HomeMy WebLinkAboutS12 - Back Bay Science CenterSeptember 9, 2003
Agenda Item No. S12
CITY OF NEWPORT BEACH
CITY COUNCIL STAFF REPORT
TO: HONORABLE MAYOR AND MEMBERS OF THE CITY COUNCIL
FROM: Public Works Department
Lloyd Dalton, P.E.
949 - 644 -3311
Idalton @City.newport- beach.ca.us
SUBJECT: BACK BAY SCIENCE CENTER — APPROVAL OF PROFESSIONAL
SERVICES AGREEMENT WITH RON YEO, FAIA ARCHITECT, INC.
RECOMMENDATIONS:
As listed in the August 26, 2003 Agenda Item concerning this project (copy attached).
DISCUSSION:
Additional information was requested by City Council to clarify the August 26, 2003 staff
report. Accordingly, the item was continued from that agenda.
The clarification concerns wording contained in Sentence 3 of the last paragraph of Page
2 of the report. The wording "In addition to the architectural design work that Ron Yeo will
provide, professional engineering subconsultants will be retained for structural, civil,
mechanical, and electrical design." is incorrect. The aforementioned subconsultants are
proposed to be retained and supervised by Ron Yeo, FAIA Architect, Inc., and
compensation for the subconsultants is included in Yeo's fee proposal.
Staff has met with Mayor Pro Tern Ridgeway to explain the miscommunication.
Prepared by: Submitted by,; >!
OKt:
VfAew
.
LI d Dalton, PE Stephen . Badum, PE
esign Engineer Public^orks Director
CITY OF NEWPORT BEACH
CITY COUNCIL STAFF REPORT
Agenda Item No. s
August 26, 2003
TO: HONORABLE MAYOR AND MEMBERS OF THE CITY COUNCIL
FROM: Public Works Department
Lloyd Dalton, P.E.
949 - 644 -3311
Idalton @city.newport- beach.ca.us
SUBJECT: BACK BAY SCIENCE CENTER — APPROVAL OF PROFESSIONAL
SERVICES AGREEMENT WITH RON YEO, FAIA ARCHITECT, INC.
RECOMMENDATIONS:
1. Approve a final design Professional Services Agreement with Ron Yeo, FAIA
Architect, Inc., for $363,000, and authorize the Mayor and the City Clerk to
execute the Agreement.
2. Approve a Budget Amendment establishing a contribution account in the amount
of $153,000 for the California Department of Fish and Game Federal grant funds
in Account No. 7251- C0310600.
DISCUSSION:
The Back Bay Science Center (previously named the Marine Studies Center) is proposed
to be constructed on Shellmaker Island in the Upper Newport Bay Ecological Preserve on
land owned by the State of California and managed by the Department of Fish and
Game. The project has been undergoing preliminary design since early 2002 and, as
currently proposed, consists of three separate buildings totaling approximately 13,000
square feet connected with walkways and roof coverings. A copy of the current site plan
is attached for reference.
The Department of Fish and Game (DF &G) will use one building for their administrative
offices replacing the double -wide modular units they presently occupy. A second building
will be used by DF &G as an educational laboratory in conjunction with local middle
schools, high schools, community colleges, and universities. The largest building will be
L- shaped with the Orange County Health Care Agency using one wing as their
permanent Water Quality Laboratory replacing the triple -wide modular unit that the City
arranged to have installed on the site approximately one year ago and is currently being
used as the Temporary Water Quality Laboratory. The other wing will have a visitors
restroom area along with spaces for the storage of DF &G boats and maintenance
equipment as well as a small repair shop area.
SUBJECT: Back Bay Science Center - Approval of Professional Services Agreement with Ron Yee, FAIA Architect, Inc.
August 26, 2003
Page 2
As a separate project, the University of California at Irvine (UCI) intends to replace their
existing 3,000 square foot crew building with a new 6,000 square foot structure to house
their men and women crew teams. The existing building was constructed more than 30
years ago when UCI's rowing program had only a men's crew team.
In addition to the four proposed buildings, the overall Shellmaker Island project includes
site improvements for access and parking, landscaping with native vegetation, bio-
filtration marsh basins for surface runoff, salt -water wetlands restoration and expansion,
and a perimeter pathway system connecting a series of eight education stations. The
objective is to provide an educational setting for the study of water quality, wildlife, and
plant life in an estuarine environment.
The FY 2001 -2002 budget allocated $500,000 from the American Trader Settlement
Funds for the Marine Studies Center project on Shellmaker Island. On October 9, 2001,
the City Council authorized installation of the modular units for the County's Temporary
Water Quality Laboratory and directed staff to proceed with project preliminary design and
to initiate a cooperative agreement with the various agencies involved. On April 11, 2002,
the City Council approved an agreement with DF &G to implement design and
construction of the Shellmaker Island project and accepted the $1.000,000 federal grant
DF &G had obtained.
CURRENT STATUS:
Preliminary design work for the project has been done by Ron Yeo, FAIA Architect, Inc.
since early 2002 and is now complete. Mr. Yeo's work was performed under a
Professional Services Agreement with the City and included doing research as to needs
and objectives, meeting with prospective users of the facilities, and preparing numerous
site and building layouts with corresponding cost estimates. Included in the scope of
services was preparation of a topographic survey and map and preparation of
geotechnical reports based on field investigation and laboratory analysis. A total of
$120,000 has been authorized for this completed preliminary design work.
The current estimated construction cost for the three buildings (UCI crew building is
excluded) is $3,240,000. Including the cost for design, construction management,
materials testing, permits, and a 10% construction contract contingency, the total
estimated project cost is $4,100,000.
A proposal has been received from Ron Yeo, FAIA Architect, Inc. to provide final design
of the project. The total cost of $363,000 is proposed for such final design services which
consists of three phases: design development, contract documents, and support during
construction. In addition to the architectural design work that Ron Yeo will provide,
professional engineering subconsultants will be retained for structural, civil, mechanical,
and electrical design. The final design proposal also includes the services of a irrigation
system designer. Ron Yeo has completed design services for numerous City projects
over the years; the more recent ones being public restroom buildings at Bob Henry Park,
Balboa Village (Washington Street), and the Bonita Canyon Sports Park. Mr. Yeo also
performed the design for the Interpretive Center constructed by the County of Orange
SUBJECT: Back Bay Science Center- Approval of Professional Services Agreement with Ron Yen, FAIA Architect, Inc.
August 26, 2003
Page 3
adjacent to University Drive at the "top" of Upper Newport Bay. He is well qualified and
his familiarity and background knowledge of this proposed project are invaluable. Staff
recommends approval of the Professional Services Agreement for the final design of the
Back Bay Science Center.
