consultant shall follow the
desires of City only in the results of the services.
6. COOPERATION
Consultant agrees to work closely and cooperate fully with City's designated
Project Administrator, and any other agencies which may have jurisdiction or interest in
the work to be performed. City agrees to cooperate with Consultant on Project.
7. PROJECT MANAGER
Consultant shall assign Project to a Project Manager, who shall coordinate all
phases of Project. This Project Manager shall be available to City at all reasonable times
during term of Project. Consultant has designated Omar M. Dandashi, P.E., to be its
Project Manager. Consultant shall not bill any personnel to Project other than those
-5-
personnel identified in Exhibit "B ", whether or not considered to be key personnel, without
City's prior written approval by name and specific hourly billing rate. Consultant shall not
remove or reassign any personnel designated in this Section or assign any new or
replacement person to Project without the prior written consent of City. City's approval
shall not be unreasonably withheld with respect to removal or assignment of non -key
personnel.
Consultant, at the sole discretion of City, shall remove from Project any of its
personnel assigned to the performance of services upon written request of City.
Consultant warrants it will continuously furnish the necessary personnel to complete
Project on a timely basis as contemplated by this Agreement.
8. TIME OF PERFORMANCE
Time is of the essence in the performance of the services under this Agreement
and the services shall be performed by Consultant to complete by May 31, 2002. The
failure by Consultant to strictly adhere to the schedule may result in termination of this
Agreement by City and assessment of damages against Consultant for delay.
Notwithstanding the foregoing, Consultant shall not be responsible for delays which are
due to causes beyond Consultant's reasonable control. However, in the case of any such
delay in the services to be provided for Project, each party hereby agrees to provide
notice to the other party so that all delays can be addressed.
8.1 Consultant shall submit all requests for extensions of time for performance
in writing to the Project Administrator not later than ten (10) calendar days after the start
of the condition which purportedly causes a delay, but not later than the date upon which
In
performance is due. The Project Administrator shall review all such requests and may
grant reasonable time extensions for unforeseeable delays which are beyond
Consultant's control.
8.2 For all time periods not specifically set forth herein, Consultant shall
respond in the most expedient and appropriate manner under the circumstances by
telephone, fax, hand delivery or mail.
9. CITY POLICY
Consultant shall discuss and review all matters relating to policy and project
direction with the Project Administrator in advance of all critical decision points in order to
ensure that Project proceeds in a manner consistent with City goals and policies.
10. CONFORMANCE TO APPLICABLE REQUIREMENT
All work prepared by Consultant shall conform to applicable city, county, state and
federal law, regulations and permit requirements and be subject to approval of the Project
Administrator and City Council.
11. PROGRESS
Consultant is responsible to keep the Project Administrator or his duly authorized
designee informed on a regular basis regarding the status and progress of the work,
activities performed and planned, and any meetings that have been scheduled or are
desired.
12. HOLD HARMLESS
Consultant shall indemnify, defend, save and hold harmless City, its City Council,
boards and commissions, officers and employees from and against any and all loss,
-7-
damages, liability, claims, allegations of liability, suits, costs and expenses for damages of
any nature whatsoever, including, but not limited to, bodily injury, death, personal injury,
property damages, or any other claims arising from any and all negligent acts or
omissions of Consultant, its employees, agents or subcontractors in the performance of
services or work conducted or performed pursuant to this Agreement, excepting only the
active negligence or willful misconduct of City, its officers or employees, and shall include
attorneys' fees and all other costs incurred in defending any such claim. Nothing in this
indemnity shall be construed as authorizing, any award of attorneys' fees in any action on
or to enforce the terms of this Agreement.
13. INSURANCE
Without limiting consultant's indemnification of City, and prior to commencement of
work, Consultant shall obtain and provide and maintain at its own expense during the
term of this Agreement policy or policies of liability insurance of the type and amounts
described below and satisfactory to City. Certification of all required policies shall be
signed by a person authorized by that insurer to bind coverage on its behalf and must be
filed with City prior to exercising any right or performing any work pursuant to this
Agreement. Except workers compensation and errors and omissions, all insurance
policies shall add City, it's elected officials, officers, agents, representatives and
employees as additional insured for all liability arising from Consultant's services as
described herein.
Insurance policies with original endorsements indemnifying Project for the
following coverages shalt be issued by companies admitted to do business in the State of
0
California and assigned Best's A- VII or better rating:
A. Worker's compensation insurance covering all employees and principals of
Consultant, per the laws of the State of California.