Environmental Review:
A negative declaration has been prepared for the Back Bay Science Center with the
Calfornia Department of Fish & Game as the lead agency. The document was prepared
by Civic Solutions under an Agreement with the City of Newport Beach. The comment
period closed August 22, 2003, and a Notice of Completion is expected to be issued by
DF &G no later than September 30, 2003.
Funding Availability:
The FY 2003 -2004 budget contains a balance of $238,000 of American Trader
Settlement Funds from the $500,000 initial allocation for the Shellmaker Island project.
The balance of those funds are available to pay for the project's final design. In addition,
staff is recommending approval of a Budget Amendment establishing a contribution
account for $153,000 of Federal grant money. The County of Orange has set aside
$1,230,000 to pay for the Water Quality Laboratory building and those funds will be
added to the contribution account during the next six months when an appropriate
Cooperative Agreement is entered into with the County. Additional revenue sources are
being sought to increase the contribution account to meet the estimated construction
costs.
Upon approval of the proposed Budget Amendment, funds from the following accounts
are available to cover the cost of the Professional Services Agreement for final design of
the Back Bay Science Center:
Account Description
Shellmaker Island Marine Studies Center
Shellmaker Island Contributions
Submitted by:
Richard ston, PE
Acting Public Works Director
Attachment: Location Map
Professional Services Agreement
Account Number Amount
7295- C0310600 $210,000
7251- C0310600 $153,000
Total $363,000
,\
i I
h i � r
F `a� � N
.OG :'
�\
�' \ ' i
,.b i.
``V ..�, r/ ilk
1 M,
C `' /t . // }II �
w - I
� ` a
p� � _ /i•.
O Q � �'�
O Q � r,—,,
I ;�
_ ;l � s
,,
i" V � `��
%?'
' %�
'�� /� _ �
. i i� �� Uw � �,i
c
� `� 4�
� ` < ' r
w
_ - � %,
1
r � �� ;
o��
r, ��
s
0
���d axs
e,.N3�3��3,�a::a�da
i I
h i � r
F `a� � N
.OG :'
�\
�' \ ' i
,.b i.
``V ..�, r/ ilk
1 M,
C `' /t . // }II �
w - I
� ` a
p� � _ /i•.
O Q � �'�
O Q � r,—,,
I ;�
_ ;l � s
,,
i" V � `��
%?'
' %�
'�� /� _ �
. i i� �� Uw � �,i
c
� `� 4�
� ` < ' r
w
_ - � %,
1
r � �� ;
o��
r, ��
s
0
PROFESSIONAL SERVICES AGREEMENT
WITH RON YEO, FAIA, ARCHITECT, INC.
FOR BACK BAY SCIENCE CENTER
ON SHELLMAKER ISLAND
THIS AGREEMENT, entered into this day of 2003, by and
between the City of Newport Beach , a Municipal Corporation (hereinafter referred to as
"City "), and Ron Yeo, FAIA Architect, Inc., whose address is 500 Jasmine Avenue,
Corona del Mar, California, 92625, (hereinafter referred to as "Consultant'), is made with
reference to the following:
RECITALS
A. City is a Municipal Corporation duly organized and validly existing under the
laws of the State of California with the power to carry on its business as it is
now being conducted under the statutes of the State of California and the
Charter of City.
B. City is planning to implement the design and construction of the Back Bay
Science Center on Shellmaker Island in the Upper Newport Bay Ecological
Preserve ('Project').
C. City desires to engage Consultant to provide architectural and engineering
services for final design of the Project as outlined in the Scope of Services
attached hereto as Exhibit "A" and upon the terms and conditions contained
in this Agreement.
D. The principal members of Consultant are for purpose of this Project is Ron
Yeo, FAIA Architect.
E. City has solicited and received a proposal from Consultant, has reviewed
S!
the previous experience and evaluated the expertise of Consultant, and
desires to contract with Consultant under the terms and conditions provided
in this Agreement.
NOW, THEREFORE, it is mutually agreed by and between the undersigned
parties as follows:
The term of this Agreement shall commence on the 27th day of August, 2003, and
shall terminate on the 30th day of June, 2005, unless terminated earlier as set forth
herein.
2. SERVICES TO BE PERFORMED
Consultant shall diligently perform all the duties set forth in the Scope of Services,
attached hereto as Exhibit "A" and incorporated herein by reference.
3. COMPENSATION TO CONSULTANT
City shall pay Consultant for the services in accordance with the provisions of this
Section and the scheduled billing rates set forth in Exhibit "B" attached hereto and
incorporated herein by reference. No rate changes shall be made during the term of this
Agreement without prior written approval of City. Consultant's compensation for all work
performed in accordance with this Agreement, including all reimbursable items and
subconsultant fees, shall not exceed the total contract price of Three Hundred Sixty -
Three Thousand Dollars ($363,000).
3.1 Consultant shall maintain accounting records of its billings which includes
the name of the employee, type of work performed, times and dates of all work which is
billed on an hourly basis and all approved incidental expenses including reproductions,
-2-
computer printing, postage and mileage.
3.2 Consultant shall submit monthly progress invoices to City payable by City
within thirty (30) days of receipt of invoice, subject to the approval of City.
3.3 Consultant shall not receive any compensation for extra work without prior
written authorization of City. Any authorized compensation shall be paid in accordance
with the schedule of the billing rates as set forth in Exhibit "B ".
3.4 City shall reimburse Consultant only for those costs or expenses which
have been specifically approved in this Agreement, or specifically approved in advance
by City. Such cost shall be limited and shall include nothing more than the following costs
incurred by Consultant:
A. The actual costs of subconsultants for performance of any of the services
which Consultant agrees to render pursuant to this Agreement which have
been approved in advance by City and awarded in accordance with the
terms and conditions of this Agreement.
B. Actual costs and /or other costs and /or payments specifically authorized in
advance in writing and incurred by Consultant in the performance of this
Agreement.
3.5 Notwithstanding any other paragraph or provision of this Agreement,
beginning on the effective date of this Agreement, City may withhold payment of ten
percent (10 %) of each approved payment as approved retention until all services under
this Agreement have been substantially completed.
4. STANDARD OF CARE
4.1 All of the services shall be performed by Consultant or under Consultant's
-3-
supervision. Consultant represents that it possesses the professional and technical
personnel required to perform the services required by this Agreement and that it will
perform all services in a manner commensurate with community professional standards.
All services shall be performed by qualified and experienced personnel who are not
employed by City nor have any contractual relationship with City. Consultant represents
to City that it has or shall obtain all licenses, permits, qualifications and approvals required
of its profession. Consultant further represents that it shall keep in effect all such
licenses, permits, and approvals during the term of this Agreement.
4.2 Consultant shall not be responsible for delay, nor shall Consultant be
responsible for damages or be in default or deemed to be in default by reason of strikes,
lockouts, accidents, acts of God, failure of City to furnish timely information or to promptly
approve or disapprove Consultant's work, delay or faulty performance by City,
contractors, or governmental agencies, or any other delays beyond Consultant's control.
S. INDEPENDENT PARTIES
City retains Consultant on an independent contractor basis and Consultant is not
an employee of City. The manner and means of conducting the work are under the
control of Consultant, except to the extent they are limited by statute, rule or regulation
and the expressed terms of this Agreement. Nothing in this Agreement shall be deemed
to constitute approval for Consultant or any of Consultant's employees or agents to be the
agents or employees of City. Consultant shall have the responsibility for and control over
the details and means of performing the work provided that Consultant is in compliance
with the terms of this Agreement. Anything in this Agreement which may appear to give
City the right to direct Consultant as to the details of the performance of the services or to
13
exercise a measure of control over Consultant shall mean only that Consultant shall
follow the desires of City with respect to the results of the services.
6. COOPERATION
Consultant agrees to work closely and cooperate fully with City's designated
Project Administrator, and any other agencies which may have jurisdiction or interest in
the work to be performed. City agrees to cooperate with Consultant on Project.
7. PROJECT MANAGER
Consultant shall assign Project to a Project Manager, who shall coordinate all
phases of Project. This Project Manager shall be available to City at all reasonable times
during term of Project. Consultant has designated Ron Yeo to be its Project Manager.
Consultant shall not bill any personnel to Project other than those personnel identified in
Exhibit "B ", whether or not considered to be key personnel, without City's prior written
approval by name and specific hourly billing rate. Consultant shall not remove or
reassign any personnel designated in this Section or assign any new or replacement
person to Project without the prior written consent of City. City's approval shall not be
unreasonably withheld with respect to removal or assignment of non -key personnel.
Consultant, at the sole discretion of City, shall remove from Project any of its
personnel assigned to the performance of services upon written request of City.
Consultant warrants it will continuously furnish the necessary personnel to complete
Project on a timely basis as contemplated by this Agreement.
8. TIME OF PERFORMANCE
Time is of the essence in the performance of the services under this Agreement
and Consultant shall perform the services in accordance with the schedule specified
-5-
below. The failure by Consultant to strictly adhere to the schedule may result in
termination of this Agreement by City and assessment of damages against Consultant for
delay. Notwithstanding the foregoing, Consultant shall not be responsible for delays,
which are due to causes beyond Consultant's reasonable control. However, in the case
of any such delay in the services to be provided for Project, each party hereby agrees to
provide notice to the other party so that all delays can be addressed.
8.1 Consultant shall submit all requests for extensions of time for performance
in writing to the Project Administrator not later than ten (10) calendar days after the start
of the condition, which purportedly causes a delay, but not later than the date upon which
performance is due. The Project Administrator shall review all such requests and may
grant reasonable time extensions for unforeseeable delays, which are beyond
Consultant's control.
8.2 For all time periods not specifically set forth herein, Consultant shall
respond in the most expedient and appropriate manner under the circumstances by
telephone, fax, hand delivery or mail.
9. CITY POLICY
Consultant shall discuss and review all matters relating to policy and project
direction with the Project Administrator in advance of all critical decision points in order to
ensure that Project proceeds in a manner consistent with City goals and policies.
10. CONFORMANCE TO APPLICABLE LAW REQUIREMENT
All work prepared by Consultant shall conform to applicable city, county, state and
federal law, regulations and permit requirements and be subject to approval of the Project
Administrator and City Council.
M
11. PROGRESS
Consultant is responsible to keep the Project Administrator and /or his /her duly
authorized designee informed on a regular basis regarding the status and progress of the
work, activities performed and planned, and any meetings that have been scheduled or
are desired.
12. HOLD HARMLESS
Consultant shall indemnify, defend, save and hold harmless City, its City Council,
boards and commissions, officers and employees from and against any and all loss,
damages, liability, claims, allegations of liability, suits, costs and expenses for damages of
any nature whatsoever, including, but not limited to, bodily injury, death, personal injury,
property damages, or any other claims arising from any and all negligent acts or
omissions of Consultant, its employees, agents or subcontractors in the performance of
services or work conducted or performed pursuant to this Agreement, excepting only the
sole negligence or willful misconduct of City, its officers or employees, and shall include
attorneys' fees and all other costs incurred in defending any such claim. Nothing in this
indemnity shall be construed as authorizing any award of attorneys' fees in any action on
or to enforce the terms of this Agreement.
13. INSURANCE
Without limiting consultant's indemnification of City, and prior to commencement
of work, Consultant shall obtain and provide and maintain at its own expense during the
term of this Agreement policy or policies of liability insurance of the type and amounts
described below and satisfactory to City. Certification of all required policies shall be
signed by a person authorized by that insurer to bind coverage on its behalf and must be
-7-
filed with City pghor to exercising any right or performing any work pursuant to this
Agreement. Except for workers compensation and errors and omissions insurance, all
insurance policies shall add City, its elected officials, officers, agents, representatives and
employees as additional insureds for all liability arising from Consultant's services as
described herein.
All insurance policies shall be issued by an insurance company currently
authorized by the Insurance commissioner to transact the business of insurance in the
State of California, with an assigned policyholders' Rating of A (or higher) and Financial
size Category Class VII (or larger) in accordance with the latest edition of Bests Key
Rating guide: unless otherwise approved by the City Risk Manager. The following
policies are required:
A. Worker's compensation insurance, including a 'Waiver of Subrogation"
clause, covering all employees and principals of Consultant, per the laws of
the State of California.
B. Commercial general liability insurance original certificate and
endorsement (which includes additional insured and primary and non-
contributory wording), covering third party liability risks, including without
limitation, contractual liability, in a minimum amount of $1 million combined
single limit per occurrence for bodily injury, personal injury and property
damage. If commercial general liability insurance or other form with a
general aggregate is used, either the general aggregate shall apply
separately to this Project, or the general aggregate limit shall be twice the
occurrence limit.
C. Commercial auto liability and property insurance, including additional
insured wording, covering any owned and rented vehicles of Consultant in
a minimum amount of $1 million combined single limit per accident for
bodily injury and property damage.
D. Professional errors and omissions insurance, which covers the services, to
be performed in connection with this Agreement in the minimum amount of
One Million Dollars ($1,000,000).
Said policy or policies shall be endorsed to state that coverage shall not be
canceled by either party, except after thirty (30) days' prior notice has been given in
writing to City. Consultant shall give City prompt and timely notice of claim made or suit
instituted arising out of Consultant's operation hereunder. Consultant shall also procure
and maintain, at its own cost and expense, any additional kinds of insurance, which in its
own judgment may be necessary for its proper protection and prosecution of the work.