B. Commercial general liability insurance covering third party liability risks,
including without limitation, contractual liability, in a minimum amount of $1
million combined single limit per occurrence for bodily injury, personal injury
and property damage. If commercial general liability insurance or other
form with a general aggregate is used, either the general aggregate shall
apply separately to this Project, or the general aggregate limit shall be twice
the occurrence limit.
C. Commercial auto liability and property insurance covering any owned and
rented vehicles of Consultant in a minimum amount of $1 million combined
single limit per accident for bodily injury and property damage.
D. Professional errors and omissions insurance which covers the services to
be performed in connection with this Agreement in the minimum amount of
one million dollars ($1,000,000.00).
Said policy or policies shall be endorsed to state that coverage shall not be
canceled by either party, except after thirty (30) days' prior notice has been given in
writing to City. Consultant shall give City prompt and timely notice of claim made or suit
instituted arising out of Consultant's operation hereunder. Consultant shall also procure
and maintain, at its own cost and expense, any additional kinds of insurance, which in its
own judgment may be necessary for its proper protection and prosecution of the work.
in
Consultant agrees that in the event of loss due to any of the perils for which it has
agreed to provide comprehensive general and automotive liability insurance, that
Consultant shall look solely to its insurance for recovery. Consultant hereby grants to
City, on behalf of any insurer providing comprehensive general and automotive liability
insurance to either Consultant or City with respect to the services of Consultant herein, a
waiver of any right of subrogation which any such insurer of said Consultant may acquire
against City by virtue of the payment of any loss under such insurance.
14. PROHIBITION AGAINST TRANSFERS
Neither party shall assign, sublease, hypothecate or transfer this Agreement or any
of the services to be performed under this Agreement, directly or indirectly, by operation
of law or otherwise without prior written consent of both parties. Any attempt to do so
without consent of both parties shall be null and void.
The sale, assignment, transfer or other disposition of any of the issued and
outstanding capital stock of Consultant, or of the interest of any general partner or joint
venturer or syndicate member or co- tenant if Consultant is a partnership or joint- venture
or syndicate or co- tenancy, which shall result in changing the control of Consultant, shall
be construed as an assignment of this Agreement. Control means fifty percent (50 %) or
more of the voting power, or twenty -five percent (25 %) or more of the assets of the
corporation, partnership orjoint- venture.
The rights and benefits under this agreement are for the sole and exclusive benefit
o Client and Consultant and it shall not be construed that any third party has interest in
this agreement.
-10-
15. OWNERSHIP OF DOCUMENTS
Each and every report, draft, work product, map, record and other document
reproduced, prepared or caused to be prepared by Consultant pursuant to or in
connection with this Agreement shall be the exclusive property of City.
Documents, including drawings and specifications, prepared by Consultant
pursuant to this Agreement are not intended or represented to be suitable for reuse by
City or others on any other project. Any use of completed documents for other projects
and any use of incomplete documents without specific written authorization from
Consultant will be at City's sole risk and without liability to Consultant. Further, any and
all liability arising out of changes made to Consultant's deliverables under this Agreement
by City or persons other than Consultant is waived as against Consultant and City
assumes full responsibility for such changes unless City has given Consultant prior notice
and has received from Consultant written consent for such changes.
Consultant shall, at such time and in such forms as City may require, furnish
reports concerning the status of services required under this Agreement.
16. CONFIDENTIALITY
The information, which results from the services in this Agreement, is to be kept
confidential unless the release of information is authorized by City.
17. CITY'S RESPONSIBILITIES
In order to assist Consultant in the execution of his responsibilities under this
Agreement, City agrees to provide the following:
-11-
A. City will provide access to and upon request of Consultant, provide one
copy of all existing record information on file at City. Consultant shall be
entitled to rely upon the accuracy of data information provided by City or
others without independent review or evaluation. City will provide all such
materials in a timely manner so as not to cause delays in Consultant's work
schedule.
B. City staff will provide usable life of facilities criteria and provide information
with regards to deficient facilities.
18. ADMINISTRATION
This Agreement will be administered by the Public Works Department. Bill
Patapoff, P.E. shall be considered the Project Administrator and shall have the authority
to act for City under this Agreement. The Project Administrator or his authorized
representative shall represent City in all matters pertaining to the services to be rendered
pursuant to this Agreement.