Consultant agrees that in the event of loss due to any of the perils for which it has
agreed to provide comprehensive general and automotive liability insurance, Consultant
shall look solely to its insurance for recovery. Consultant hereby grants to City, on behalf
of any insurer providing workers compensation, comprehensive general, and automotive
liability insurance to either Consultant or City with respect to the services of Consultant
herein, a waiver of any right of subrogation, which any such insurer of said Consultant
may acquire against City by virtue of the payment of any loss under such insurance.
14. PROHIBITION AGAINST TRANSFERS
Consultant shall not assign, sublease, hypothecate or transfer this Agreement or
any of the services to be performed under this Agreement, directly or indirectly, by
Wa
operation of law or otherwise without prior written consent of City. Any attempt to do so
without consent of City shall be null and void.
The sale, assignment, transfer or other disposition of any of the issued and
outstanding capital stock of Consultant, or of the interest of any general partner or joint
venturer or syndicate member or co- tenant if Consultant is a partnership or joint- venture
or syndicate or co- tenancy, which shall result in changing the control of Consultant, shall
be construed as an assignment of this Agreement. Control means fifty percent (50 %) or
more of the voting power, or twenty -five percent (25 %) or more of the assets of the
corporation, partnership orjoint- venture.
15. OWNERSHIP OF DOCUMENTS
Each and every report, draft, work product, map, record and other document
reproduced, prepared or caused to be prepared by Consultant pursuant to or in
connection with this Agreement shall be the exclusive property of City. All
improvement/construction plans shall be prepared with indelible waterproof ink or
electrostaticly plotted on standard 24 -inch by 36 -inch mylar with a minimum
thickness of 3 mils. (A copy of the City of Newport Beach Standard Design
Requirements is available from the Public Works Department).
Documents, including drawings and specifications, prepared by Consultant
pursuant to this Agreement are not intended or represented to be suitable for reuse by
City or others on any other project. Any use of completed documents for other projects
and any use of incomplete documents without specific written authorization from
Consultant will be at City's sole risk and without liability to Consultant. Further, any and
all liability arising out of changes made to Consultant's deliverables under this Agreement
SN11
by City or persons other than Consultant is waived as against Consultant and City
assumes full responsibility for such changes unless City has given Consultant prior notice
and has received from Consultant written consent for such changes.
Consultant shall, at such time and in such forms as City may require, furnish
reports concerning the status of services required under this Agreement.
16. CONFIDENTIALITY
The information, which results from the services in this Agreement, is to be kept
confidential unless City authorizes the release of information.
17. CITY'S RESPONSIBILITIES
In order to assist Consultant in the execution of his responsibilities under this
Agreement, City agrees to provide the following:
A. City will provide access to and upon request of Consultant, provide one
copy of all existing record information on file at City. Consultant shall be
entitled to rely upon the accuracy of data information provided by City or
others without independent review or evaluation. City will provide all such
materials in a timely manner so as not to cause delays in Consultant's work
schedule.
B. Provide blueprinting, CADD plotting, copying and other services through
City's reproduction company for each of the required submittals. Consultant
will be required to coordinate the required submittals with City's
reproduction company. All other reproduction will be the responsibility of
Consultant and as defined above.
-11-
C. City staff will provide usable life of facilities criteria and provide information
with regards to deficient facilities.
D. City will prepare and provide to Consultant street base digital file in
AutoCAD (DWG) compatible format.
18. ADMINISTRATION
The Public Works Department will administer this Agreement. Lloyd Dalton, P.E.
shall be considered the Project Administrator and shall have the authority to act for City
under this Agreement. The Project Administrator or his /her authorized representative
shall represent City in all matters pertaining to the services to be rendered pursuant to
this Agreement.
19. RECORDS
Consultant shall keep records and invoices in connection with the work to be
performed under this Agreement. Consultant shall maintain complete and accurate
records with respect to the costs incurred under this Agreement. All such records shall be
clearly identifiable. Consultant shall allow a representative of City during normal business
hours to examine, audit and make transcripts or copies of such records. Consultant shall
allow inspection of all work, data, documents, proceedings and activities related to the
Agreement for a period of three (3) years from the date of final payment under this
Agreement.
20. WITHHOLDINGS
City may withhold payment of any disputed sums until satisfaction of the dispute
with respect to such payment. Such withholding shall not be deemed to constitute a
failure to pay according to the terms of this Agreement. Consultant shall not discontinue
-12-
work as a result of such withholding. Consultant shall have an immediate right to appeal
to the City Manager or his designee with respect to such disputed sums. Consultant shall
be entitled to receive interest on any withheld sums at the rate of seven percent (7 %) per
annum from the date of withholding of any amounts found to have been improperly
withheld.
21. ERRORS AND OMISSIONS
In the event of errors or omissions that are due to the negligence or professional
inexperience of Consultant which result in expense to City greater than what would have
resulted if there were not errors or omissions in the work accomplished by Consultant, the
additional design, construction and /or a restoration expense shall be borne by Consultant.
Nothing in this paragraph is intended to limit City's rights under any other sections of this
Agreement.
22. CITY'S RIGHT TO EMPLOY OTHER CONSULTANTS
City reserves the right to employ other consultants in connection with Project.
23. CONFLICTS OF INTEREST
A. Consultant or its employees may be subject to the provisions of the
California Political Reform Act of 1974 (the "Act "), which (1) requires such
persons to disclose financial interest that may foreseeably be materially
affected by the work performed under this Agreement, and (2) prohibits
such persons from making, or participating in making, decisions that will
foreseeably financially affect such interest.
B. If subject to the Act, Consultant shall conform to all requirements of the Act.
Failure to do so constitutes a material breach and is grounds for termination
-13-
of this Agreement by City. Consultant shall indemnify and hold harmless
City for any and all claims for damages resulting from Consultant's violation
of this Section.
24. SUBCONSULTANT AND ASSIGNMENT
Except as specifically authorized under this Agreement, the services to be
provided under this Agreement shall not be assigned, transferred, contracted or
subcontracted without prior written approval of City.
25. NOTICES
All notices, demands, requests or approvals to be given under this Agreement
shall be given in writing and conclusively shall be deemed served when delivered
personally or on the third business day after the deposit thereof in the United States mail,
postage prepaid, first class mail, addressed as hereinafter provided.
All notices, demands, requests or approvals from Consultant to City shall be
addressed to City at:
City of Newport Beach
Public Works Department
3300 Newport Boulevard
Newport Beach, CA, 92658 -8915
Phone: (949) 644 -3311
Fax: (949) 644 -3318
All notices, demands, requests or approvals from City to Consultant shall be
addressed to Consultant at:
Ron Yeo
Ron Yeo, FAIA Architect, Inc.