19. RECORDS
Consultant shall keep records and invoices in connection with the work to be
performed under this Agreement. Consultant shall maintain complete and accurate
records with respect to the costs incurred under this Agreement. All such records shall be
clearly identifiable. Consultant shall allow a representative of City during normal business
hours to examine, audit and make transcripts or copies of such records. Consultant shall
allow inspection of all work, data, documents, proceedings and activities related to the
Agreement for a period. of three (3) years from the date of final payment under this
-12-
Agreement.
20. WITHHOLDINGS
City may withhold payment of any disputed sums until satisfaction of the dispute
with respect to such payment. Such withholding shall not be deemed to constitute a
failure to pay according to the terms of this Agreement. Consultant shall not discontinue
work for a period of thirty (30) days from the date of withholding as a result of such
withholding. Consultant shall have an immediate right to appeal to the City Manager or
his designee with respect to such disputed sums. Consultant shall be entitled to receive
interest on any withheld sums at the rate of seven percent (7 %) per annum from the date
of withholding of any amounts found to have been improperly withheld.
21. ERRORS AND OMISSIONS
In the event of errors or omissions that are due to the negligence or professional
inexperience of Consultant which result in expense to City greater than would have
resulted if there were not errors or omissions in the work accomplished by Consultant, the
additional design, construction and /or a restoration expense shall be borne by Consultant.
Nothing in this paragraph is intended to limit City's rights under any other sections of this
Agreement.
22. CITY'S RIGHT TO EMPLOY OTHER CONSULTANTS
City reserves the right to employ other consultants in connection with Project.
23. CONFLICTS OF INTEREST
A. Consultant or its employees may be subject to the provisions of the
California Political Reform Act of 1974 (the "Act "), which (1) requires such
-13-
persons to disclose financial interest that may foreseeably be materially
affected by the work performed under this Agreement, and (2) prohibits
such persons from making, or participating in making, decisions that will
foreseeably financially affect such interest.
B. If subject to the Act, Consultant shall conform to all requirements of the Act.
Failure to do so constitutes a material breach and is grounds for termination
of this Agreement by City. Consultant shall indemnify and hold harmless
City for any and all claims for damages resulting from Consultant's violation
of this Section.
24. SUBCONSULTANT AND ASSIGNMENT
Except as specifically authorized under this Agreement, the services included in
this Agreement shall not be assigned, transferred, contracted or subcontracted without
prior written approval of City.
25. NOTICES
All notices, demands, requests or approvals to be given under this Agreement
shall be given in writing and conclusively shall be deemed served when delivered
personally or on the third business day after the deposit thereof in the United States mail,
postage prepaid, first class mail, addressed as hereinafter provided.
All notices, demands, requests or approvals from Consultant to City shall be
addressed to City at:
City of Newport Beach
3300 Newport Boulevard
Newport Beach, CA, 92658 -8915
(949) 644 -3311 Fax (949) 644 -3318
0
-14-
All notices, demands, requests or approvals from City to Consultant shall be
addressed to Consultant at:
Attention: Mr. Omar Dandashi
Harris & Associates
34 Executive Park, Suite 150
Irvine, CA 92614 -4705
949 - 655 -3900
949 - 655 -3995
26. TERMINATION
In the event either part hereto fails or refuses to perform any of the provisions
hereof at the time and in the manner required hereunder, that party shall be deemed in
default in the performance of this Agreement. If such default is not cured within a period
of two (2) days, or if more than two (2) days are reasonably required to cure the default
and the defaulting party fails to give adequate assurance of due performance within two
(2) days after receipt by defaulting party from the other party of written notice of default,
specifying the nature of such default and the steps necessary to cure such default, the
nondefaulting party may terminate the Agreement forthwith by giving to the defaulting
party written notice thereof.
26.1 City shall have the option, at its sole discretion and without cause, of
terminating this Agreement by giving seven (7) days' prior written notice to Consultant as
provided herein. Upon termination of this Agreement, City shall pay to Consultant that
portion of compensation specified in this Agreement that is earned and unpaid prior to the
effective date of termination.
-15-
27. COMPLIANCES
Consultant shall comply with all laws, state or federal and all ordinances, rules and
regulations enacted or issued by City.
28. WAIVER
A waiver by either party of any breach, of any term, covenant or condition
contained herein shall not be deemed to be a waiver of any subsequent breach of the
same or any other term, covenant or condition contained herein whether of the same or a
different character.