500 Jasmine Avenue
Corona del Mar, CA 92625
Phone: (949) 644 -8111
Fax (949) 644 -0449
-14-
26. TERMINATION
In the event either part hereto fails or refuses to perform any of the provisions
hereof at the time and in the manner required hereunder, that party shall be deemed in
default in the performance of this Agreement. If such default is not cured within a period
of two (2) days, or if more than two (2) days are reasonably required to cure the default
and the defaulting party fails to give adequate assurance of due performance within two
(2) days after receipt of written notice of default, specifying the nature of such default and
the steps necessary to cure such default, the nondefaulting party may terminate the
Agreement forthwith by giving to the defaulting party written notice thereof.
26.1 City shall have the option, at its sole discretion and without cause, of
terminating this Agreement by giving seven (7) days' prior written notice to Consultant as
provided herein. Upon termination of this Agreement, City shall pay to Consultant that
portion of compensation specified in this Agreement that is earned and unpaid prior to the
effective date of termination.
27. COMPLIANCES
Consultant shall comply with all laws, state or federal and all ordinances, rules and
regulations enacted or issued by City.
28. WAIVER
A waiver by either party of any breach, of any term, covenant or condition
contained herein shall not be deemed to be a waiver of any subsequent breach of the
same or any other term, covenant or condition contained herein whether of the same or a
different character.
-15-
29. INTEGRATED CONTRACT
This Agreement represents the full and complete understanding of every kind or
nature whatsoever between the parties hereto, and all preliminary negotiations and
agreements of whatsoever kind or nature are merged herein. No verbal agreement or
implied covenant shall be held to vary the provisions hereon. Any modification of this
Agreement will be effective only by written execution signed by both City and Consultant.
30. OPINION OF COST
Any opinion of the construction cost prepared by Consultant represents his /her
judgment as a design professional and is supplied for the general guidance of City. Since
Consultant has no control over the cost of labor and material, or over competitive bidding
or market conditions, Consultant does not guarantee the accuracy of such opinions as
compared to contractor bids or actual cost to City.
31. COMPUTER DELIVERABLES
CADD data delivered to City shall include the professional stamp of the engineer
or architect in responsible charge of the work. City agrees that Consultant shall not be
liable for claims, liabilities or losses arising out of, or connected with (a) the modification or
misuse by City, or anyone authorized by City, of CADD data; (b) the decline of accuracy
or readability of CADD data due to inappropriate storage conditions or duration; or (c) any
use by City, or anyone authorized by City, of CADD data for additions to this Project, for
the completion of this Project by others, or for any other project, excepting only such use
as is authorized, in writing, by Consultant. By acceptance of CADD data, City agrees to
indemnify Consultant for damages and liability resulting from the modification or misuse of
such CADD data.
5n
All original drawings shall be submitted to the City in the version of AutoCAD used
by the City, in ".dwg" file format on a CD, and should comply with the City's digital
submission requirements for Improvement Plans. The City will provide AutoCad file of
City Title Sheets. All written documents shall be transmitted to the City in the City's latest
adopted version of Microsoft Word and Excel.
32. PATENT INDEMNITY
Consultant shall indemnify City, its agents, officers, representatives and
employees against liability, including costs, for infringement of any United States' letters
patent, trademark, or copyright infringement, including costs, contained in Consultant's
drawings and specifications provided under this Agreement.
IN WITNESS WHEREOF, the parties have caused this Agreement to be executed
on the day and year first written above.
APPROVED AS TO FORM: CITY OF NEWPORT BEACH
A Municipal Corporation
By:
City Attorney
Steven Bromberg
Mayor
ATTEST: RON YEO, FAIA ARCHITECT, INC.
By: By:
City Clerk Ron Yeo
f :\users \pbw \shared\agreements \fy 03- 04\back bay science center -yeo -final design- 082603.doc
-17-
•
:•u
DATE:
RE
EXHIBIT A
INC. 500 JASMINE AVENUE CORONA DEL MAR, CALIFORNIA 92625 PHONE: (949) 644 -8111 FAX 644 -0449
Lloyd Dalton, City of Newport Beach
Ron
August 19, 2003
Fee Proposal for
Professional Services for the "Back Bay Science Center" Project
Project Scope of Work is based upon the approved schematic plans for three new
structures of approximately 13,000 square feet along with required minimal site
development.
1. Orange County Water Quality lab & Storage /Maintenance /Public Restroom building
2. Department of Fish & Game Teaching Lab Building
3. Department of Fish & Game Administration Building
4. The UCI Crew building is not a part of this scope
The construction budget is $3,500,000. If the existing funding for construction of
$1,560,000 is not increased, the Construction Bid Documents will be formatted by
deleting some structures and or site work in order to meet the available funds. This
concept would utilize some of the existing structures.
PHASES OF DESIGNATED SERVICES
Schematic Design Phase. This Phase has been completed. It is the stage in which
the general scope, conceptual design, and the scale and relationship of components of
the Project are established.
Design Development Phase. This Phase is the stage in which the size and
character of the Project are further refined and described, including architectural,
structural, mechanical and electrical systems, materials, and such other elements as
may be appropriate.
Construction Documents Phase. This Phase is the stage in which the requirements
for the Work are set forth in detail.
Bidding or Negotiations Phase. This Phase is the stage in which bids or negotiated
proposals are solicited and obtained and in which contracts are awarded.
Exhibit A Back Bay Science Center page 1
Construction Support Phase. This phase is the stage in which the work is
performed by one or more Contractors. The scope for assistance within this phase
includes-
1 . Attend the pre - construction meeting
2. Review the Contractor's shop drawings and submittals
3. Provide w ritten responses to the Contractor's requests for information
4. Provide monthly job site visits. Provide a construction observation report for each
visit
5. Prepare the final punch lists for the buildings and site work
Post - Contract Phase. This phase is the stage in which assistance in the Owner's
use and occupancy of the Project is provided.
ARCHITECTURAL Design /Documentation
Project Administration services: Consisting of administrative functions such as
Consultation, Research, Conferences, Communications and Progress reports.
2. Disciplines Coordination /Document Checking: Consisting of Coordination
between the architectural work and the work of engineering and other disciplines
involved in the Project.
3. Schedule DevelopmenWonitoring services: Including the establishment of initial
schedule for Architect's services, decision - making, design, documentation.
Review and update of previously established schedules.
4. Presentation services: Consisting of presentations and recommendations by the
Architect to the following client representatives:
• City Staff
• User groups
• Neighborhood groups & HOA
During the Design Development Phase: Consisting of continued development and
expansion of architectural Schematic Design Documents to establish the final
scope, relationships, forms, size and appearance of the Project throughout:
• Plans, sections and elevations
• Typical construction details
• Final materials selection
• Layouts of Equipment furnished by user groups
• Coordination with Building Official for code review
6. During the Construction Document Phase: Consisting of preparation of Plans &
Specifications based on approved Design Development Documents setting forth in
detail the construction requirements for the Project ready for permits & bidding.