29. INTEGRATED CONTRACT
This Agreement represents the full and complete understanding of every kind or
nature whatsoever between the parties hereto, and all preliminary negotiations and
agreements of whatsoever kind or nature are merged herein. No verbal agreement or
implied covenant shall be held to vary the provisions hereon. Any modification of this
Agreement will be effective only by written execution signed by both City and Consultant.
30. PATENT INDEMNITY
Consultant shall indemnify City, its agents, officers, representatives and
employees against liability, including costs, for infringement of any United States' letters
patent, trademark, or copyright infringement, including costs, contained in Consultant's
submittals provided under this Agreement.
-16-
IN WITNESS WHEREOF, the parties have caused this Agreement to be executed
on the day and year first written above.
APPROVED AS TO FORM:
By:
Robin Clauson
Assistant City Attorney
ATTEST:
in
LaVonne Harkless
City Clerk
-17-
CITY OF NEWPORT BEACH
A Municipal Corporation
By:
Mayor Garold B. Adams
City of Newport Beach
HARRIS & ASSOCIATES
EXHIBIT A
.m G d
i'.° t c s y
WAmd 'tom A o U co E
w� c
W 72 c U m o_ E n o
cn
5 A
.W,.
W
M e
W.
E 72 aj o c c
'F c° ° EO 'y^ ... O O O y
O G
A c A ❑ 2° d
to yy+F y
y O r ?
t6 A U U N y CL O O O
en
tp p°
a
i
�_ G c A 0.c
LL. N t,°., L ,0 N �.. W ^
91,
O X ❑ N '� W 'O 6FJ d°
vpOA� .5E oA a a'� �o
v
72 y N Fri .ti d � OU d r°i
91,
a. y
°, F
9x ° ow° v a 9a o:wO w E 41. 0 O A
d V.
W a.
R'
.0 : y •a � d':.
W IL U N
Cc C . d O .00
c. 2 V
y > 8 �+
O a
ci d A F ° A td y H F
7
W
�y
/r/�
W
A? 0 7
0 d E
a
u o
d
en v
7
0
0
D
a w U
U� o W
a
y
N�
� a: Z
3
N
i
N
4
' c. "
�'". W
o �
�
❑
c.
F
_
W
W
��
v❑
� V.
m
v
U y
.5
u
w
O U
r3 N
N
'�
OA U ..
Q
..
❑
A � A «
U
ebo a
'D
X aio
.0
3 ,s o r
v
Z
X O v7i Q
U U
'O U
x
i" GO A A GpC
4
� �'� T
❑ 7
CFO
F X
N
0
A
r
r U A U G�
FO
QO
LL
O v
E A w A
a F
o o
E
a... o ❑
�- v
pv
E U .v U
°
N 0. dd
yG
W
_
O
7
v
rz
N
4i
O
0
G
G
o
0
q
c
v
v
v
G
7
W
W
c'
d
O y� �`
17 N O
d�LA
aCi.Y N
�^
0
O
O
p
U C
p
N
C U
C
z >•
F
ti N U O V
Q�
f^ RS w'
a
d
d
d
_
N
^
O
0 >
V
O^
c
3 °
y
91,
b
w��
y
o
C
Z.
c
c
a
b 0
d� W
.m.
O
2
�.
A a 7'p
�
91,
6
Ab
v
a 0
0
o❑
N .^
a❑
A❑
v
y
y
O
v w
ca y
A >+ C
p
17
O«
ci O C
O >.
.0 w C C
U1 P O
v
o
mP F�.o
E
O° c
4 y
y X O d
O
g. o
o
O
'
d'
O�
°° w
A 0 0
U
C CC N
C G >.'.C.
O
m
o A
❑
>
o E
a
C
m
y
P.
U
C
w d
y^
w
V.
r d d
Ea¢m
o
fl*0u
�E
V
m
00
yoy
c
o
Aoo'$
A'a�°A�
Eve
aoa°a
«r
O
ig O CJ N
O y U U O Vl
a G
O f0 V
F' V U N
yv
Gv0vi
Od3O 0'7
y
«0.5
OOD'O
O
o
^S
z
7°
Em A
E c => c
A
o
�n
s°
OrG�
vE
Ad =xOOV
oa
0MZ�4
°� ❑m
m c
v my E
:
a;;
A .=
vdQ
�OO�
`
¢v
O.E,o1v00
a.�V
a Eos�
w V z ..
A.
W
V
d
a
L6
N
E
O
❑
A
b
7
e0
m
LLI
J
.a°
.ao
Q
o
0 '0
y 0
Uv
Q
w
7
.