Statement of probable construction costs: @ the Completion of the Design
Development Phase and updated at 90% completion of the construction documents
8. During the Construction Support Phase: Consisting of the following
Attend the pre- construction meeting
Review the Contractor's shop drawings and submittals
Provide written responses to the contractor's requests for information
Provide monthly job site visits.
Provide Construction observation report for each visit
Prepare the final punch list for the building and site work
Exhibit A Back Bay Science Center page 2
CIVIL ENGINEERING DESIGN /DOCUMENTATION
Task 1: Preliminary Grading & Utility Plan:
Prepare a Preliminary Grading & Utility Plan for submittal by the architect for review and
approval. This plan will include preliminary grades and elevations to show general
grading and drainage concepts and preliminary layout of sewer and water facilities.
This preliminary design information will be added to a CADD file of the architect's site
plan and will be based on the Topographic Survey prepared by this office under
separate contact.
Task 2: Horizontal Control Plan:
Prepare a Horizontal Control Plan based on an approved dimensioned site plan provided
by the architect. This would include a computer plot of the site boundary, proposed
building and curb locations and will show critical dimensions. This plan will be used for
coordination purposes with the architect and for staking control during construction.
Task 3: Precise Grading Plan:
Prepare a Precise Grading Plan for the proposed development. This plan will be based
on the Preliminary Grading Plan and Horizontal Control Plan in Tasks 1 and 2 above and
Topographic Survey previously prepared. This will include a quantity /cost estimate for
permit purposes and the required Erosion Control Plan. This assumes no offsite
improvements are required.
Task 4: Onsite Storm Drain Plan:
Prepare an Onsite Storm Drain Plan in conjunction with the Precise Grading Plan. This
plan will show the location, elevations and sizes of the proposed onsite drain lines and
basins. This will include a quantity /cost estimate and the required onsite hydrology.
This assumes connection /discharge to a filtration marsh designed by others.
Task 5: Water and Sewer Plan:
Prepare a Water and Sewer Plan for the proposed development showing public fire
hydrants, fire sprinkler services to the detector checks and domestic water and sewer
services to within five feet of the building. Fire hydrant locations are to be obtained and
supplied by others with fire department approval. This assumes a public onsite water
system to the fire hydrants and detector checks and private sewer system connecting
to the existing pump station. This includes a quantity /cost estimate for permit purposes
and the legal descriptions and sketches required for the easements for the public lines.
The site w ill be designed to accommodate a future UCI Crew Building.
Task 6: Underground Fire Protection Plan (if required):
Prepare an Underground Fire Protection Plan showing the fire sprinkler service from the
detector check provided on the Water Plan above to a fire riser 6 inches above the
building finished floor. This plan will include the required fire department notes and
thrust block details. This plan will be processed through the fire department for their
approval.
Exhibit A Back Bay Science Center page 3
Task 7: Water Quality Management Plan (W.Q.M.P.):
Prepare a Water Quality Management Plan as required by the City prior to permit
issuance which identifies Best Management Practices (BMP's) to prevent and monitor
potential pollutant sources from entering storm water runoff. At time of preparation of
this plan, input will be required from the City of Newport Beach for inclusion within the
plan. This plan will include actions that must be abided by at building occupancy.
Task 8: Storm Water Pollution Prevention Plan (S.W.P.P.P.):
Prepare the required Storm Water Pollution Prevention Plan (S.W.P.P.P.) for the
proposed development which identifies Best Management Practices (BMP's) to prevent
and monitor potential pollutant sources from entering storm water runoff during
construction. We will also aid in the filing of the Notice of Intent (N.O.I.) with the
Regional Water Quality control Board.
Task 9: Specifications:
Prepare the special provision portion of the specification relating to our civil work as
shown on our plans. These mark -ups will be provided to the architect for incorporation
in the overall project specifications.
Task 10: Meetings, Coordination and Processing (T &M Budget):
Provide an allowance for project meetings and project coordination with client and
consultants and processing of plans with governing agencies. This allowance is for
budget purposes only and will be billed on an hourly basis for work as required. This
assumes an allowance of approximately 40 man - hours.
Task 11: Construction Phase Services (T &M Budget):
Provide an allowance for construction phase services as required for the project. This
includes responding to RFI's, providing clarification of the drawings and field visits as
needed. This allowance is for budget purposes only and will be billed on an hourly
basis for work as required. This assumes an allowance of approximately 24 man -
hours.
STRUCTURAL ENGINEERING DESIGN /DOCUMENTATION
DESIGN DEVELOPMENT
• Assist in deterrrining any need for Special Studies
• Provide structural criteria for Geotechnical Consultant
Prepare preliminary foundation layout
Prepare preliminary structural design calculations for typical elements
Prepare preliminary framing layout
CONTRACT DOCUMENTS
Prepare structural design of primary structural system
Designate elements to be designed by specialty engineers & specify design criteria
Assist in coordination w ith Building Official
Provide structural calculations
Provide structural drawings
Review specified submittals
CONSTRUCTION ASSISTANCE
Make site visits at appropriate stage of construction
Exhibit A Back Bay Science Center page 4
ELECTRICAL ENGINEERING DESIGN /DOCUMENTATION
1. Site visit to review existing conditions
2. Required conferences for construction documents
3. Design coordination
4. Electrical drawings and specifications including the following:
a. Interior lighting and controls
b. Convenience, telephone and data outlets
c. Exterior lighting systems including parking area & photometric plans
d. Connection to HVAC equipment
5. Title 24 lighting calculations
6. Electrical plan check corrections
7. Review equipment submittals
8. Normal telephone calls during construction
MECHANICAL ENGINEERING DESIGN /DOCUMENTATION
HVAC: Energy efficient heating, ventilating and air conditioning systems will be provided
for the facility. All equipment and materials w ill be selected for use in a marine
environment. The HVAC systems w ill use natural ventilation for cooling to the greatest
extent possible. Please note the outdoor summer temperature exceeds 80 deg. F 44-
hours per year and 87 deg. F 9 -hours per years. Mechanical ventilation w ill be provided
for restrooms, storage rooms, janitor closets and similar spaces. Exhaust and make -up
air systems w ill be provided for the Water Quality Laboratory fume hood.
Plumbing: The plumbing fixture types and locations will be indicated on the
Architectural drawings; the fixtures and trim will be specified as part of the plumbing
work. The sanitary sewer, water and natural gas utility services will be extended to the
buildings and will include provisions for the future UCI Crew Building. The sizing of the
site utilities will be included in the mechanical design services and furnished to the Civil
Engineer. It will be determined if the existing sewer lift station is adequate or if it will
have to be modified or replaced; the consulting services for the design of the sewer lift
station modification are included in this proposal. The Water Quality Laboratory will have
compressed air, d. I. water, and acid waste and vent systems. A neutralizer tank and
monitor controls will be provided for treatment of the laboratory wastes. All equipment
and materials will be selected for use in a marine environment.
Automatic Fire Sprinkler System: The buildings will be provided with automatic fire
sprinkler systems. The connection to the w ater service as indicated on the Civil plans,
detector check, fire department connection, post indicator valves and fire risers w ill be
indicated on the plumbing draw ings. Design -build specifications w ill be provided for the
fire sprinkler systems. All equipment and materials w ill be selected for use in a marine
environment.
Exhibit A Back Bay Science Center page 5
LANDSCAPE ARCHITECTURAL DESIGN/DOCUMENTATION
1. PRELIMINARY PHASE:
Prepare a preliminary planting plan for submittal to California Coastal Commission in
collaboration with consultants and the Architect .
Review plans with Department of Fish and Wildlife and other on -site agency
representatives.
Z CONSTRUCTION DOCUMENTS PHASE:
Landscape Planting Plan for the dunes, wetlands and fresh water filtration ponds
• Landscape Irrigation Plan w ith drip irrigation for the dunes area only
3. CONSTRUCTION SUPPORT PHASE
Observation of forces to installing plants in the three designated areas.
Assistance from either the Department of Fish and Wildlife or outside consultants
may be required in the w etland and w ater filtration portion of the project, w hich is
not part of this scope.
WETLANDS REHABILITATION DESIGN/DOCUMENTATION
1. PRELIMINARY PHASE:
Prepare a preliminary planting plan for submittal to California Coastal Commission in
collaboration with consultants and the Architect .
Review plans with Department of Fish and Wildlife and other on -site agency
representatives.
Z CONSTRUCTION DOCUMENTS PHASE:
Prepare concept grading plan for the w etland rehab area to be incorporated into the
grading plan by the Civil Engineer
Refine the preliminary planting plan to be incorporated into the landscape planting
plan by the Landscape Plan for the dunes, wetlands and fresh w ater filtration
ponds
Review the landscape Planting Plan
3. CONSTRUCTION SUPPORT PHASE
Observation and monitoring of forces to installing plants in the three designated
areas.
Issue field monitoring reports
4. POST CONSTRUCTIONMONITORNING PHASE
This is not part of this agreement
Exhibit A Back Bay Science Center page 6
ADDITIONAL SERVICES
Services which are not specifically identified herein as services to be performed by the
consultant, are considered "Additional Services" for purposes of this Agreement.
EXCLUSIONS
Consulting services relating to any of the following items are specifically excluded from
this contract at this time.
Agricultural soil testing
"As- Built" drawings
Alternate power source studies
Amphitheater rehab & cover
Blueprinting services for bidding
Bulkhead design
Construction staking or certifications
Courier services, overnight express, etc.
Economic feasibility studies, Project financing
Environmental Studies & Reports
Exhibit & Aquarium design
Full time Construction Management
Furniture, fixture & equipment design
Green House design
Identification, removal and disposal of any hazardous materials within the site or
in existing structures
Irrigation and landscape design
LEED documentation and /or "commissioning"
Monitoring of the growth of the wetlands rehab area after installation
Marketing, Fund raising program
Offsite improvements
Owner /agency and /or coastal commission revisions after approval to proceed
Plan check submittals, fees and permits
Relocation of existing structures
Soils engineering, testing and reports
Specialized foundation design other than a mat foundation
Title Reports, recorded documents, etc.
Trails and teaching station design
UCI Crew Building design
COMPENSATION -To be invoiced monthly on the percentage completed to date
Design Development phase $ 90,099
Construction Document phase 198,901
Construction Administration phase 62.000
Total $ 351,000
Allowance for direct expenses at 1.5 x cost $12,000
If through no fault of the Architect the services covered by this Agreement have not
been completed within 2 years of the date hereof, compensation for the Architect's
services beyond that time shall be appropriately adjusted.
Exhibit A Back Bay Science Center page 7
57,
2
W
Q)
U
(1)
u
C:
Q)
u
Io
Lf)
CO
CID
X
LLJ
C5
0
C5
C5
(D
N
;I-
cr�
(d
6
C14
N
-ci
0
0
0
1 :C-)
0 010
CDD
00,0
00
0000
0
U)i
<
C�
i
C� q; 6,
o'!
6'
6,
1
co�
0
10:
0000
I
P
in
y
I.
io
;
0 Ojo
CID
0
0
-ctl
0666,
OOON.
0
0
;CO
(D mlu')
N
Fi
N
C4 ' 1
L5
NJ
co
idl
0
of
Z
(001"V0.0
1=
N !(D
0-11-
IN
0
0
-,1-
N
N.o
N
Lu
Flo
I
i(D
LU;
03
Lo'j
0
<
0
0
O)o
010,0
0
010
0 0
010
0
0
0
0
010
0
0
0
0
0
010
ojc�
0
0
010 ONO
0
1.6
010
0
0
0
0
Ojo
0
0
0
C3
L6
UX10
0 Olin
0
0' Inlin
0
LOILO
0
0
Lo
Lo
0;0
o
0
Lo
LU
m
co
in
mico
m collmo
In In
OT
in
In
co
in.m
in
In
co
LU
LU
LU
U)
LD
cr.
a)
0
Z
LU
a)
a)
rli
10
10
OI
(1)
-0
!<
.0
Q)j
0
W
cr
C
<
0
01
LU
0
-Fu
Lu
a)
0
0
(D
176
CU
2! 0
a)
a)
0
0
C'
0
2
w
ce
0
i
LLJ
—
Z
0
<
�0
>
a
<I
U)
rno)2EM
I 00
57,
2
W
Q)
U
(1)
u
C:
Q)
u
Io
Lf)
CO
CID
X
LLJ
F
(D
CD
Q)
u
u
U')
CO
X
ui
CD
a)
0
co
0
ON'�N
—oo
M
Lo
(D
N
C'i
m
SO=
-,I-
0
J-�
�
(6
_:
L6
4
C'i
of
N
iLU
U)
-Uc)
<
0
0.1 %
0
olc�
0 c
0
z
LU
0
:0
0
I
0
'uM
0 0
Co.
Cl�
LQ
LQ
C�
(D -Il-
N
N
Nom
O
0
(0;
0
co
N
BIZ
f
LU 0
0
Ij
0
Lol Lo
0
0
010;(
.
610
0
0
COIT
MICOF
�.m
co
m
=:00
I =.col
�.�m
�lm
mm
LU
to
a)
LU
U).