� o
o
G 3
.0 OD
c
c0.a .o N
U v
m
0
U
LLI
E A
F
E
u
4pZvu
zwz4 w
m
IL
U
U
A
w
d
v
v
L
W
°
°e
o
k U
a
a
E
W
U
M
0
U
Q
O
O
E
�
y
'O
G
N
N
O O
7
Z
Z
V
c
u c
w .0
w .0
o
•J U
c y
O
m'
o
E
LL
❑ o
c v
a° v
m G
n G
U'>
c o s
N U
N U
E
a
.r
'� ...
O
m
y .�
w'0
o 0
u
_
c^
E U
o o v
U E
o o �`
u en
U�
U U
x c
N
d
�
U
m
V
W
c
Q
.. CC
0
z
U
v
3
S
N
F
R
E
d
IWY
m
o
o
X
v
N
V
a
V
=
w
a
w
U
v
August 22, 2001
Mr. Bill Patapoff, P.E.
City of Newport Beach
Public Works Department
3300 Newport Beach
PO Box 1768
Newport Beach, California 92658
Re: City of Newport Beach
Balboa Village Improvements
Dear Bill:
Harris & Associates
Program Managers
Construction Managers
Civil Engineers
Enclosed please find Harris & Associates final cost proposal for construction management services for
the Balboa Village Improvement Project in the amount of $361,100.00 based on the attached fee
breakdown dated August 22, 2001.
We value our relationship with the City and look forward to the opportunity to continue working with
you and your staff.
Respectfully,
Harris & Associates, Inc.
fG 6r. FP E.
Project Director
cc: D. Seevers
O. Dandashi
34 Executive Park, Suite 150 Irvine, California 92614 -4705 949.655.3900 FAX 949.655.3995 irvine @harris- assoc.com
Project Fee - Final
Phase I
August 22, 2001
Percent Construction Cost 10.32%
Assumptions:
Construction cost is based on $3.5 million.
Overtime, Rain, Holidays, and potential time extensions may result in additional Construction Management Services.
This cost estimate provides an estimate of the cost of the construction management services based upon an assumed schedule
of construction that may differ from the actual schedule.
Should the actual schedule require more or less Construction Management services that currently proposed adjustments
to this estimate may be required.
Harris & Associates
Program Managers
Construction Managers
Civil Engineers
2001
1 2002
Sep
I Oct
Nov
I Dec
I Jan
Feb Mar A r
Mav
Jun
Task 1 - Pre - Construction
Task 2 - Construction
Task 3 - Project Close Out
Staffing Plan
2001
2002
Project Total$
Utilization
Hour y
Rata
Sep
Oct
Nov
Decl
Jan
Feb
Mar
Apr
Ma
Jun
I Total
Project Director 1
5% 1
150.00
8
8
8
8
8
8
8
8
8
1 72
10,800.00
Construction Manager
100% 1
135.00
80
160
160
160
160
160
160
160
172,800.00
:!!:L!!
Inspector
100%
95.00
40
160
160
160
160
160
160
160
80
1 1240
117,800.00
Contract Administration / Labor Compliance
16%
50.00
20
24
24
24
24
24
24
24
40
228
11,400.00
Materials Tessin : NINYO & MOORE
32.300.00
32,300.00
Survey: COAST SURVEYING Check Only)
6,000.00
6,000.00
Field Office
10,000.00
10,000.00
Total
0
1 1481
352
1352
1 352
352
352
352
352
208
2820
$361,100.00
Percent Construction Cost 10.32%
Assumptions:
Construction cost is based on $3.5 million.
Overtime, Rain, Holidays, and potential time extensions may result in additional Construction Management Services.
This cost estimate provides an estimate of the cost of the construction management services based upon an assumed schedule
of construction that may differ from the actual schedule.
Should the actual schedule require more or less Construction Management services that currently proposed adjustments
to this estimate may be required.
Harris & Associates
Program Managers
Construction Managers
Civil Engineers
1
_. �;x PARKING LOT
NY
16' WATER
MAIN
STORM DRAIN N
ALLEY 256 -S I l(n ALLEY 256 -T 1 o ALLEY 256 -U
OCEAN FRONT
T-41 ;F.' �dilililil
r'r ; i11�111111� L
I� I
Q
h ALLEY 256 -V
ril
PENINSULA
PARK
�BALBOA PIER
RESTROOM
BALBOA VILLAGE IMPROVEMENT PROJECT - PHASE 1
NOT TO SCALE
LOCATION MAP