Z
LU
LU
Ol
Z
. LD
a)
0
❑
LU
N
C)
to
0
a)
a)
a)
a)
0
D
<
03
a)
(1)
Lu
E
w
w
Iz
0
O
—
g
0�
,
u
E
Q
0
a)
U
0
LU
j
I
a)
'0
0
co)
U)
I
U—)
F
(D
CD
Q)
u
u
U')
CO
X
ui
0
X
uj
0
oj(:�;O
C �
CD
a)
0
M
i0
0
0
0
MI0.0
0
0
cz�
o,m
cz�
cz�
cz�
N
O;co
=
N
M
mlmlu
=
ID
i=M
m
q0000qo
CD
CD
CD
CD
co
c
0
1-1
N
0
-cl-
M
LLJ
0
M
cc)
N
0
N
N
iU)
C
0
N
-cl-
'I
l<
U)
00100
0
0
0
00
0
0
0
o o
0 OP
0
0
010
0
0
0
0 0 0 0;
010. 0 0
10
0
CD
CD
CD
CD
cl-; Loll, �M-1
U)
co
N
I
121
N
cl�
C\F
05'
0
1
co
co
�IID
(6
U)
z
10
0
o
o o
O;C-) C-) 0 0
0 0 O
0
0
Of q 0
0 q O
O
C'pio.
�
0 0 � In C) 0
Lf3 ) * ,
Ln Lf) 0 0O ol)
LU
m
coi�
mico m
co� m
co 1 m m co
a)
LU
LL
a)
Lu
0
(D
Z
U)
Lu
a)
LU
o
u
LD
.0
0
Z :;
L U;
0
C
C,
N
(D
C
o
0
a)
0
0
cr,
m
<
0
LLJ
<
(1)
M
(D
0
of
LLJ
-mo
Lij
(1)
0�
0
0 LL
>
ill
(4
-E
a)
(1)
o
(30 o
�U)
0
LU
'E
U) I
<
<
< <
<
a)
a)
bobb
-2
<!
IU)
u)
rn
o
�E
Ei
�0—
0
X
uj
L61 EXHIBIT B
RON YEO, FAIA ARCHITECT, INC. 500 JASMINE AVENUE CORONA DEL MAR, CALIFORNIA 92625 PHONE: (949) 644 -8111 FAX 644 -0449
SCHEDULE OF FEES FOR EXTRA SERVICES & DIRECT EXPENCES
SCHEDULE OF FEES ARCHITECT
Principal Architect
Structural Engineering
Project Architect
Senior Design Architect
Design Architect
Senior draftsperson /designer
Intermediate draftsperson /designer
Apprentice draftsperson /designer
Professional administration staff
— Ron Yeo, FAIA Architect Inc
130.00 /HR.
120.00 /HR.
85.00 /HR.
75.00 /HR.
65.00 /HR
55.00 /HR.
50.00 /HR.
40.00 /HR.
50.00 /HR.
SCHEDULE OF FEES CIVIL ENGINEERING — Walden
Principal
Associate
Project Manager
Project Engineer /Land Surveyor
Design Engineer /Land Surveyor
Engineer /Land Surveyor
Assistant Engineer /Designer /Land Surveyor
Senior Draftsman
Draftsman
2 -man Survey Crew
3 -man Survey Crew
& Associates
150.00 /HR.
130.00 /HR.
115.00/HR.
100.00 /HR.
95.00 /HR.
90.00 /HR.
80.00 /HR.
75.00 /HR.
60.00 /HR.
159.00/HR.
191.00/HR.
SCHEDULE OF FEES STRUCTURAL ENGINEERING — ABS / EQE / JTA
Principal
150.00 /HR
Project Structural Engineer
120.00 /HR
Senior Associate
105.00 /HR
Design Engineer
85.00 /HR
Project Draftsperson
75.00 /HR
Draftsperson
65.00 /HR
Clerical
50.00 /HR
SCHEDULE OF FEES MECHANICAL ENGINEERING — F. T.
Principal
Engineer
Senior Designer
Designer
Draftsperson
Clerical
Andrews Inc.
115.00/HR.
100.00 /HR
90.00 /HR
80.00 /HR.
65.00 /HR
50.00 /HR
Exhibit B Back Bay Science Center page 1
SCHEDULE OF FEES ELECTRICAL ENGINEERING — GLP Engineering
Principle
135.00/HR.
Associate
115.00/HR.
Project Manager
100.00 /HR.
Design Drafter
85.00 /HR.
Technical Typist
55.00 /HR.
SCHEDULE OF FEES COST ESTIMATING — Construction Analysts inc.
Senior estimator 90.00 /HR
SCHEDULE OF WETLANDS CONSULTANT — Coastal Resources Management
Senior Biologist
Endangered Species Biologist
Word Processor
100.00 /HR
75.00 /HR
45.00 /HR
SCHEDULE OF FEES LANDSCAPE ARCHITECT — Katzmaier Newell Kehr
Principle
Drafting/Technical
DIRECT EXPENSES (reproduction, etc) AT COST PLUS 15%
125.00/HR
95.00 /HR
Exhibit B Back Bay Science Center page 2
City! of Newport Beach
BUDGET AMENDMENT
2003 -04
E -CT ON BUDGETARY FUND BALANCE:
Increase Revenue Estimates
X Increase Expenditure Appropriations
Transfer Budget Appropriations
SOURCE:
from existing budget appropriations
from additional estimated revenues
X from unappropriated fund balance
EXPLANATION:
NO. BF.- 006
AMOUNT: s153,o00.00
Increase in Budgetary Fund Balance
AND X Decrease in Budgetary Fund Balance
No effect on Budgetary Fund Balance
This budget amendment is requested to provide for the following:
To increase expenditure appropriations and revenue estimates for the Back Bay Science Center.
ACCOUNTING ENTRY:
BUDGETARY FUND BALANCE
Fund Account Description
REVENUE ESTIMATES (360 1)
Fund /Division Account Description
250 4879 Dept of Fish & Game
EXPENDITURE APPROPRIAT IONS (3603)
Signed: A�-
Financial Approval: Adminisjr5Ke Services Director
Signed:
S J:
Administrative App /val: City Manager
City Council Approval: City Clerk
Amount
Debit Credit
$153,000.00
`➢153,000.00
Date
1'r ted�
Date
Description
Division
Number
7251 Contributions
Account
Number
C0310600 Marine Education Facility
Division
Number
Account
Number
Division
Number
Account
Number
Division
Number
Account
Number
Signed: A�-
Financial Approval: Adminisjr5Ke Services Director
Signed:
S J:
Administrative App /val: City Manager
City Council Approval: City Clerk
Amount
Debit Credit
$153,000.00
`➢153,000.00
Date
1'r ted�
Date